THU16 - Reviewing the CPM Spec for a GSA Project
|
|
- Dustin Smith
- 6 years ago
- Views:
Transcription
1 Swan Resort at Walt Disney World Florida January 10th to 13th, 2017 THU16 - Reviewing the CPM Spec for a GSA Project 1
2 Abstract Reviewing the CPM Spec for a GSA Project The Federal Government, and particularly the General Services Administration (GSA), has focused significant attention in the recent years on improving its schedule oversight and management functions in the face of a history of projects that have experienced significant delay, cost overruns, claims and disputes. This has included the implementation of revised Division 1 Specifications for scheduling, resource loading, monitoring of actua l manpower expenditures against the approved baseline schedule, and proof of delay and time extensions. This session will provide an overview of the CPM scheduling and proof of Delay requirements under a recent GSA project that employed the revised Section Division 1 Specifications. 2
3 Presenter Mark I. Anderson Mark Anderson is executive vice president and chief operating officer of Warner Construction Consultants, Inc. He has over 30 years of experience in the preparation, analysis and resolution of construction claims and disputes, both internationally and in the United States. Mr. Anderson has testified as an expert in the areas of CPM scheduling, delay analysis, and cost and damage analysis on more than two dozen occasions in various forums, including the US Court of Federal Claims, the Armed Services Board of Contract Appeals, and the US District Court, as well as before arbitration panels, mediators and dispute review boards. 3
4 He cries whenever we take him out, we just leave him in there - Lorraine s Mother Regarding Marty s Uncle (Who is always in jail). 4
5 Scheduling Requirements Purpose of Schedule (1.1.C.) Key Terms and Concepts: CPM, Critical Path, Float (1.2.A) Early Completion (1.3.C) Baseline Schedule (1.4.C) Long Lead/Procurement Activity Durations Milestones Cost Loading Approval of Baseline Schedule (1.4.D.1.d) Resource (Manpower) Loading (1.4.D.2.g) Updates (1.4.E) Progress Update v. Change Impacts (1.4.E.1) Manpower Usage (1.4.E.4.g) Narrative (1.4.E.4.h.iv viii) Delays Construction CPM Conference GSA Division 1 Specification Topical Outline Delays and Extensions of Time Schedule Revisions (1.4.F) Recovery Schedule (1.4.F.2.d) Change Modifications (1.4.F.4.): Time Impact Analysis (Timing 1.4.F.4.a/b/e) Fragnets and Narratives (1.4.F.3.c) Government Approval (1.4.F.4.d) Responsibility for Completion (1.5) Responsibility to Accelerate (1.5.A) Diligence in Prosecution of the Work and Termination (1.5.B) Performance Monitoring (1.7.A) Resource Usage by Area and Activity Used to Evaluate Adequacy for Performance, Manpower and Claims 5
6 Fifth Amendment No person shall be held to answer for a capital, or otherwise infamous crime, unless on a presentment or indictment of a Grand Jury, ; nor shall any person be subject for the same offence to be twice put in jeopardy of life or limb; nor shall be compelled in any criminal case to be a witness against himself, without due process of law Miranda Rights You have the right to remain silent. Anything you say can and will be used against you in a court of law. You have the right to an attorney. If you cannot afford an attorney, one will be provided for you. Do you understand the rights I have just read to you? With these rights in mind, do you wish to speak to me? You have no protective rights under the GSA Specification* * Overly dramatic for effect. 6
7 Scheduling Requirements Purpose of Schedule (1.1.C.) Key Terms and Concepts: CPM, Critical Path, Float (1.2.A) Early Completion (1.3.C) Baseline Schedule (1.4.C) Long Lead/Procurement Activity Durations Milestones Cost Loading Approval of Baseline Schedule (1.4.D.1.d) Resource (Manpower) Loading (1.4.D.2.g) Updates (1.4.E) Progress Update v. Change Impacts (1.4.E.1) Manpower Usage (1.4.E.4.g) Narrative (1.4.E.4.h.iv viii) Delays Construction CPM Conference GSA Division 1 Specification Topical Outline Delays and Extensions of Time Schedule Revisions (1.4.F) Recovery Schedule (1.4.F.2.d) Change Modifications (1.4.F.4.): Time Impact Analysis (Timing 1.4.F.4.a/b/e) Fragnets and Narratives (1.4.F.3.c) Government Approval (1.4.F.4.d) Responsibility for Completion (1.5) Responsibility to Accelerate (1.5.A) Diligence in Prosecution of the Work and Termination (1.5.B) Performance Monitoring (1.7.A) Resource Usage by Area and Activity Used to Evaluate Adequacy for Performance, Manpower and Claims 7
8 Analytical Examples 8
9 9
10 10
11 11
12 12
13 13
14 14
15 15
16 16
17 17
18 18
19 19
20 20
21 21
22 22
23 23
24 24
25 25
26 26
27 Takeaway Tom Brady won t be needing his helmet in Week 1. Or Week 2, or 3 or 4. (Kathy Willens/Associated Press) If they tell you not to do it, and then you get busted and what happens, happens, then you suffer the consequences, -Carson Palmer on Tom Brady and DeflateGate The Washington Post 27
28 28
29 29
30 30
31 Average of 25NOV16 Activity % Complete(%) Average of 02DEC16 Activity % Complete(%) 02DEC16 Progressed? 02DEC16 Criticality Count of Activity ID Progressed Q1-Most Critical Q2-More Critical Q3-Less Critical Progressed Total Not Progressed Q1-Most Critical Q2-More Critical Q3-Less Critical Not Progressed Total Grand Total Sum of 28NOV16 Sum of 02DEC16 Sum of 02DEC16 Sum of 02DEC16 02DEC16 Progressed? 02DEC16 Criticality Remaining Hrs Remaining Hrs Earned Hrs FTEs Progressed Q1-Most Critical 8, , , Q2-More Critical 2, , Q3-Less Critical Progressed Total 11, , , Not Progressed Q1-Most Critical 15, , Q2-More Critical 3, , Q3-Less Critical Not Progressed Total 20, , Grand T otal 31, , ,
32 32
33 Never Followed or Fulfilled Any Schedule It Used Manhours to be Earned Per Month Baseline Schedule (DH01) For Mediation Purposes Only 33
34 Never Followed or Fulfilled Any Schedule It Used Manhours to be Earned Per Month Actual as of April 2013 (CO39) For Mediation Purposes Only 34
35 Turner Never Followed or Fulfilled Any Schedule It Used Manhours to be Earned Per Month Completion Requirements (DH13) For Mediation Purposes Only 35
36 Never Followed or Fulfilled Any Schedule It Used Manhours to be Earned Per Month Actual as of July 2013 (CO60) For Mediation Purposes Only 36
37 Turner Never Followed or Fulfilled Any Schedule It Used Manhours to be Earned Per Month Completion Requirements (DH15) For Mediation Purposes Only 37
38 Never Followed or Fulfilled Any Schedule It Used Manhours to be Earned Per Month Actual as of March 2014 (Recovery Schedule) For Mediation Purposes Only 38
39 Turner Never Followed or Fulfilled Any Schedule It Used Manhours to be Earned Per Month Completion Requirements (RS23) For Mediation Purposes Only 39
40 Never Followed or Fulfilled Any Schedule It Used Manhours to be Earned Per Month Continued Rescheduling Continued Under- of Uncompleted Performance After Work March 2014 For Mediation Purposes Only 40
41 7-8 months BLANK FOR GRAPHIC (Delay based on completion %) 5-6 months 4-5 months For Mediation Purposes Only 41
42 7-8 months Each Completion BLANK Schedule Increased the FOR GRAPHIC (Delay based on Number of Manhours to completion be Completed %) 5-6 months (Burned) Per Month 4-5 months For Mediation Purposes Only 42
43 7-8 months Each Completion Schedules Increased BLANK the Number of FOR GRAPHIC (Delay based on Manhours to be completion %) 5-6 months Completed (Burned) Per Month 4-5 months For Mediation Purposes Only 43
44 7-8 months Each Completion Schedules Increased BLANK the Number of FOR GRAPHIC (Delay based on Manhours to be completion %) 5-6 months Completed (Burned) Per Month 4-5 months For Mediation Purposes Only 44
45 7-8 months BLANK FOR GRAPHIC (Delay based on completion %) 5-6 months Yet, Actual Performance Never Changed or Improved 4-5 months For Mediation Purposes Only 45
46 Non Cx-Predecessor Construction Activities Required to be in Progress Per Week Cx-Predecessor Construction Activities Required to be in Progress Per Week For Mediation Purposes Only 46
47 On Average, Work on Less Than 1/3 of the Required Activities in any Week Underperformance 150 For Mediation Purposes Only 47
SECTION ARCHITECTURAL AND ENGINEERING CPM SCHEDULES
SECTION 01 32 16.01 ARCHITECTURAL AND ENGINEERING CPM SCHEDULES PART 1- GENERAL 1.1 DESCRIPTION: The Architect/Engineer of Record (A/E) shall develop a Critical Path Method (CPM Schedule) plan and schedule
More informationVIRGINIA DEPARTMENT OF TRANSPORTATION SPECIAL PROVISION FOR SECTION 109 MEASUREMENT AND PAYMENT
SECTION 102.01 PREQUALIFICATION OF BIDDERS of the Specifications is amended as follows: The eighth paragraph is replaced by the following: When the Contractor's actual progress is more than 10 percent
More informationCase 1:17-cr ABJ Document 471 Filed 01/08/19 Page 1 of 10 UNITED STATES DISTRICT COURT FOR THE DISTRICT OF COLUMBIA ) ) ) ) ) ) ) ) )
Case 1:17-cr-00201-ABJ Document 471 Filed 01/08/19 Page 1 of 10 UNITED STATES DISTRICT COURT FOR THE DISTRICT OF COLUMBIA UNITED STATES OF AMERICA v. PAUL J. MANAFORT, JR., Defendant. Criminal No. 17-201
More informationIN THE COURT OF APPEAL OF BELIZE, A.D. 2006
IN THE COURT OF APPEAL OF BELIZE, A.D. 2006 CRIMINAL APPEAL NO. 5 OF 2006 BETWEEN: LAURIANO RAMIREZ Appellant AND THE QUEEN Respondent BEFORE: The Hon. Mr. Justice Mottley President The Hon. Mr. Justice
More informationMICHIGAN DEPARTMENT OF TRANSPORTATION SPECIAL PROVISION FOR CRITICAL PATH METHOD NETWORK SCHEDULE
MICHIGAN DEPARTMENT OF TRANSPORTATION SPECIAL PROVISION FOR CRITICAL PATH METHOD NETWORK SCHEDULE C&T:JTL 1 of 6 C&T:APPR:JDC:PAL:07-24-02 FHWA:APPR:06-01-11 a. Description. In addition to the progress
More informationSECTION PROJECT SCHEDULES (SMALL PROJECTS DESIGN/BID/BUILD)
SECTION 01 32 16.15 PROJECT SCHEDULES (SMALL PROJECTS DESIGN/BID/BUILD) PART 1- GENERAL 1.1 DESCRIPTION: A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment
More informationSECTION NETWORK ANALYSIS SCHEDULES (DESIGN-BUILD ONLY)
SECTION 01 32 16.16 NETWORK ANALYSIS SCHEDULES (DESIGN-BUILD ONLY) PART 1- GENERAL 1.1 DESCRIPTION: SPEC WRITER NOTES: 1. Coordinate this Design-Build Specification with FAR 52.232, VAAR 852.236 and Section
More information2017 CASBO Conference Workers Compensation Fraud
April 14 th, 2017 2017 CASBO Conference Workers Compensation Fraud Robert J. Nagle President RJN Investigations, Inc. Pamela Leitao Deputy District Attorney Orange County Workers Compensation Fraud The
More informationDISTRICT COURT OF APPEAL OF THE STATE OF FLORIDA FOURTH DISTRICT
DISTRICT COURT OF APPEAL OF THE STATE OF FLORIDA FOURTH DISTRICT ANTONNINE SCOTSMAN, Appellant, v. STATE OF FLORIDA, Appellee. No. 4D15-2729 [February 21, 2018] Appeal from the Circuit Court for the Seventeenth
More informationPROSPECTIVE Vs. RETROSPECTIVE DELAY ANALYSIS. MASIN PROJECTS PRIVATE LIMITED (
PROSPECTIVE Vs. RETROSPECTIVE DELAY ANALYSIS BY:- ROHIT SINGHAL, SHISHIR KANT, ADARSH KUMAR MASIN PROJECTS PRIVATE LIMITED (www.masinproject.com) Page 1 of 10 ABSTRACT Infrastructure, construction and
More informationEMPLOYMENT ARBITRATION OPINION AND AWARD
Florman #2 EMPLOYMENT ARBITRATION OPINION AND AWARD In the Matter of Arbitration Between: EMPLOYEE and EMPLOYER, INC. ARBITRATOR: Phyllis E. Florman Termination FINDING OF FACTS 1. Ms. Employee was hired
More informationARBITRATION ACT. Act No: 10/2013 ARBITRATION ACT Maldivian Government Gazette Volume 42 Edition rd July 2013
ARBITRATION ACT Act No: 10/2013 ARBITRATION ACT Maldivian Government Gazette Volume 42 Edition 102 3 rd July 2013 Chapter I Preamble Introduction & Title 1 (a) This Act lays out the principles for the
More information(FinCEN) Director's Weekly Reports to the Department of the Treasury Office of Terrorism and Financial Intelligence (TFI), Feb-Jul 2017
Description of document: Requested date: Released date: Posted date: Source of document: Nineteen (9) Financial Crimes Enforcement Network (FinCEN) Director's Weekly Reports to the Department of the Treasury
More informationSECTION PROGRESS SCHEDULE
NOTE: Review this section carefully. If Project Scope is complex this Specification is to be used. If project is relatively simple and straightforward use Section 01310. SECTION 01311 PART 1 GENERAL 1.1
More informationHULL & COMPANY, INC. DBA: Hull & Company MacDuff E&S Insurance Brokers PRODUCER AGREEMENT
HULL & COMPANY, INC. DBA: Hull & Company MacDuff E&S Insurance Brokers PRODUCER AGREEMENT THIS PRODUCER AGREEMENT (this Agreement ), dated as of, 20, is made and entered into by and between Hull & Company,
More information- 1 - IN THE DISTRICT COURT OF THE UNITED STATES FOR THE DISTRICT OF
- 1-26 U.S.C. 7203 Sole Proprietorship or Partnership Employer's Quarterly Return Failure to File - Tabular Form Information Venue in District of Service Center 1 IN THE DISTRICT COURT OF THE UNITED STATES
More informationIn The Court of Appeals For The First District of Texas NO CR. BRUCE GLENN MILNER, Appellant. THE STATE OF TEXAS, Appellee
Opinion issued December 18, 2008 In The Court of Appeals For The First District of Texas NO. 01-07-00501-CR BRUCE GLENN MILNER, Appellant V. THE STATE OF TEXAS, Appellee On Appeal from the 239th District
More informationRichard J. Long, P.E. and Rod C. Carter, CCP, PSP
Richard J. Long, P.E. and Rod C. Carter, CCP, PSP LONG INTERNATIONAL Long International, Inc. 5265 Skytrail Drive Littleton, Colorado 80123-1566 USA Telephone: (303) 972-2443 Fax: (303) 200-7180 www.long-intl.com
More informationCase 1:05-cr EWN Document 1 Filed 12/20/2005 Page 1 of 8 IN THE UNITED STATES DISTRICT COURT FOR THE DISTRICT OF COLORADO
Case 1:05-cr-00545-EWN Document 1 Filed 12/20/2005 Page 1 of 8 IN THE UNITED STATES DISTRICT COURT FOR THE DISTRICT OF COLORADO Criminal Case No. UNITED STATES OF AMERICA, v. Plaintiff, 1. JOSEPH P. NACCHIO,
More informationIN THE COURT OF CRIMINAL APPEALS OF TENNESSEE AT NASHVILLE Assigned on Briefs September 20, 2000
IN THE COURT OF CRIMINAL APPEALS OF TENNESSEE AT NASHVILLE Assigned on Briefs September 20, 2000 SHANTA FONTON MCKAY V. STATE OF TENNESSEE Appeal from the Criminal Court for Davidson County No. 97-B-786
More informationIN THE COURT OF CRIMINAL APPEALS OF TENNESSEE AT KNOXVILLE Assigned on Briefs October 30, 2007
IN THE COURT OF CRIMINAL APPEALS OF TENNESSEE AT KNOXVILLE Assigned on Briefs October 30, 2007 STATE OF TENNESSEE v. SCOTT G. CLEVENGER Appeal from the Circuit Court for Grainger County No. 4190 O. Duane
More informationLEGAL SERVICE BENEFIT CONTRACT
LEGAL SERVICE BENEFIT CONTRACT This is a contract by and between Firearms Legal Protection, LLC, a Texas Limited Liability Company (also referred to as "FLP ; our ; we ; or us") and the Primary Member,,
More informationARMED SERVICES BOARD OF CONTRACT APPEALS. Appeals of -- ) ) R&R Group, Inc. ) ASBCA Nos , ) Under Contract No. SPO D-2920 )
ARMED SERVICES BOARD OF CONTRACT APPEALS Appeals of -- ) ) R&R Group, Inc. ) ASBCA Nos. 52328, 52711 ) Under Contract No. SPO300-97-D-2920 ) APPEARANCE FOR THE APPELLANT: Francis Louis Zarrilli, Esq. Broomall,
More informationCASE NO. 1D Nancy A. Daniels, Public Defender, and Kathleen Stover, Assistant Public Defender, Tallahassee, for Appellant.
IN THE DISTRICT COURT OF APPEAL FIRST DISTRICT, STATE OF FLORIDA MARKEL LATRAE BASS, v. Appellant, NOT FINAL UNTIL TIME EXPIRES TO FILE MOTION FOR REHEARING AND DISPOSITION THEREOF IF FILED CASE NO. 1D12-3284
More informationAND IN THE MATTER of an Arbitration pursuant to the Arbitration Act. S.O R.B.C. GENERAL INSURANCE COMPANY. - and - LOMBARD INSURANCE COMPANY
IN THE MATTER of a dispute between R.B.C. General Insurance Company and Lombard Insurance Company pursuant to Regulation 283/95 under the Insurance Act, R.S.O 1990, I.8 as amended AND IN THE MATTER of
More informationTHE SUPREME COURT OF APPEAL OF SOUTH AFRICA JUDGMENT NOMFUSI NOMPUMZA SEYISI
THE SUPREME COURT OF APPEAL OF SOUTH AFRICA JUDGMENT Case no: 117/12 Non Reportable In the matter between: NOMFUSI NOMPUMZA SEYISI APPELLANT and THE STATE RESPONDENT Neutral citation: Seyisi v The State
More informationYour assets and the financial assessment for care home fees
Your assets and the financial assessment for care home fees If you need help from the council to pay care home fees, this factsheet looks at what happens if you transfer your property, spend large sums
More informationLONG INTERNATIONAL. Rod C. Carter, CCP, PSP and Richard J. Long, P.E.
Rod C. Carter, CCP, PSP and Richard J. Long, P.E. LONG INTERNATIONAL Long International, Inc. 5265 Skytrail Drive Littleton, Colorado 80123-1566 USA Telephone: (303) 972-2443 Fax: (303) 200-7180 www.long-intl.com
More informationTHE IMMIGRATION ACTS. On 17 December 2015 On 5 January Before DEPUTY UPPER TRIBUNAL JUDGE DOYLE. Between
Upper Tribunal (Immigration and Asylum Chamber) THE IMMIGRATION ACTS Heard at Field House Decision & Reasons Promulgated On 17 December 2015 On 5 January 2016 Before DEPUTY UPPER TRIBUNAL JUDGE DOYLE Between
More informationIN THE COURT OF APPEAL BETWEEN AND
TRINIDAD AND TOBAGO IN THE COURT OF APPEAL Mag. Appeal No. 13 of 2011 BETWEEN DAVENDRA OUJAR Appellant AND P.C. DANRAJ ROOPAN #15253 Respondent PANEL: P. WEEKES, J A R. NARINE, J A Appearances: Mr. Jagdeo
More informationCase 1:15-cr RMB Document 353 Filed 11/20/17 Page 1 of 1
Case 1:15-cr-00867-RMB Document 353 Filed 11/20/17 Page 1 of 1 Boston Brussels Chicago Dallas Düsseldorf Frankfurt Houston London Los Angeles Miami Milan Munich New York Orange County Paris Rome Seoul
More informationVIRGINIA DEPARTMENT OF TRANSPORATION SPECIAL PROVISION FOR CPM PROGRESS SCHEDULE FOR CATEGORY IV PROJECTS
S108D00-0911 VIRGINIA DEPARTMENT OF TRANSPORATION SPECIAL PROVISION FOR CPM PROGRESS SCHEDULE FOR CATEGORY IV PROJECTS March 1, 2011 Section 103.06(e) Progress Schedule of the Specifications is deleted
More informationREASONS FOR DECISION
Financial Services Commission of Ontario Commission des services financiers de l Ontario BETWEEN: ROSARIO UNGARO Applicant and AVIVA CANADA INC. Insurer REASONS FOR DECISION Before: Heard: Appearances:
More informationS09A2076. STEVENS v. STATE
In the Supreme Court of Georgia Decided: March 1, 2010 S09A2076. STEVENS v. STATE BENHAM, Justice. Appellant Daquan Stevens appeals his conviction for malice murder, participation in criminal street gang
More informationRegulatory Notice 17-29
Regulatory Notice 17-29 Definition of Non-Public Arbitrator SEC Approves Amendments to Arbitration Codes to Revise the Definition of Non-Public Arbitrator Effective Date: October 9, 2017 Summary FINRA
More informationMnDOT Project Management Office Presents: Project Reporting. Presenter: Jonathan McNatty Senior Schedule Consultant DRMcNatty & Associates, Inc.
MnDOT Project Management Office Presents: Project Reporting Presenter: Jonathan McNatty Senior Schedule Consultant DRMcNatty & Associates, Inc. Housekeeping Items Lines will be muted during the webinar
More informationTWELFTH APPELLATE DISTRICT OF OHIO. Plaintiff-Appellee, : CASE NO. CA : O P I N I O N -vs- 6/14/2004 :
[Cite as State v. Philpot, 2004-Ohio-3006.] IN THE COURT OF APPEALS TWELFTH APPELLATE DISTRICT OF OHIO BUTLER COUNTY STATE OF OHIO, : Plaintiff-Appellee, : CASE NO. CA2003-05-103 : O P I N I O N -vs- 6/14/2004
More informationPROJECT TITLE PROJECT NO: CONTRACT TITLE UNIVERSITY OF CALIFORNIA, DAVIS CITY, CALIFORNIA
This section is used for projects over $1,000,000 use other section if less than $1M SECTION 01 32 00 CONSTRUCTION PROGRESS DOCUMENTATION PART 1 - GENERAL 1.1 SCOPE A. Preliminary Contract Schedule, Contract
More informationbar counsel repor t In Re: BRANDON L. PHILLIPS Bar No.: Case No.: OBC Filed: August 8, 2017 LETTER OF REPRIMAND
In Re: BRANDON L. PHILLIPS Bar No.: 12264 Case No.: OBC16-1406 Filed: August 8, 2017 LETTER OF REPRIMAND Mr. Phillips: On Friday May 12, 2017, a Hearing Panel of the Southern Nevada Disciplinary Panel
More informationEvaluating Schedule Impacts. By: Wendy Kaszycki, PE Randa Jarjour, CCE 12/06/06
Evaluating Schedule Impacts By: Wendy Kaszycki, PE Randa Jarjour, CCE 12/06/06 Overview Definitions Methods of Evaluating Delays Best Practices 2 Classification of Project Delays (Risk Point of View) Non-excusable
More informationHIGH COURT OF SOUTH AFRICA (GAUTENG DIVISION, PRETORIA)
- - ------------------- HIGH COURT OF SOUTH AFRICA (GAUTENG DIVISION, PRETORIA) CASE NO: A200/2016 DELETE WHICHEVER IS NOT APPLICABLE (1) REPORTABLE: ~ / NO. (2) OF INTEREST TO OTHER JUDGES:,$ I NO. (3)
More informationIN THE LABOUR COURT OF SOUTH AFRICA, JOHANNESBURG
IN THE LABOUR COURT OF SOUTH AFRICA, JOHANNESBURG Not Reportable Not of interest to other judges Case no: JS171/2014 In the matter between: LYALL, MATHIESON MICHAEL Applicant And THE CITY OF JOHANNESBURG
More informationUNITED STATES DISTRICT COURT EASTERN DISTRICT OF VIRGINIA RICHMOND DIVISION
UNITED STATES DISTRICT COURT EASTERN DISTRICT OF VIRGINIA RICHMOND DIVISION UNITEDSTATES OF AMERICA, ) CRIMINAL ACTION NO. ) 3:05-CR-00202-REP-1 Plaintiff, ) ) v. ) ) JAMES DOMINIC YYY, ) ) Defendant.
More informationUNITED STATES COURT OF APPEALS FOR THE NINTH CIRCUIT
FOR PUBLICATION UNITED STATES COURT OF APPEALS FOR THE NINTH CIRCUIT IN RE: CERY BRADLEY PERLE, Debtor, CERY BRADLEY PERLE, Appellant, No. 11-60000 BAP No. 10-1048 OPINION v. ALFONSO FIERO, Appellee. Appeal
More informationIN THE COURT OF CRIMINAL APPEALS OF TENNESSEE AT KNOXVILLE Assigned on Briefs March 22, 2005
IN THE COURT OF CRIMINAL APPEALS OF TENNESSEE AT KNOXVILLE Assigned on Briefs March 22, 2005 STATE OF TENNESSEE v. EARL D. MILLS - July 5, 2005 Direct Appeal from the Criminal Court for Knox County No.78215
More informationVIRGINIA DEPARTMENT OF TRANSPORATION SPECIAL PROVISION FOR CPM PROGRESS SCHEDULE FOR CATEGORY III PROJECTS
S108C00-0911 VIRGINIA DEPARTMENT OF TRANSPORATION SPECIAL PROVISION FOR CPM PROGRESS SCHEDULE FOR CATEGORY III PROJECTS March 1, 2011 Section 103.06(e) Progress Schedule of the Specifications is deleted
More informationHow to Properly Demonstrate Delays in a P3 Schedule to Support a Delay Claim. Michael E. Stone
How to Properly Demonstrate Delays in a P3 Schedule to Support a Delay Claim Michael E. Stone Construction Delays & CPM Schedules Recognize different types of delays Understand how to use P3 to measure
More informationWORKWEEK DISPUTE FORM
WORKWEEK DISPUTE FORM CPT ID: «ID» SUPERIOR COURT OF THE STATE OF CALIFORNIA FOR THE COUNTY OF SAN MATEO James v. Park N Fly Service, LLC et al. Case No. 17CIV05465 CPT ID: 1 *1* Aanenson, Taylor Alan
More informationSeattle Metropolitan Credit Union Error Resolution Form
Seattle Metropolitan Credit Union Error Resolution Form Name: Account #: ATM or Debit Card Number: Phone: Email: Provisional credit will be posted to your account within 5 business days upon receipt of
More informationThe Audit is Over Now What?
Where Do We Go From Here: A Comparison of Alternatives When You and the IRS Agree to Disagree JENNY LOUISE JOHNSON, Holland & Knight LLP Co-Chair of Tax Controversy Practice CHARLES E. HODGES, Kilpatrick
More informationIN THE COURT OF APPEALS FOR THE FIFTH DISTRICT OF TEXAS DALLAS, TEXAS. VS. NOS CR and CR THE STATE OF TEXAS, Appellee.
IN THE COURT OF APPEALS FOR THE FIFTH DISTRICT OF TEXAS DALLAS, TEXAS RONALD DEMOND JOHNSON, Appellant VS. NOS. 05-09-00494-CR and 05-09-00495-CR THE STATE OF TEXAS, Appellee. ON APPEAL FROM THE 363RD
More informationCan a Contractor Be Entitled to a Time Extension If The Delay Is Not Critical?
Can a Contractor Be Entitled to a Time Extension If The Delay Is Not Critical? Presented by Mark Nagata, PSP, Director/Shareholder, Trauner Consulting Services, Inc. 8/14/17 Meet Your Presenter, Mark Nagata,
More informationSUPREME COURT OF QUEENSLAND
SUPREME COURT OF QUEENSLAND CITATION: R v M [2003] QCA 380 PARTIES: R v M (applicant/appellant) FILE NO/S: CA No 92 of 2003 DC No 334 of 2003 DIVISION: PROCEEDING: ORIGINATING COURT: Court of Appeal Appeal
More informationPOWER OF ATTORNEY BY THE PARTNERS OF A FIRM TO ONE OF THEM
POWER OF ATTORNEY BY THE PARTNERS OF A FIRM TO ONE OF THEM TO ALL TO WHOM THESE PRESENTS SHALL COME, We (1) Mr. A, residing at.. (2) Mr. B. residing at... and (3) Mr. C, residing at... SEND GREETINGS:
More informationIN THE COURT OF APPEALS OF OHIO SIXTH APPELLATE DISTRICT WILLIAMS COUNTY. Court of Appeals No. WM Appellee Trial Court No.
[Cite as State v. Robbins, 2012-Ohio-3862.] IN THE COURT OF APPEALS OF OHIO SIXTH APPELLATE DISTRICT WILLIAMS COUNTY State of Ohio Court of Appeals No. WM-11-012 Appellee Trial Court No. 10 CR 103 v. Barry
More informationClient Quantity Surveyor Agreement 1998
THE ASSOCIATION OF SOUTH AFRICAN QUANTITY SURVEYORS Client Quantity Surveyor Agreement 1998 Project Client Quantity surveyor/ Consortium representative Agreement date File reference Effective date: 1 June
More informationYour assets and the financial assessment for care home fees
Your assets and the financial assessment for care home fees If you need help from the council to pay care home fees, this factsheet looks at what happens if you transfer your property, spend large sums
More informationUCB, Inc. Defined Benefit Pension Plan Litigation NOTICE OF PROPOSED CLASS ACTION SETTLEMENT
UCB, Inc. Defined Benefit Pension Plan Litigation NOTICE OF PROPOSED CLASS ACTION SETTLEMENT Ahrens, et al., v. UCB Holdings, Inc., et al., No. 15-cv-348-TWT (N.D. Ga.) A Federal Court authorized this
More informationNo. 1D On appeal from the Circuit Court for Escambia County. Jan Shackelford, Judge. July 9, 2018
FIRST DISTRICT COURT OF APPEAL STATE OF FLORIDA No. 1D17-711 FELICE JOHN VEACH, Appellant, v. STATE OF FLORIDA, Appellee. On appeal from the Circuit Court for Escambia County. Jan Shackelford, Judge. July
More informationPolicies and Procedures Related to Continuing Disclosure Obligations
Contacts: David K. Medanich Vice Chairman 777 Main Street, Suite 1200 Fort Worth, Texas 76102 817.332.9710 david.medanich@firstsw.com Greg Schaecher McCall, Parkhurst & Horton, L.L.P., Bond Counsel 717
More informationCASE NO. 1D Pamela Jo Bondi, Attorney General, and Michael McDermott, Assistant Attorney General, Tallahassee, for Appellee.
IN THE DISTRICT COURT OF APPEAL FIRST DISTRICT, STATE OF FLORIDA PETER BAPTISTE, v. Appellant, NOT FINAL UNTIL TIME EXPIRES TO FILE MOTION FOR REHEARING AND DISPOSITION THEREOF IF FILED CASE NO. 1D14-1868
More informationCOURT OF APPEALS MUSKINGUM COUNTY, OHIO FIFTH APPELLATE DISTRICT
[Cite as State v. Deavers, 2007-Ohio-5464.] COURT OF APPEALS MUSKINGUM COUNTY, OHIO FIFTH APPELLATE DISTRICT STATE OF OHIO -vs- Plaintiff-Appellee LANCE EDWARDS DEAVERS, AKA, TONY CARDELLO Defendant-Appellant
More informationDISTRICT COURT OF APPEAL OF THE STATE OF FLORIDA FOURTH DISTRICT
DISTRICT COURT OF APPEAL OF THE STATE OF FLORIDA FOURTH DISTRICT MUSTAFA A. ABDULLA, Appellant, v. STATE OF FLORIDA, Appellee. No. 4D16-2606 [July 5, 2017] Appeal from the Circuit Court for the Fifteenth
More informationUNITED STATES NAVY-MARINE CORPS COURT OF CRIMINAL APPEALS WASHINGTON, D.C.
UNITED STATES NAVY-MARINE CORPS COURT OF CRIMINAL APPEALS WASHINGTON, D.C. Before M.D. MODZELEWSKI, F.D. MITCHELL, M.K. JAMISON Appellate Military Judges UNITED STATES OF AMERICA v. TROY B. NORMAN SERGEANT
More informationMnDOT use of Calendars in Primavera P6
MnDOT Project Management Office Presents: MnDOT use of Calendars in Primavera P6 Presenter: Jonathan McNatty, PSP Senior Schedule Consultant DRMcNatty & Associates, Inc. Housekeeping Items Lines will be
More informationUNITED STATES AIR FORCE COURT OF CRIMINAL APPEALS UNITED STATES. Senior Airman TROY N. SINES United States Air Force ACM S32192.
UNITED STATES AIR FORCE COURT OF CRIMINAL APPEALS UNITED STATES v. Senior Airman TROY N. SINES United States Air Force 09 December 2014 Sentence adjudged 17 September 2013 by SPCM convened at Travis Air
More informationDoes a Taxpayer Have the Burden of Showing Intent to Divert Corporate Funds as Return of Capital?
Michigan State University College of Law Digital Commons at Michigan State University College of Law Faculty Publications 1-1-2008 Does a Taxpayer Have the Burden of Showing Intent to Divert Corporate
More informationSTATE OF MICHIGAN COURT OF APPEALS
STATE OF MICHIGAN COURT OF APPEALS PEOPLE OF THE STATE OF MICHIGAN, Plaintiff-Appellee, UNPUBLISHED October 28, 2014 v No. 317500 Houghton Circuit Court JESSICA LEE GOSTLIN, LC No. 2012-002621-FH Defendant-Appellant.
More informationSTATE OF OHIO MACK THOMAS, JR.
[Cite as State v. Thomas, 2009-Ohio-1784.] Court of Appeals of Ohio EIGHTH APPELLATE DISTRICT COUNTY OF CUYAHOGA JOURNAL ENTRY AND OPINION No. 91112 STATE OF OHIO PLAINTIFF-APPELLEE vs. MACK THOMAS, JR.
More information"One clause which was discussed was the 6-month notification for termination."
MINUTES OF THE FIFTH MEETING OF KISSIMMEE UTILITY AUTHORITY, HELD THURSDAY,, AT 7:02 P.M., CITY COMMISSION CHAMBERS, MUNICIPAL ADMINISTRATION BUILDING, KISSIMMEE, FLORIDA. July 25, 1985 PAGE 17 Present
More informationBill 75 (2016, chapter 13)
FIRST SESSION FORTY-FIRST LEGISLATURE Bill 75 (2016, chapter 13) An Act respecting the restructuring of university-sector defined benefit pension plans and amending various legislative provisions Introduced
More informationIN THE COURT OF APPEAL OF THE STATE OF CALIFORNIA SIXTH APPELLATE DISTRICT
Jonathan Grossman 154452 Staff Attorney Sixth District Appellate Program 100 N. Winchester Blvd., Suite 310 Santa Clara, CA 95050 (408) 241-6171 Attorney for Reginald Dewayne Ferguson IN THE COURT OF APPEAL
More informationCPM MANAGEMENT ANALYSIS REPORT SOUTH STREET ELEMENTARY SCHOOL NEWARK, NJ
1300 ROUTE 73 SUITE 301 MOUNT LAUREL, NEW JERSEY 08054 TEL: (609) 261-0100 FAX: (609) 261-8584 email:whi-corp@whi-inc.com internet: www.whi-inc.com CPM MANAGEMENT ANALYSIS REPORT SOUTH STREET ELEMENTARY
More informationIN THE COURT OF APPEALS OF OHIO TENTH APPELLATE DISTRICT. Clay O. Burris, : (REGULAR CALENDAR) D E C I S I O N. Rendered on November 19, 2013
[Cite as State v. Burris, 2013-Ohio-5108.] IN THE COURT OF APPEALS OF OHIO TENTH APPELLATE DISTRICT State of Ohio, : Plaintiff-Appellee, : No. 13AP-238 v. : (C.P.C. No. 12CR-01-238) Clay O. Burris, : (REGULAR
More informationREPORT OF THE OFFICE OF THE INSPECTOR GENERAL
OFFICE OF THE INSPECTOR GENERAL CHICAGO HOUSING AUTHORITY REPORT OF THE OFFICE OF THE INSPECTOR GENERAL 2016 FOURTH QUARTER REPORT OCTOBER 1, 2016 THROUGH DECEMBER 31, 2016 ELISSA RHEE-LEE INSPECTOR GENERAL
More information1THE WALL STREET JOURNAL1
1THE WALL STREET JOURNAL1 The Infiltrator on the Current State of Bank Compliance SAMUEL RUBENFELD Aug 1, 2016 In this image released by Broad Green Pictures, Bryan Cranston appears in a scene from 'The
More informationSUPREME COURT OF QUEENSLAND
SUPREME COURT OF QUEENSLAND CITATION: R v MCE [2015] QCA 4 PARTIES: R v MCE (appellant) FILE NO: CA No 186 of 2014 DC No 198 of 2012 DIVISION: PROCEEDING: ORIGINATING COURT: Court of Appeal Appeal against
More informationIN THE COURT OF APPEALS OF OHIO SIXTH APPELLATE DISTRICT LUCAS COUNTY. Court of Appeals No. L Trial Court No.
[Cite as State v. Dorsey, 2010-Ohio-936.] IN THE COURT OF APPEALS OF OHIO SIXTH APPELLATE DISTRICT LUCAS COUNTY State of Ohio Appellee Court of Appeals No. L-09-1016 Trial Court No. CR0200803208 v. Joseph
More informationArbitration CAS 2010/A/2078 Gabros International Football Club v. Hertha BSC Berlin, award of 16 November 2010
Tribunal Arbitral du Sport Court of Arbitration for Sport Arbitration CAS 2010/A/2078 Panel: Mr Mark Hovell (United Kingdom), Sole Arbitrator Football Transfer Withdrawal of the offer before its acceptance
More informationWhat To Do When The Feds Come Knocking. Christine Williams Dave Taylor
What To Do When The Feds Come Knocking Christine Williams Dave Taylor February 5, 2013 Christine Williams Anchorage, AK (907) 263-6931 Cwilliams@perkinscoie.com Presenters Dave Taylor Seattle, WA (206)
More informationCAREER SERVICE BOARD, CITY AND COUNTY OF DENVER, STATE OF COLORADO
CAREER SERVICE BOARD, CITY AND COUNTY OF DENVER, STATE OF COLORADO Appeal No. 25-08 A. FINDINGS AND ORDER IN THE MA TIER OF THE APPEAL OF: BOBBY ROGERS, Appellant/Petitioner, vs. DENVER SHERIFF'S DEPARTMENT,
More informationSTATE OF OHIO LAVELLE COLEMAN
[Cite as State v. Coleman, 2008-Ohio-2806.] Court of Appeals of Ohio EIGHTH APPELLATE DISTRICT COUNTY OF CUYAHOGA JOURNAL ENTRY AND OPINION No. 89358 STATE OF OHIO PLAINTIFF-APPELLEE vs. LAVELLE COLEMAN
More informationConsultation paper Introduction of a mechanism for eliminating double imposition of VAT in individual cases
EUROPEAN COMMISSION DIRECTORATE-GENERAL TAXATION AND CUSTOMS UNION INDIRECT TAXATION AND TAX ADMINISTRATION VAT and other turnover taxes TAXUD/D1/. 5 January 2007 Consultation paper Introduction of a mechanism
More informationCase 3:17-cv BR Document 1 Filed 01/24/17 Page 1 of 21
Case 3:17-cv-00117-BR Document 1 Filed 01/24/17 Page 1 of 21 Michael Fuller, OSB No. 09357 Lead Trial Attorney for Estrella Rex Daines, OSB No. 952442 Of Attorneys for Estrella Olsen Daines PC US Bancorp
More informationFourteenth Court of Appeals
Affirmed and Memorandum Opinion filed December 16, 2010. In The Fourteenth Court of Appeals NO. 14-09-00868-CR NO. 14-09-00869-CR ARRINGTON FLOYD BURLEY, Appellant V. THE STATE OF TEXAS, Appellee On Appeal
More informationDavid T. Hulett, Ph.D, Hulett & Associates, LLC # Michael R. Nosbisch, CCC, PSP, Project Time & Cost, Inc. # 28568
David T. Hulett, Ph.D, Hulett & Associates, LLC # 27809 Michael R. Nosbisch, CCC, PSP, Project Time & Cost, Inc. # 28568 Integrated Cost-Schedule Risk Analysis 1 February 25, 2012 1 Based on AACE International
More informationNOS CR CR IN THE COURT OF APPEALS TWELFTH COURT OF APPEALS DISTRICT TYLER, TEXAS
NOS. 12-17-00298-CR 12-17-00299-CR IN THE COURT OF APPEALS TWELFTH COURT OF APPEALS DISTRICT TYLER, TEXAS DONALD RAY RUNNELS, APPELLANT V. THE STATE OF TEXAS, APPELLEE APPEALS FROM THE 123RD JUDICIAL DISTRICT
More informationBRAAMFONTEIN CASE NO: JS 274/01. THE DEPARTMENT OF CORRECTIONAL SERVICES Respondent J U D G M E N T
Sneller Verbatim/MLS IN THE LABOUR COURT OF SOUTH AFRICA BRAAMFONTEIN CASE NO: JS 274/01 2003-03-24 In the matter between M KOAI Applicant and THE DEPARTMENT OF CORRECTIONAL SERVICES Respondent J U D G
More informationIN THE DISTRICT COURT OF APPEAL OF THE STATE OF FLORIDA FIFTH DISTRICT. v. Case No. 5D
IN THE DISTRICT COURT OF APPEAL OF THE STATE OF FLORIDA FIFTH DISTRICT NOT FINAL UNTIL TIME EXPIRES TO FILE MOTION FOR REHEARING AND DISPOSITION THEREOF IF FILED JOSE LUIZ RECCO, Appellant, v. Case No.
More informationDECISION I. INTRODUCTION
HEARING OFFICER, CAREER SERVICE BOARD CITY AND COUNTY OF DENVER, COLORADO Appeal No. 60-04 DECISION IN THE MATTER OF THE APPEAL OF: VINCENT MACIEYOVSKI, Appellant, vs. Department of Safety, Denver Sheriff's
More informationCourt of Appeals of Ohio
[Cite as State v. Nixon, 2007-Ohio-160.] Court of Appeals of Ohio EIGHTH APPELLATE DISTRICT COUNTY OF CUYAHOGA JOURNAL ENTRY AND OPINION No. 87847 STATE OF OHIO PLAINTIFF-APPELLEE vs. LAKISHA NIXON DEFENDANT-APPELLANT
More informationNo. 1D On appeal from the Circuit Court for Clay County. John H. Skinner, Judge. April 18, 2018
FIRST DISTRICT COURT OF APPEAL LEO C. BETTEY JR., Appellant, v. STATE OF FLORIDA No. 1D17-0064 STATE OF FLORIDA, Appellee. On appeal from the Circuit Court for Clay County. John H. Skinner, Judge. April
More informationAGREEMENT BETWEEN AND THE GOVERNMENT OF THE CZECH REPUBLIC
AGREEMENT BETWEEN THE GOVERNMENT OF THE REPUBLIC OF MAURITIUS AND THE GOVERNMENT OF THE CZECH REPUBLIC FOR THE PROMOTION AND RECIPROCAL PROTECTION OF INVESTMENTS The Government of the Republic of Mauritius
More informationO.C.G.A GEORGIA CODE Copyright 2015 by The State of Georgia All rights reserved. *** Current Through the 2015 Regular Session ***
O.C.G.A. 48-5-311 GEORGIA CODE Copyright 2015 by The State of Georgia All rights reserved. *** Current Through the 2015 Regular Session *** TITLE 48. REVENUE AND TAXATION CHAPTER 5. AD VALOREM TAXATION
More informationTHE IMMIGRATION ACTS. Before UPPER TRIBUNAL JUDGE HEMINGWAY. Between ENTRY CLEARANCE OFFICER. and
IAC-AH-SAR-V1 Upper Tribunal (Immigration and Asylum Chamber) THE IMMIGRATION ACTS Heard at Bradford Decision & Reasons Promulgated On 27 th October 2015 On 6 th November 2015 Before UPPER TRIBUNAL JUDGE
More informationIN THE COMMONWEALTH COURT OF PENNSYLVANIA
IN THE COMMONWEALTH COURT OF PENNSYLVANIA Lawrence P. Olster, : Petitioner : : v. : : Unemployment Compensation : Board of Review, : No. 763 C.D. 2012 Respondent : Submitted: October 5, 2012 BEFORE: HONORABLE
More informationYour guide to debt management
Your guide to debt management This guide will help you understand debt management: what it is and who it can help. There are many solutions that help people deal with debt so it s best to get the advice
More informationFreedom of Information Request Reference No: I note you seek access to the following information:
Freedom of Information Request Reference No: I note you seek access to the following information: Please can you provide me with annual figures for the number of petrol station drive-offs - or making off
More information14 Tips To Help Deal With (Or Avoid) The IRS In 2014
Portfolio Media. Inc. 860 Broadway, 6th Floor New York, NY 10003 www.law360.com Phone: +1 646 783 7100 Fax: +1 646 783 7161 customerservice@law360.com 14 Tips To Help Deal With (Or Avoid) The IRS In 2014
More information1- The term "Investment" means every kind of properties and more particularly though not exclusively:
AGREEMENT BETWEEN THE GOVERNMENT OF THE HASHEMITE KINGDOM OF JORDAN AND THE GOVERNMENT OF THE REPUBLIC OF TUNISIA ON THE MUTUAL PROMOTION AND PROTECTION OF INVESTMENTS The Government of the Hashemite Kingdom
More information