PROJECT MANAGEMENT STRATEGIC ISSUES
|
|
- Bertram Green
- 6 years ago
- Views:
Transcription
1 PROJECT MANAGEMENT STRATEGIC ISSUES THE SCOTTISH PARLIAMENT BUILDING PROJECT FAILURE A REPORT Prepared By: AHMAD LEBBE MUFEEZ; Regd. No: Semester 2, 2011
2 C O N T E N T S P A G E 1. Introduction 2 2. The Scottish Parliament Building an overview 3 3. Project Schedule Delay 4 4. Project Cost Over-run 5 5. Roles of Project Management 6 6. Strategic Project Management 8 7. Learning from Project Failure 9 8. Conclusion Bibliography 12 Page 1
3 1. I N T R O D U C T I O N Much government initiated massive constructions of public building projects have failed over past many years. For example, projects such as British Library, the Scottish Parliament, the Channel Tunnel and the New Wembley Stadium were highly criticized for its cost over-run and huge delay in final handing over which resulted in unfulfilled project objectives the stakeholder s expectation. Form the lessons learnt from the failed projects, application of project management techniques could have been successful to deliver the projects on time and within the budget. Even thought for the last 50 years, there have been lot of research and development (R&D) on the subject of Project Management to improve the performance of the construction industry together with the collective construction industry experience gained over years, the projects failure continues. The new Scottish Parliament Building project is an example. The project failed in terms of cost, time and stakeholders expectation however the finished project achieved a high quality criteria and the project on completion in 2004 was welcomed by the millions of Scottish and visitors. The project cost approximately 414 million against the initial cost of 50 when it was completed in August 2004 that is 42 months later than original completion date. There were many reasons inflicted to the cost overrun of the Scottish Parliament Building Project. First of all, none except one of the shortlisted architect adhered to the proposed budget and brief and all others failed and the one who adhered was not awarded the Project. Initially the cost estimates were prepared for an incomplete design. During the course of the project, the architect added another 4,000 m 2 to the initial scope of work which increased the cost. Therefore the original budget of 40 million was not realistic for the original scope at that time and that cannot be compared with the final project cost. The increased scope, the complexity of the design consumed a lot of time and the project delayed. Project Cost and Project Delays are always come together, This report analyses the main reasons for the new Scottish Parliament Building failure. Section 2 outlines overview of the project. The following two sections detail the numerous delays occurred in the project from inception to completion and associated cost overrun due to additional design development and prolongation. Section 5 and 6 describes the project management roles and strategic project management techniques that could have been adopted to have delivered the project with a success. The last sections brief about the lessons learnt from the project failure following a conclusion at the end. Page 2
4 2. T H E S C O T T I S H P A R L I A M E N T B U I L D I N G A N O V E R V I E W The Scottish Parliament Building was built in an area of 1.6 ha and located 1 km east of Edinburgh city centre on the edge of the Old Tow constructed from a mixture of steel, oak, and granite, the new Scottish Parliament is a striking and very complex building with high quality materials and some unusual design and construction features. The parliament was procured using Construction Management Procurement in which the most of the risks remains with the Client. The cost of the new parliament was originally estimated at 50 million back in July 1997 with gross area 20,740 m 2. Final cost of the project was 414 million and completed in August 2004 after 42 months delay. Total trade contracts awarded were 58 numbers. Fig 1. Site Plan Key Dates Commencement Date : June 1999 Date for Completion : March 2001 (Original Duration 21 months) Completion Date : August 2004 (42 months delay) Page 3
5 Main Buildings MSP Building Queensberry House Tower 1 and 2 Tower 3 and 4 Canongate Tower Debating chamber Lightwell/Public stair Key Project Team Client Project Architects Structural Engineers (Consulting Engineers) Planning Supervisor & Project Managers Quantity Surveyors & Cost Consultants Construction Manager Service Engineers : Scottish Parliament Corporate Body (SPCB) : EMBT & RMJM : Ove Arup & Partners : Turner & Townsend : Davis Langdon & Everest (DLE) : Bovis Lend Lease : EMJM Page 4
6 3. P R O J E C T S C H E D U L E D E L AY The main cause of the project schedule delay were delays in completing the detailed design required for this challenging project that needed to be delivered against a unrealistic target dates using an unusual construction management (procurement) route and the interrupted supply of information throughout the construction process. In addition to the above, the other reasons for the delay are communication problems with the involved project teams and political intervention on the project also disrupted the progress of the progress. The client requirement for additional net usable area of 4,000 m 2 in August 1999 required an extended design period. This caused the Architect to issue almost 2,000 design changes and also for the original incomplete design. The Architect was also facing a pressure in progressing against unrealistic target dates assigned by the Client. Effective communication in construction project is very important skill required for a delivery of projects on schedule. This was not the case in the Scottish Parliament Building. The both Project Architects, EMBT from Spain and RMJM from Scotland from two different cultures and working from their own locations added problems in communication to resolve the issues arising at the Holyrood Site. The problem became much more when the Client changed from the Scottish Office to Scottish Parliamentary Corporate Body (SPCB) in 1 June 1999 and introduction of Presiding Officer and Architectural Advisor. Another major reason was the selection of construction management as a procurement route. This was considered as unusual in the Scottish Construction Industry. None of the advantages and disadvantages was reviewed by the Client before adopting it to deliver this complicated project. The following are some of the disadvantages of Construction Management that contributed to the schedule delay; Since there is no main contractor present, the client must carry all the risk of the activities of almost 58 individual trade contractors deployed at site at a peak time thus delaying or disrupting each other s activities. The construction management primarily doing a coordination roles between trade contractors, the Client and the Architects and never assume risks other than his negligence and again he put the risk on the client. Page 5
7 The Client was responsible for design coordination and bears the risk of delays and disruption caused by the trade contractors. It was not possible to conclude the final project cost until the last work package was awarded. The political interventions time to time throughout the project put pressure on the Architects and other trade contractors delaying the project even worse. Page 6
8 4. P R O J E C T C O S T O V E R - R U N The main reasons for cost increases are prolongation due to delays, disruption and design development, inflation, and client management to brief. Time was of essence. The delays for the project discussed above prolonged the completion till August This cost a lot of money to be spent on site general requirements (site preliminaries). After 9/11 attack, the security of public buildings became paramount so as to implement mandatory security measures which contribute a part of the cost over-un. Another reason for the increased cost was that the addition of variations for high level design development in September 2000 which added 80 million and delay and complexity in the construction process. The increase in the scale of the building, increase in construction costs and other dependent costs, increased fees to advisors and site organisation costs are the some other reasons for cost overrun. In most of the trade contracts the estimated final cost greatly exceeds the original cost plan allowance due to uncompetitive procurement of trade contracts with scope uncertainty. The remaining fit out works, additional landscaping, and site acquisition and programme contingency costs accounted for some smaller increase of the project cost. The following is a tabulation of project cost during the duration of the project. Date Project Cost in million Date Project Cost in million Jul Mar Apr Oct Jun Jan Apr Jun Aug Sep Nov Aug Page 7
9 5. R O L E S O F P R O J E C T M A N A G E M E N T Project management is an application of knowledge, skills, tools, and techniques to project activities to meet the project requirements (PMBOK Guide). A project success is always linked to time, cost, quality, scope and risk parameters. As discussed above the Scottish Parliament failed in terms of Time and Cost. The project cost increased by more than 350 million and delayed by 42 months due to failure of managing the scope and risk. But the quality was achieved. Selection of construction management procurement route without a proper understanding of the risks involved was adversely affected the complete construction process later on since all the risks were transferred to the Client. This is a procurement management failure of project management roles. Construction Management was not suitable for the project since it does not take full responsibility of huge risks involved, complexity of the project and managements of tens of subcontractors. The overall role was just a management and coordination only. The more the Construction Manager stay in the project, the more he earned his fees. And also Bovis was rejected and excluded in the shortlist but appointed later for the Construction Management role with political influence. It was clear that key stakeholders such as Members of the Scottish Parliament, Scottish Executive civil servants and Scottish Parliament official were not involved in procurement selection, and approval of revise budget and scope changes. This affected the lack of monitoring and controlling of the complete construction process Communication management was failed due to lack communication between the key players such as Project Architects EMBT and RMRJ. The Lead Architect was working outside the country where the project was located. Value Engineering (VE) exercise is a process during any stage of a project s design development cycle that gives all stakeholders the opportunity to be involved in the decision-making process and seeks to achieve the essential functions of a project at the lowest total cost, consistent with required levels of performance and quality. It constitutes an examination of all relevant options for the design and construction of the project, leading to a refinement of the design brief and identification of any budget constraints. The VE exercise carried out in the Scottish Parliament Building project suggested many recommendations that could have saved at least 25 million but it was failed because of successive new design variations. Page 8
10 6. S T R A T E G I C P R O J E C T M A N A G E M E N T ( S P M ) Strategic project management actions could have been applied to have minimised or avoided completely the disastrous results. Strategic project management is defined as the project perspective, direction, and guidelines on what to do and how to do it, to achieve the highest competitive advantage and the best project results and it equips the project team members with powerful tools to deliver the project with a success. Strategic Project Management (SPM) has been defined by Callahan & Brooks (2004) as the use of the appropriate project management knowledge, skills, tools and techniques in the context of the companies goals and objectives so that the project deliverables will contribute to company value in a way that can be measured (Callahan & Brooks, 2004, p. 23). The following five Strategic Project Management frame works could have been considered at the beginning of the project which in turn could have reduced the cost overrun and project delay making the project a success. 1. Strategic Alignment of Projects This means that the project objectives should align with the goals of the Client organization. This is only possible when the leadership is well defined and they should involve from the beginning in defining the project and selection of the other teams. 2. Cultivate a Project Management Culture The knowledge of Project Management techniques could have increased by training the team involved in the projects. It would definitely have helped to create a responsibility, understanding within various teams and accountability for what they are performing within their organization. 4. Track and Measure Projects and Outcomes Tracking and measuring system in the Scottish Parliament Project was apparently poor. Due to the increase and numerous design variations, it was not carried out. 5. Create Open Channels of Communication There was always a problem when it comes to communication between the various teams. Effective communication is a project management tool to control and use the time effectively eliminating unwanted issues. If some or all of the listed SPM techniques could have been practiced from the beginning of the project, a lot of time and money could have been saved and thus making the project a success. Page 9
11 7. L E A R N I N G F R O M P R O J E C T F A I L U R E Identifying whether a project is a success or a failure can change with time. The new Scottish Parliament Building was clearly a failure on the criteria of cost and time, yet the building later became the amazing postmodern architectural achievement. In its first six months after opening in 2004, it attracted over a quarter of a million visitors. Within a year, it had become Scotland s number one tourist attraction. With the project is complete, the financial bleeding is over, the memory of disaster will fade, but it is important that we remember the causes of project failures and apply the lessons learned. The following items listed needs more consideration; Procurement Route: The selected procurement route must be able to allow those who can manage the risks involved. It must be not a criterion to allocate or transfer risk from one party to another. Construction Management route allocate the complete risks on the Client and where the Client lacks construction experience, this become e a worse case. Milestones: To measure the progress of the project, it is important that milestones are introduced throughout the project duration which will help to find out the area where there is a problem and to take corrective action in a timely manner. Communication and Leadership: The change of the Client, project sponsors, project directors and appointment of Project Managers and their resignation showed a lack in leadership roles. Due to multi-headed clients, and their different perspective idea, they could not control the project. Therefore single point of leadership will benefit the lack of leadership role and help control the project flow. Budget: The initial budget was not adequate since it was planned for extending of an existing building but later decided to for new building. The cost estimates was not complete and realistic since the design was incomplete and design brief was not clear. It is so important first to make the scope defined and do the costs estimate. And design to costing should be adopted. Project planning: It is very important that at the beginning of the project, a realistic planning is prepared particularly in projects where there is significant complexity or technical risk, or when there is a tight schedule for completion. Due to the political intervention and urgency for a parliament building, the schedule was tight and unrealistic and not revised as per the revised and additional scope of work. Proper planning and monitoring Page 10
12 of construction projects is a key to success and all the stakeholders should be informed about inadequacy of project planning. In addition to the above, it is advisable to avoid politician involvement in the construction process and decision making, and secure the project funding and resources. Page 11
13 8. C O N C L U S I O N S The above report examined the most likely reasons for the failure of Scottish Parliament Building Project in terms of time and cost even though it was successful in quality issues. Anyway the project was criticised by many people and it was a real failure. Political intervention, not clear design brief, multi-headed clients, not having experience in construction management procurement route, wrong appointment of project team, lack of clarity in project objectives at the initial stage are some many reasons discussed. The following project management techniques could have been exercised to have completed the project on time and within the budget. With the proper procurement route suitable to allocate the risks involved in such complex project, assigning the roles and responsibilities to the right project team, preparing a realistic project budget, defined leadership and communication skills would have been adopted. Page 12
14 9. B I B I L I O G R A P H Y 1. Fraser of Carmyllie Q.C., Rt Hon Lord (2004) The Holyrood Inquiry, Scottish Parliament Corporate Body, September 2. Auditor General (2004) Management of the Holyrood building project: prepared for the Auditor General for Scotland: Audit Scotland, June 3. Auditor General (2000) The new Scottish Parliament Building: An examination of the management of the Holyrood project, Audit Scotland, September 4. Morris, P. W. G. Research at Oxford into the preconditions of success and failure in major projects. Proc. Project Management Institute Seminars/Symp. On Measuring Success, Montreal, 1986, Project Management Institute, Drexel Hill, PA, William G. Ramroth, JR., AIA. (2007) Planning for Disaster, How Natural and Manmade Disasters Shape the Built Environment, 6. Morris, P W G. The Management of Projects, Thomas Telford Ltd. 1994, ISBN: X 7. (last accessed on 20 March 2011) 8. Major Project Association (MPA, 2003), 9. A Guide to the Project Management Body of Knowledge, (PMBOK Guide) 10. Callahan, K., & Brooks, L. (2004). Essentials of strategic project management. Hoboken, NJ: John Wiley & Sons (last accessed on 16 April 2011) Page 13
PPP CONFERENCE HONG KONG 2005 The Exclusion of Scottish Firms in Scotland s PFI Projects
PPP CONFERENCE HONG KONG 2005 The Exclusion of Scottish Firms in Scotland s PFI Projects Kirsty Hunter and Professor John Kelly Glasgow Caledonian University School of the Built and Natural Environment
More informationThe Cost Monitoring of Construction Projects Through Earned Value Analysis
211 International Conference on Economics and Finance Research IPEDR vol.4 (211) (211) IACSIT Press, Singapore The Cost Monitoring of Construction Projects Through Earned Value Analysis Mohd Faris Khamidi
More informationFDD FIRM STORAGE SERVICE NORTHERN NATURAL GAS COMPANY
FDD FIRM STORAGE SERVICE NORTHERN NATURAL GAS COMPANY FIRM STORAGE SERVICE OPTIONS Northern s firm storage service is provided pursuant to the FDD Rate Schedule located in Northern s FERC Gas Tariff. The
More informationCabinet. 27 July Classification: Part Exempt (Appendix 1 Exempt) Report of: Corporate Director Place. Housing Capital Projects: Pipeline schemes
Cabinet 27 July 2017 Report of: Corporate Director Place Classification: Part Exempt (Appendix 1 Exempt) Housing Capital Projects: Pipeline schemes Lead Member Originating Officer(s) Wards affected Community
More informationEarned Value and PRINCE2 Alex Davis. Programme Manager Close Combat Programme Support Office Ministry of Defence
Earned Value and PRINCE2 Alex Davis Programme Manager Close Combat Programme Support Office Ministry of Defence PRINCE2 is a Registered Trade Mark of the Office of Government Commerce in the United Kingdom
More informationContract Certainty Subscription Market Progress Update for FSA
Programme Office Contract Certainty Subscription Market Progress Update for FSA 19th September 2006 Dane Douetil, Chair Market Reform Group The Market is making progress in line with expectations 100%
More informationProject Connect. September 14, 2011
Project Connect September 14, 2011 Introduction Meeting Minutes Approval Project Status Report IV&V Update By Ernst & Young Other Business Public Comments Review of Actions from Meeting Schedule Next Meeting
More informationFundamentals of Project Risk Management
Fundamentals of Project Risk Management Introduction Change is a reality of projects and their environment. Uncertainty and Risk are two elements of the changing environment and due to their impact on
More informationReview of Registered Charites Compliance Rates with Annual Reporting Requirements 2016
Review of Registered Charites Compliance Rates with Annual Reporting Requirements 2016 October 2017 The Charities Regulator, in accordance with the provisions of section 14 of the Charities Act 2009, carried
More informationUCISA TOOLKIT. Major Project Governance Assessment. version 1.0
UCISA TOOLKIT Major Project Governance Assessment version 1.0 Contents Introduction 1 Roles and responsibilities 2 Definition of a Major Project 3 Guidance for using the Toolkit 4 Governance elements 4
More informationCase study: Delivering the first phase of two new universities for the South African government. Dr Ron Watermeyer Spencer Hodgson
Case study: Delivering the first phase of two new universities for the South African government Dr Ron Watermeyer Spencer Hodgson Wits capital projects programme Started 2007 Refurbishment of old buildings
More informationProject Connect. August 10, 2011
Project Connect August 10, 2011 Introduction Meeting Minutes Approval Project Status Report IV&V Update By Ernst & Young Other Business Public Comments Review of Actions from Meeting Schedule Next Meeting
More informationZero Waste Scotland. Case Study: Review of a Waste Recycling Services Contract
Case Study: Review of a March 2010 Case Study: Review of a March 2010 Date: March 2009 For By: Caledonian Environment Centre School of the Built and Natural Environment Glasgow Caledonian University 5th
More informationPerformance Report October 2018
Structured Investments Indicative Report October 2018 This report illustrates the indicative performance of all Structured Investment Strategies from inception to 31 October 2018 Matured Investment Strategies
More informationInvestigation into oversight of the Student Loans Company s governance, and management of its former chief executive
A picture of the National Audit Office logo Report by the Comptroller and Auditor General Department for Education Investigation into oversight of the Student Loans Company s governance, and management
More informationEvaluation of the Uganda Social Assistance Grants For Empowerment (SAGE) Programme. What s going on?
Evaluation of the Uganda Social Assistance Grants For Empowerment (SAGE) Programme What s going on? 8 February 2012 Contents The SAGE programme Objectives of the evaluation Evaluation methodology 2 The
More informationAudit & Compliance Guidance
Audit & Compliance Guidance Green Infrastructure Fund Guidance for Applicants September 2018 Disclaimer Applicants should be aware that as the Green Infrastructure Fund is a new programme, the guidance
More informationSCOTTISH FUNDING COUNCIL CAPITAL PROJECTS DECISION POINT PROCESS
SCOTTISH FUNDING COUNCIL CAPITAL PROJECTS DECISION POINT PROCESS Incorporating amendments by Scottish Futures Trust (Proposals for Decision Points 2 5 Only) Executive summary... 1 Section 1: Introduction
More informationHealth and Wellness: Colchester Regional Hospital Replacement
4 Health and Wellness: Colchester Regional Hospital Replacement Summary The project to replace the Colchester Regional Hospital was approved in 2005 with a budget of $104 million. This budget was not a
More informationPROPERTY DEVELOPMENT FEASIBILITY STUDY. Categorised Profit & Loss (Inclusive of GST) - Full Taxation
Development: Demo page 1 Categorised Profit & Loss (Inclusive of GST) - Full Taxation Income: Development Sales 7,700,000 Lending Interest 33,785 Other 1,000 Less: GST Collected in Income -700,091 7,034,694
More informationPROJECT MANAGEMENT DIPLOMA COURSE
PROJECT MANAGEMENT DIPLOMA COURSE UNIT FOUR PROJECT IMPLEMENTATION TUTOR TALK: The Learning Outcomes for this assignment are: Evaluate how a project is prepared for implementation. Analyse the following
More informationRepublic of the Philippines: Strengthening Provincial and Local Planning and Expenditure Management Phase 2
Technical Assistance Report Project Number: 40345 April 2008 Republic of the Philippines: Strengthening Provincial and Local Planning and Expenditure Management Phase 2 The views expressed herein are those
More informationConstruction of the #7 Line Subway Extension Project New York September 17, 2018
Construction of the #7 Line Subway Extension Project New York September 17, 2018 Saibal Basuroy, PMP Project Controls Director, Hill International Inc. Disclaimer This presentation is protected by US and
More informationNIRS 2: Contract extension. REPORT BY THE COMPTROLLER AND AUDITOR GENERAL HC 355 Session : 14 November 2001
NIRS 2: Contract extension REPORT BY THE COMPTROLLER AND AUDITOR GENERAL HC 355 Session 2001-2002: 14 November 2001 The National Audit Office scrutinises public spending on behalf of Parliament. The Comptroller
More informationIntroduction by Philip Croessmann, V.P., Director of Risk Management Sources of Construction Claims Common Types of Construction Claims Risk
Introduction by Philip Croessmann, V.P., Director of Risk Management Sources of Construction Claims Common Types of Construction Claims Risk Management Preconstruction & Construction Managing Construction
More informationHighland Self Build Loan Fund (HSBLF) Information Brochure
Highland Self Build Loan Fund (HSBLF) Information Brochure 1 The Scottish Government has provided a fund of 4,000,000 to help selfbuilders in the Highland Council area. This fund is being administered
More informationEARNED VALUE MANAGEMENT. Is it worth the effort?
EARNED VALUE MANAGEMENT Is it worth the effort? Session Objectives Examples of earned value in use. Why don t more Project Managers use EMV? Road Map to EVA Maturity? What you need to know? How is our
More informationSource: Statistics New Zealand International Travel and Migration March 2015 MBIE: International Visitor Survey December 2014
Source: Statistics New Zealand International Travel and Migration March 2015 MBIE: International Visitor Survey December 2014 Source: Statistics New Zealand International Travel and Migration March 2015
More information64 th SESSION Proposed programme budget for the biennium
64 th SESSION Proposed programme budget for the biennium Course on UN Reform: Organized Jointly by UNITAR and the Permanent Mission of Switzerland to the United Nations Jun Yamazaki, Controller United
More informationXML Publisher Balance Sheet Vision Operations (USA) Feb-02
Page:1 Apr-01 May-01 Jun-01 Jul-01 ASSETS Current Assets Cash and Short Term Investments 15,862,304 51,998,607 9,198,226 Accounts Receivable - Net of Allowance 2,560,786
More informationFinance Committee. Inquiry into methods of funding capital investment projects. Submission from PPP Forum
About Finance Committee Inquiry into methods of funding capital investment projects Submission from Established in 2001, the is an industry body representing over 110 private sector companies involved
More informationConstruction Report Update
NEW TRIER HIGH SCHOOL Construction Report Update September 2016 New Trier Winnetka Campus West Side Addition TABLE OF CONTENTS I. Neighbor Relations II. III. IV. Project Summary Schedule Progress Milestones
More informationPMI - Dallas Chapter. Sample Questions. March 22, 2002
PMI - Dallas Chapter PMP Exam Sample Questions March 22, 2002 Disclaimer: These questions are intended for study purposes only. Success on these questions is not necessarily predictive of success on the
More informationMaking sense of Schedule Risk Analysis
Making sense of Schedule Risk Analysis John Owen Barbecana Inc. Version 2 December 19, 2014 John Owen - jowen@barbecana.com 2 5 Years managing project controls software in the Oil and Gas industry 28 years
More informationExplanatory Memorandum to the Education (Student Loans) (Repayment) (Amendment) Regulations 2018
Explanatory Memorandum to the Education (Student Loans) (Repayment) (Amendment) Regulations 2018 This Explanatory Memorandum has been prepared by the Higher Education Division and is laid before the National
More informationCommon Agricultural Policy Futures programme
Common Agricultural Policy Futures programme Further update EMBARGOED UNTIL 00.01 HOURS THURSDAY 15 JUNE 2017 Prepared by Audit Scotland June 2017 Auditor General for Scotland The Auditor General s role
More informationEdinburgh transport projects review
Edinburgh transport projects review Prepared for the Auditor General for Scotland June 2007 Auditor General for Scotland The Auditor General for Scotland is the Parliament s watchdog for ensuring propriety
More informationSpheria Australian Smaller Companies Fund
29-Jun-18 $ 2.7686 $ 2.7603 $ 2.7520 28-Jun-18 $ 2.7764 $ 2.7681 $ 2.7598 27-Jun-18 $ 2.7804 $ 2.7721 $ 2.7638 26-Jun-18 $ 2.7857 $ 2.7774 $ 2.7690 25-Jun-18 $ 2.7931 $ 2.7848 $ 2.7764 22-Jun-18 $ 2.7771
More informationConsumer confidence and economic climate indicators continue to increase
%/3mma Business and Consumer Surveys July 2017 28 July 2017 Consumer confidence and economic climate indicators continue to increase The Consumer confidence indicator increased in July, resuming the positive
More informationWhy? What? When? and How? Better Financial Scrutiny A Guide for Select Committees
Why? What? When? and How? Better Financial Scrutiny A Guide for Select Committees Scrutiny Unit 1st edition January 2015 This document shows how financial scrutiny can be linked to each stage of the development
More informationConsumer confidence and economic climate indicators increase
%/3mma Business and Consumer Surveys March 2017 March, 30 th 2017 Consumer confidence and economic climate indicators increase The Consumer confidence indicator increased between September and March, resuming
More informationTerms of Reference for an Individual National Consultant to conduct the testing of the TrackFin Methodology in Uganda.
Terms of Reference for an Individual National Consultant to conduct the testing of the TrackFin Methodology in Uganda 21 July, 2017 Introduction: The Ministry of Water and Environment (MWE) is implementing
More informationProject Management CSC 310 Spring 2017 Howard Rosenthal
Project CSC 310 Spring 2017 Howard Rosenthal 1 No?ce This course is based on and includes material from the text: Effective Project - Traditional, Agile, Extreme 7TH Edition Authors: Robert K. Wysocki
More informationThe Irish Association of Pension Funds. Trustee Network Funding Proposals
The Irish Association of Pension Funds Trustee Network Funding Proposals Funding Proposals Actuarial Perspective Gavin Howlin Willis INTRODUCTION The purpose of the presentation is to work through some
More informationRequest for Qualifications for General Contractors. 8th & Cooper Multi-use Project
Request for Qualifications for General Contractors The 8 th & Cooper Ownership Group is seeking qualifications from General Contractors to provide both preconstruction and construction services for the
More informationINSE 6230 Total Quality Project Management
Lecture 5 Project Cost Management Project cost management introduction Estimating costs Budget Earned Value Management (EVM) EVM projections 2 IT projects have a poor track record for meeting budget goals
More informationShared services in the Research Councils. Department for Business, Innovation and Skills REPORT BY THE COMPTROLLER AND AUDITOR GENERAL
REPORT BY THE COMPTROLLER AND AUDITOR GENERAL HC 1459 SESSION 2010 2012 21 OCTOBER 2011 Department for Business, Innovation and Skills Shared services in the Research Councils 4 Key facts Shared services
More informationResource Allocation Charter Document
Resource Allocation Charter Document v8 Updated: September 12, 2012 Team Name Resource Allocation Executive Sponsors Business Process Owner(s) Governance Objectives - Chancellor - Provost - Vice Chancellor
More informationThe United Kingdom s Future Nuclear Deterrent Capability
Ministry of Defence The United Kingdom s Future Nuclear Deterrent Capability LONDON: The Stationery Office 14.35 Ordered by the House of Commons to be printed on 3 November 2008 REPORT BY THE COMPTROLLER
More informationContents. Contents. Introduction. Background. Commentary. Graphs and statistics. Annex A: Data sources. Annex B: Explanatory notes.
Registry Trust Limited Public Statistics September 2017 Contents Contents Introduction Background Commentary Graphs and statistics Annex A: Data sources Annex B: Explanatory notes Annex C: Contacts 2 3
More informationThe Nuclear Decommissioning Authority s Magnox contract
A picture of the National Audit Office Logo Report by the Comptroller and Auditor General Department for Business, Energy & Industrial Strategy The Nuclear Decommissioning Authority s Magnox contract HC
More informationPortfolio Project Performance Reporting. Client Case Study
Portfolio Project Performance Reporting Client Case Study MetaPM 2016 The Challenge MetaPM s client need a mechanism to enable them to balance, reprioritise and provide recommendations (backed up by data)
More informationMajor Project Authority Integrated Assurance
Major Project Authority Integrated Assurance March 2012 Major Project Authority Integrated Assurance March 2012 Official versions of this document are printed on 100% recycled paper. When you have finished
More informationSOUTHERN AFRICA GROWTH INCENTIVE PROGRAMME (GIP)
SOUTHERN AFRICA GROWTH INCENTIVE PROGRAMME (GIP) PERFORMANCE YEAR (PY) 20/ The presentation contains IP protected works; it is intended for ABOs use only; the content of the presentation should not be
More informationEconomic Indicators December 2017
Economic Indicators December 2017 General Economy GDP % Change U.S. GDP Growth First two consecutive quarters over 3% in 3 years 6.0% 4.0% 2.0% 0.0% -2.0% -4.0% -6.0% Last 3 quarters: 3Q17: 3.2% 2Q17:
More informationDIGGING DEEPER INTO THE VOLATILITY ASPECTS OF AGRICULTURAL OPTIONS
R.J. O'BRIEN ESTABLISHED IN 1914 DIGGING DEEPER INTO THE VOLATILITY ASPECTS OF AGRICULTURAL OPTIONS This article is a part of a series published by R.J. O Brien & Associates Inc. on risk management topics
More informationProject & Construction Management (PCM) Manage project goals, costs, decisions, and risks right from Day 1
(PCM) Manage project goals, costs, decisions, and risks right from Day 1 plan early and confirm often DEFINE GOALS PREPARE A PLAN MEASURE RESULTS (PCM) proven results Plan early and continuously monitor
More informationDemand Characteristics for Imported Cod Products in Portugal: An Application of PCAIDS and Demand Growth Index Modelling
Demand Characteristics for Imported Cod Products in Portugal: An Application of PCAIDS and Demand Growth Index Modelling Frank Asche & Daniel V. Gordon University of Stavanger University of Florida University
More informationInvestment DANA FIXED INCOME STRATEGIES.
Investment DANA Advisors THE WISE CHOICE HERITAGE A strong family culture Since our founding in 1980, Dana has remained independent and Employee-owned. Our investment firm is built on trust, integrity,
More informationChapter 2 Department of Supply and Services Public-Private Partnership: Eleanor W. Graham Middle School and Moncton North School
Department of Supply and Services - Public-Private Partnership: Chapter 2 Department of Supply and Services Public-Private Partnership: Eleanor W. Graham Middle School and Moncton North School Contents
More informationCHARLOTTE PUBLIC SCHOOLS CONSTRUCTION MANAGEMENT SERVICES REQUEST FOR PROPOSALS ("RFP")
CHARLOTTE PUBLIC SCHOOLS CONSTRUCTION MANAGEMENT SERVICES REQUEST FOR PROPOSALS ("RFP") May 12, 2017 CHARLOTTE PUBLIC SCHOOLS A. Instructions REQUEST FOR PROPOSAL FOR CONSTRUCTION MANAGEMENT SERVICES PART
More informationProject Connect. June 22, 2011
Project Connect June 22, 2011 Introduction Meeting Minutes Approval Project Status Report IV&V Update By Ernst & Young Other Business Public Comments Review of Actions from Meeting Schedule Next Meeting
More informationMajor Projects Advisory Project Leadership Series
KPMG GLOBAL ENERGY INSTITUTE Major Projects Advisory Project Leadership Series February 7, 2013 Disclaimer The information contained herein is of a general nature and is not intended to address the circumstances
More informationImproving Risk Management Capability Using the Project Risk Maturity Model - a Case Study Based on UK Defence Procurement Projects
PM WORLD TODAY CASE STUDY OCTOBER 2011 Improving Risk Management Capability Using the Project Risk Maturity Model - a Case Study Based on UK Defence Procurement Projects Introduction Martin Hopkinson Risk
More informationEmployment Related Services Association
Employment Related Services Association Response: Smith Commission call for evidence October 2014 1. Introduction 1.1 This paper has been developed by the Employment Related Services Association (ERSA),
More informationMANAGING FOR RESULTS: An Implementation Plan for the City of Portland
MANAGING FOR RESULTS: An Implementation Plan for the City of Portland Office of Management and Finance City Auditor s Office Bureau of Planning City of Portland, Oregon June, 2003 Managing for Results
More informationA Project Management Guide for Researchers
A Project Management Guide for Researchers Prepared by: Research Grant and Contract Services January 2018 Copyright 2018 Memorial University of Newfoundland Table of Contents 1.0 Introduction... 4 2.0
More informationSmart Metering Entity (SME) Licence Order Working Group
Smart Metering Entity (SME) Licence Order Working Group Meeting # 8 September 8 th, 2016 Call-In Numbers: Local: (416) 915-8942 Toll Free: 1 855 244-8680 Agenda Review and approval of the minutes from
More informationINTEGRATING ASSESSMENT, PLANNING & BUDGETING. Presentation to URPC August 26, 2016 Lisa Castellino, PhD Office of Institutional Effectiveness
INTEGRATING ASSESSMENT, PLANNING & BUDGETING Presentation to URPC August 26, 2016 Lisa Castellino, PhD Office of Institutional Effectiveness 1 Campus Context Why integrate these activities? ON TOP Strategic
More information3 The conversion factor from MIPS (1975 = 100) to PUBSEC (1995 = 100) is i.e. 480 divided by = BIS PUBSEC 173.
Email: kerry.ward@shaestm.nhs.uk Tel No. 0121 695 2259 Date 23rd September 2011 Address to. St Chads Court 213 Hagley Road Edgbaston Birmingham B16 9RG Tel: 0121 695 2259 For the attention of all NHS Capital
More informationLiquidity & Treasury Management Conference. Reporting to the Board Writing a Winning Treasury Report
Liquidity & Treasury Management Conference Reporting to the Board Writing a Winning Treasury Report Martin Watts Head of Treasury, L&Q email: mwatts@lqgroup.org.uk Introduction Post TSA abolishment, the
More informationProject Connect. July 11, 2012
Project Connect July 11, 2012 Introduction Meeting Minutes Approval Project Status Report IV&V Update by Ernst & Young Other Business Public Comments Review of Actions from Meeting Scheduling of Next Meeting
More informationResponse to Scottish Parliament Justice 2 Committee
National Galleries of Scotland Tribunals, Courts and Enforcement Bill Response to Scottish Parliament Justice 2 Committee Introduction The National Galleries of Scotland welcomes the opportunity to respond
More informationREQUEST FOR PROPOSAL
REQUEST FOR PROPOSAL For Construction Manager as Constructor for Tri-North Middle School Response Due: April 2, 2018, 1:00 pm MCCSC Service Building 560 E. Miller Drive Bloomington, IN 47401. REQUEST FOR
More informationReport by the Comptroller and Auditor General. The Scottish Office Development Department. The Skye Bridge
Report by the Comptroller and Auditor General The Scottish Office Development Department The Skye Bridge HC 5 Session 1997-98 23 May 1997 This report has been prepared under Section 6 of the National Audit
More informationProject Connect Connect January 11, 2012
Project Connect January 11, 2012 Introduction Meeting Minutes Approval Project Status Report IV&V Update By Ernst & Young Other Business Public Comments Review of Actions from Meeting Scheduling of Next
More informationSimple Interest. S.Y.Tan. 1.1 Simple Interest
Simple Interest Interest (I) a benefit in the form of a fee that lender received for letting borrower use of his money Origin date (O.D.) the date on which the borrowed money is received by the borrower
More informationD6.2 Risk Assessment Plan
D6.2 Risk Assessment Plan Project number: 730830 Project acronym: Project title: Safe4RAIL Start date of the project: 1 st of October, 2016 Duration: Programme: Safe4RAIL: SAFE architecture for Robust
More informationPROJECT PREPARATORY TECHNICAL ASSISTANCE
Appendix 3 13 A. Justification PROJECT PREPARATORY TECHNICAL ASSISTANCE 1. The project preparatory technical assistance (PPTA) is required to help the government of Mongolia design the Regional Road Development
More informationContract Management in Offshore & Marine, EPCIC and Shipyard
An Intensive 5 Day Training Course Contract Management in Offshore & Marine, EPCIC and Shipyard 18-22 Nov 2018, Dubai 28 Apr - 02 May 2019, Dubai 17-21 Nov 2019, Dubai 18-JUL-18 This course is Designed,
More informationTABLE OF CONTENTS SUBJECTS 1. INTRODUCTION 2. INSTITUTIONAL ARRANGEMENTS. Roles and responsibilities
IDP REVIEW PROCESS PLAN DEPARTMENT OF THE OFFICE OF THE MUNICIPAL MANAGER JULY 2009-JUNE2010 TABLE OF CONTENTS SUBJECTS 1. INTRODUCTION 2. INSTITUTIONAL ARRANGEMENTS Roles and responsibilities 2.1 Council
More informationManaging Cash Flow and Reserves
Slide 1 of 30 Managing Cash Flow and Cash Reserves Flow (5 Nov 2007) and Reserves HO Yew Kee PhD, FCPA, CFA Associate Professor of Finance and Accounting Vice-Dean (Finance and Accounting) NUS Business
More informationESF Support for Families with Multiple Problems statistics to July 2014
ESF Support for Families with Multiple Problems statistics to July 2014 September 2014 Contents Introduction... 2 Key Findings... 2 Background... 3 Data and Results... 4 Tables... 9 Contacts... 19 Introduction
More informationCITY OF WOODINVILLE, WA REPORT TO THE CITY COUNCIL rd Avenue NE, Woodinville, WA
To: Honorable City Council From: Richard A. Leahy, City Manager CITY OF WOODINVILLE, WA REPORT TO THE CITY COUNCIL 1731 133rd Avenue NE, Woodinville, WA 9872 WWW.CI.WOODINVILLE.WA.US By: Alexandra Sheeks,
More informationInternational Project Management. prof.dr MILOŠ D. MILOVANČEVIĆ
International Project Management prof.dr MILOŠ D. MILOVANČEVIĆ Project time management Project cost management Time in project management process Time is a valuable resource. It is also the scarcest. Time
More informationStatus of the Implementation of the Child Welfare Component of the North Carolina Families Accessing Services through Technology (NC FAST) System
Status of the Implementation of the Child Welfare Component of the North Carolina Families Accessing Services through Technology (NC FAST) System Report to the Joint Legislative Oversight Committee on
More informationInternational University of Japan Graduate School of International Business
International University of Japan Graduate School of International Business Project Financing (FIN 4370) (An Essential Tool for International Development) Fall 2015 Instructor: Instructor's Contact: Mr.
More informationACCELERATOR- ES HYPOTHETICAL PERFORMANCE CAPSULE - Trading One Lot. Jul- 09. Jul- 10. Jan- 10. Jan- 11
System Name: Accelerator- ES Auto Trade Developer: Addwins LLC dba Trading Systems Live System Type: Intraday Futures Trades: Emini S&P Subscription Cost: $650 USD Year Dates Covered: Jan 2007- Mar 31
More informationPROPERTY DEVELOPMENT FEASIBILITY STUDY
Development: Workshop Feasibility page 1 Categorised Profit & Loss Income: Development Sales 2,072,607 Other 22,528 2,095,135 Less Development Costs: Land Purchase Price 825,000 Stamp Duty Fees and Establishment
More informationDIRECTORATE OF ESTATES AND FACILITIES
DIRECTORATE OF ESTATES AND FACILITIES PROCEDURE AND INFORMATION MANUAL EPM PM4 Client Representative (University Project Manager) for Capital Projects Scope of Services Document Originated: April 2006
More informationImpact of regulation on High Cost Short Term Credit: How the functioning of the HCSTC market has evolved
Impact of regulation on High Cost Short Term Credit: How the functioning of the HCSTC market has evolved March 2017 Contents 1 Executive summary 1 2 The impact of the new regulatory regime 5 3 Market functioning
More informationCIGNA FUNDING OPTIONS
CIGNA FUNDING OPTIONS How the right choice can help your clients make the most of their health plans Lauren Stoddard Cigna Self-funding Product Manager Gerard Sessa Cigna New Business Manager FOR AGENT/BROKER
More informationUnless the context otherwise requires, the following words and expressions shall have the following meanings:- Accountin g Period Start Date
Glossary Appendix 15 Unless the context otherwise requires, the following words and expressions shall have the following meanings:- Accounting Period means the applicable accounting period from the following
More informationCPM MANAGEMENT ANALYSIS REPORT SOUTH STREET ELEMENTARY SCHOOL NEWARK, NJ
1300 ROUTE 73 SUITE 301 MOUNT LAUREL, NEW JERSEY 08054 TEL: (609) 261-0100 FAX: (609) 261-8584 email:whi-corp@whi-inc.com internet: www.whi-inc.com CPM MANAGEMENT ANALYSIS REPORT SOUTH STREET ELEMENTARY
More informationBusiness & Financial Services December 2017
Business & Financial Services December 217 Completed Procurement Transactions by Month 2 4 175 15 125 1 75 5 2 1 Business Days to Complete 25 Jan Feb Mar Apr May Jun Jul Aug Sep Oct Nov Dec 217 Procurement
More informationSession 10 and 11 EXECUTING THE WORK & CLAIMS AND DISPUTES
Audio Sessions Session 10 and 11 EXECUTING THE WORK & CLAIMS AND DISPUTES Education Program Certified Construction Contract Administrator (CCCA) Preparatory Course 2011 www.csinet.org This presentation
More informationFor. 621 Grant. Yakima, WA until: preparation. Kim Hixson Director
Yakima Valley Libraries 102 North Third Street Yakima, WA 98901 Request for Statement of Qualifications (SOQ) For Remodel of Sunnyside Community Library 621 Grant Sunnyside, WA 98944 Notice is hereby given
More informationGrossmont-Cuyamaca Community College District Project Labor Agreement Evaluation Plan
March 16, 2017 PROCEDURE MANUAL TABLE OF CONTENTS PLA EVALUATION PLAN PROCESS A. OVERVIEW... 2 Projects... 2 Controlling Laws and Regulations... 2 Roles and Responsibilities... 2 B. KEY PERFORMANCE INDICATORS
More information2 nd STEERING COMMITTEE MEETING TUNIS 15 & 16 DECEMBER 2014
Mediterranean cultural network to promote creativity in the arts, crafts and design for communities regeneration in historical cities/ MEDNETA 2 nd STEERING COMMITTEE MEETING TUNIS 15 & 16 DECEMBER 2014
More informationLecture 2: Project Management
Lecture 2: Project Management Agenda Project management Project models Project Organization and Roles Project Management Responsibility Team Risk Control Organization Resource control Limitations Planning
More information