Sub: -- Empanelment of Architect/Consulting Civil Engineers in your Bank.

Transcription

1 From, To, The Deputy General Manager, Corporation Bank Zonal Office, Thiruvananthapuram. Dear Sir, Sub: -- Empanelment of Architect/Consulting Civil Engineers in your Bank. I/we have read and understood the press notice/notice in the Corporation Bank s Website including Instructions and other conditions given. I am/ we are hereby submitting my/our application for empanelment as Architect/Consulting Engineers in your Bank. I/we do hereby declare that the information furnished in the application and supplementary sheets is correct to the best of my/our knowledge and belief. Thanking You, Yours faithfully, Signature of the applicant(s) Name: Designation Place: Date: 1 P a g e

2 Corporation Bank (A Premier Govt. of India Enterprise) APPLICATION FOR EMPANELMENT OF ARCHITECTS/CONSULTING CIVIL ENGINEERS. Cost of Application Form is Rs.500/- Last date for submission is Only parties stationed in Kerala or having an office in the Kerala State need apply. Issued To: Date: Bank's Seal: 2 P a g e

3 TERMS AND CONDITIONS 1) After empanelment any change in the Address has to be informed to the Bank in time. 2) This empanelment will be for a period of one year extendable at the discretion of the Bank. 3) Bank will have the right to negotiate with the applicants regarding their professional charges even though they have mentioned the expected percentage in the application. 4) The selected Consultant will have to coordinate with different Agencies for the smooth execution of the work. They have to also comply with the directions that will be given by our Security and Information Technology Divisions. GUIDELINES FOR FILLING THE APPLICATION 1) Application can be downloaded from the Bank s website Those who are downloading from the Website have to enclose a Demand Draft for Rs.500/- drawn in favor of Corporation Bank and payable at Mangalore. 2) Application can also be obtained from the Head Office on payment of Rs.500/- by means of Demand Draft in favor of Corporation Bank and payable at Mangalore. 3) Completed application along with all required supporting documents have to be enclosed in Envelope and superscripted as Application for empanelment of Architect/Consulting engineers for Head Office and has to reach/submit the Head Office on or before ) Applicants should not make any change/alteration to any of the clause of the Application. It will make the applicant disqualified. 5) Bank will not be responsible for any loss of application either in transit or otherwise and fo r non-receipt of the same in time. Hence applicants are advised to ensure that the completed application reach us in time. Place: Date: Signature(s) 3 P a g e

4 CORPORATION BANK (A Premier Govt. of India Enterprise) APPLICATION FOR EMPANELMENT OF ARCHITECT/CONSULTING CIVIL ENGINEERS. Sl Description To be filled by the Applicant No 1 Name of the Person/Organization/Firm 2 Complete Postal Address (With telephone (landline), Mobile, Fax numbers and ) Address of Branches if any? 3 Professional and Academic Qualifications (enclose copies of Certificates) The Applicant should have minimum graduation in Architecture, Civil Engineering with experience in designing Bank, Residential and commercial related interior works. 4 Details of membership held in Professional Bodies. (enclose copies of membership certificates) a. W h e t h e r member of Indian Institute of Architects? b. W h e t h e r member of Council of Architecture? 5 Year of Establishment and Experience (Enclose necessary proof) 6 Status of the Firm (Whether Company/Partnership/Proprietorship) 7 Name of Directors/Partners/Proprietor) i) ii) iii) 4 P a g e

5 8 Give the names of persons responsible for signing documents such as Contract Agreement, Correspondence etc. 9 Whether registered with the Registrar of Companies/Registrar of Firms. If yes, mention Registration number and date. (Enclose copy of registration Certificate) 11 a) Name and address of Bankers i) ii) iii) 12 Whether an assesses of Income Tax. If yes, mention permanent account number. Enclose copies of PAN Certificate and Income Tax Clearance Certificate/Returns) 13 Whether registered with Central Excise Department for payment of Service Tax. If yes, give registration Number and date. (Enclose copy of Registration Certificate) If not mention the reason for the same. 14 Whether registered with Commercial Taxes Department/Sales Tax Department. If yes, give registration Number and date. (If registered enclose copy of Registration Certificate) 15 Give consolidated annual financial business turnovers of the firm for the immediate last three years (year wise) in lakh rupees. (Enclose copies of audited Balance Sheets and Profit & Loss Accounts) Yes/No Yes/No 16 If you are registered in the panel of other organizations/banks, PWD etc., furnish their names, category and date of registration. (Enclose necessary proof) i) ii) iii) 5 P a g e

6 17 What are your fields of activities? Mention the fields in the order of preference i) ii) iii) 18 Whether you/staff member registered with Indian institute of Architects, Council Of Architects or any others If yes, furnish details and also enclose copies of related certificates. 19 Whether willing to offer you re services for all Branches/Offices coming under Districts office. If No, then specify the geographical area/districts. iv) 20 Whether Architecture/Consulting Engineer is your mainstream profession/business or a side-business. If it is a sideline business, attach No Objection Certificate from the mainline employer. 21 Are you conversant with the Guidelines, Directions, Observations and regulations of Central Vigilance Commission regarding Bank furnishing/renovation Works? 22 Are you conversant with the guidelines of the Indian Banks Association regarding Furnishing works? 23 Are you conversant with the local building Byelaws, rules and regulations? 24 Furnish name, designation and address with telephone of 1. three responsible persons who will be in a position to certify about the quality as well as the past performance of your firm P a g e

7 25 Do you have any relative who is working in Corporation Bank? If yes, furnish name, designation and name of the branch/office in which presently working. 26 Furnish the Professional charges expected by the applicant (Mention your charges as a percentage of actual cost of works. Please keep in mind the duties listed in the Annexure3). : (Please note that quoting of professional charges is NOT the criteria for Empanelment and Bank may ultimately decide the said charges as per the scales prevailing in the Bank. 27 Furnish the professional charges expected by the applicant for the services in assisting the Bank to purchase Boughtout items such as Sofa, Chairs Table and other furniture Fittings etc. Mention your charges as percentage of actual cost of Equipments/goods. 28 Furnish the names and addresses of three responsible persons who will be in a position to certify about the quality as well as past performance of your organisation a) Upto Rs lakh : b) Rs lakh to Rs lakh : c) Rs lakh to Rs lakh : d) Rs lakh to Rs lakh : e) Rs lakh and above : (i) (ii) (iii) 28 Specify the maximum value of work executed in a year 29 Criteria for empanelment of Architect/Consulting Engineer SNo. Particulars Weightage 01 Applicants should be Graduate/ Post Graduates in respective disciplines (Architecture / Civil Engineering) and have rendered considerable extent of consultancy work for a period of more than five years and should have executed large Furnishing /Construction projects independently. 02 Should be registered with Council of Architecture/Indian institute of Architects/Institution of Engineers etc, licensed to practice in their respective professions Preference will be given to those who are already on the panel of nationalized Banks, Financial Institutions, CPWD and other Govt. organizations. 04 They shall be in a position to offer consultancy for Corporate Office of the Bank and bank s branches/ offices situated in respective zonal offices and respective districts. 05 Registered with Income tax, Service tax. 10 Total P a g e

8 30 Details of work done for clients other than Corporation Bank in the descending order of the Value of Work. (Enclose copies of supporting documents) Sl NO A Name of Client Nature of work Value of work Professional charges received Duration of completion Date of completion B C D E F G 31 Details of work done for Corporation Bank in the descending order of value of Work. (Enclose copies of supporting documents) Sl NO Name of Client Nature of work Value of Work Duration of completion A Professional Charges received Date of completion 8 P a g e

9 B C D E F 10 P a g e

10 32 Details of key technical persons employed by you Sl No Name of Person Designation Qualification Total experience A Experience with your firm B C D 33 Any other information you may wish to provide Signature of the Applicant with seal 10 P a g e

11 DECLARATION The above particulars furnished by me/us are true and correct. The duties/functions expected to be performed by me/us as per annexure are clearly understood by me/us and I/we enclose herewith Annexure (list of duties/functions) duly signed in all the pages. I/We agree to execute necessary agreement for any work entrusted/to be entrusted to me/us at the appropriate time and I/we also agree to bear all expenses towards executing the agreement. I have enclosed copies of all required documents sought for in the application. I/We understand that Bank reserves the right to accept, negotiate, reject my/our application without assigning any reasons, whatsoever, and the decision of the Bank shall be final and binding on me/us. Place: Date: Signature(s) 11 P a g e

12 ENCLOSURE- 3 DUTIES / FUNCTIONS OF ARCHITECTS The architects shall render the following services in connection with the Bank s projects: a) Taking the employer s instructions, visiting the sites, preparing sketch designs which shall be in accordance with local governing codes / standards, regulations, etc., (inc lud ing carrying out necessary revisions till the sketch designs are finally approved by the employer) making approximate estimate of cost by cubic measurements, square metre or otherwise and preparing reports on the scheme so as to enable the employer to rake a decision on the sketch designs. b) The architect shall submit a proper PERTCHART incorporating all the activities required for the completion of the project well in time i.e., preparation of working drawings, structural drawings, detailed drawings, calling tenders etc. The programme should also include various stages of services to be done by the Consultants in co-ordination with the Architect. c) Submitting required drawings to the Municipality and other local authorities and obtaining their approval. d) Preparing architectural working drawings, structural calculations and structural drawings, layout drawings for water supply and drainage, electrical installations, telephone installations, etc., detailed estimated and all such other particulars as may be necessary for preparation of bill of quantities. e) Preparing pre-qualification documents. f) Preparing detailed tender documents for various trade viz., general builders work and specialist services such as water supply and sanitary installation, electrical installation, etc.., complete with articles of agreement, special conditions, conditions of contract, specification, bill of quantities, including detailed analysis of rates based on market rates, time and progress charts, etc. g) Inviting tenders for all trades and submitting assessment reports thereon, together with recommendations specifying abnormally high and low rated items. Preparing c o n t r a c t documents for all trades and getting them executed by the concerned contractors. h) The assessment report shall be based on proper analysis of rates with constants from an approved Standard Hand Book and market rates of materials and labour for major items of works costing about 90% of the estimated cost of the work. i) All commercial co ndit io ns shall be evaluated in financial terms instead of merely saying whether a condition may be accepted or not. j) When conditions are not susceptible of evaluation, the alternative procedure of calling all the tenderers for negotiation and asking them to submit a final bid based on the terms and conditions acceptable to the Bank may be adopted. 12 P a g e

13 k) Preparing estimates for interior decoration works based on the prevailing market rates substantiated by rate analysis for major / unusual items. l) [Proposals for interior decoration work which shall be simple but elegant consistent with functional and aesthetic requirements and shall avid lavish and ostentatious expenditure.] m) Preparing landscape drawings. n) Preparing for the use of the employer, the contractor and site staff, four copies of contract documents for all trades including all drawings, specifications and other particulars. o) Preparing such further details and drawings as are necessary for proper execution of the works. p) Assuming full responsibility for supervision and proper execution of all works by General and Specialist contractors, who are engaged from time to time, including control over quantities during the execution to restrict variation, if any, to the minimum. q) No deviations or substantiations should be authorised by the architect, without working out the financial benefit to the contractor and obtaining approval of the Bank. r) Working out the theoretical requirements and actual consumption of cement and steel for each bill. s) The architects within the fee payable to them shall appoint a full time site engineer to look after day today work during the entire duration of the work, besides personally visiting the site at least once in a fortnight or according to the exigencies of the work. t) Checking measurements of work at site, Checking contractor s bills, issuing periodical certificates for payments, issuing periodicals certificates for payment and passing and certifying accounts, so as to enable the employer to make payments to the contractors and adjustments of all accounts between the contractors and the employer. Architects shall assume full responsibility fo r all measurements c e r t ifie d by them. A recommended c e r t ific a t io n proforma for the purpose is given below: certified that the various items of work claimed in this running bill/final bill by contractors have been completed to the extent claimed and at appropriate rates and that the items are in accordance with and fully conforming to the standard prescribed specifications and hence the bill is recommended for payment of Rs. Date Signature of Architect u) Submitting detailed accounts of steel, cement and any other material that the employer may specify and certifying the quantities utilised in the words. 13 P a g e

14 v) Obtaining final building completion certificate and securing permission of Municipalit y and such other authority for occupation of the building and assisting in obtaining refund of deposit, if any, made by the employer to the Municipality or any such other authority. w) Appearing on behalf of the employer before the Municipal Assessor or such other authorities in connection with the settlement of the ratable value of the building and tendering advice in the matter to the employer. x) Preparing on completion of the work as made drawings of architectural, structural, water supply and drainage works, and electrical and other services along with a brief report on the project and submitting four copies of the same for the records of the employer. y) The architects shall be wholly and solely responsible for the successful completion of the project in all respects consistent with safety and structural stability from the inception upto the handing over for occupation to the employer. z) The architects shall assist the Bank in all arbitration proceedings between the Contractors and the Bank and also defend the Bank in such proceedings. aa) The architect shall furnish one complete set of structural designs, calculations and structural drawings for the Bank s record. bb) Any other services connected with the works usually and normally rendered by the architects, but not referred to herein above. [Signature of the Architect] 14 P a g e