FIDIC WORKSHOP 2016 GROUP 6
|
|
- Rhoda James
- 5 years ago
- Views:
Transcription
1 FIDIC WORKSHOP 2016 GROUP 6
2 QUESTION 1 WHAT ARE THE ESSENTIAL REQUIREMENTS FOR FORMATION OF CONTRACT? DISCUSS WHETHER A BINDING AND ENFORCEABLE CONTRACT HAS BEEN CONCLUDED BETWEEN JOLLY AND CAN-DO.
3 1. TENDERS AS OFFERS. The building owner who invites tenders is only indicating an intention to receive (invitation to treat) tenders for a particular project. When a contractor submits his tender, his tender is an offer made to the owner. Until the offer is duly accepted, no contractual obligations arise. In a contract, each party must have given consideration for the promise. 2. QUALIFICATIONS IN A TENDER SUBMITTED. Quite often, tenderers may consider certain aspect of the design to be unnecessarily costly or decide that certain contract conditions to be commercially inefficient or impose undue risks. In this case, the tenderer may seek to qualify the tender by excluding or amending certain conditions which he considers may increase the attractiveness of his tender. Where a contractor submits his tender with qualifications and the tender is successful, the question which often arises is whether the contract as awarded incorporates these qualifications.
4 3. ACCEPTANCE OF TENDER A tender (offer) may be accepted any time after it is made. Generally, the tender is open for a period of time which is called the tender validity period. Upon the expiry of the stipulated period, the offer lapses and can no longer be effectively accepted. The general principle of common law is that an offer can be withdrawn any time before acceptance unless there is a separate undertaking to keep the offer open. It is common for tenderers to pay a tender deposit which can be forfeited in the event that the tenderer withdraws his tender before the expiry of the offer period. The acceptance of an offer must be unambiguous and must be communicated to the tenderer before a contract can be made. Acceptance may be implied by conduct. This principle is codified in section 8 of the contracts act LETTER OF INTENT Once the owner has selected the contractor, he may communicate his decision by issuing a letter of intent which is understood that the owner intends to award the contract to the contractor. Although a letter of intent is usually stated to be nonbinding, the purpose here is to provide the contractor with some degree of assurance to persuade him to commence the mobilization of resources for the project. Contractor may also deem it a sufficient basis to place orders for materials which requires long lead time.
5 5. ESSENTIAL TERMS OF AGREEMENT. Lord Blackburn in Rossiter v Miller (1878) held that if some particulars essential to the agreement still remain to be settled afterwards, then there is no contract. Normally, an agreement requires the parties, price, time and description of works(scope of works) as the minimum necessary for a contract to be workable. 6. LETTER OF AWARD. The formal letter of award can be issued by the owner once both parties have agreed on the principal terms of the contract. The letter is usually incorporated as part of the contract document. Quite often, the letter of award may be issued even though not all terms have been agreed between the parties, e.g. The definitions of milestones within a programme, insurance and performance bonds to be subject of negotiations until after the works have commenced. The typical contents in the letter of award are follow under contract act of section 6.1 to section 6.7
6 Answer : There is an enforceable contract between Jolly and Can-do. In the event of Can-do(contractor) was given possession of the site by Jolly(client) and instructed to commence the work. Although, there was no letter of acceptance was signed but Can-do(contractor) had begun the work while the contract documents were being prepared and finalized for signing. Under red book of FIDIC in section , letter of acceptance means the letter of formal acceptance, signed by the employer, of the letter of tender, including any annexed memoranda comprising agreements between and signed by both parties. If there is no such letter of acceptance, the expression letter of acceptance means the contract agreement and the date of issuing or receiving the letter of acceptance means the date of signing the contract agreement. In such case, Bang-Bang(project manager) requested Can-do to expedite the preparation of the contract documents for signing. The bound contract documents incorporated all the correspondence and documents listed in the letter of acceptance. In Event that MrJoll (client) would be in the country brief stopover and inform Bang-bang(PM) requested Candp(contractor) to expedite the preparation of the contract documents for signing.
7 CASE LAW The classic case of Trollope & Colls Ltd V Atomic Power Construction Ltd (1963) support this situation where the subcontractors were notified of changes to the works after their submission of tender. They were instructed to commence work on the following terms: as soon as matters outstanding between us are settled we will enter into a contract agreement with you, and in the meantime please accept this letter as an instruction to proceed although no contract was actually signed, the english court held that a contract came into existence when the contractor commenced work.
8 QUESTION 2 ADVISE JAZZY ON THE VALIDITY OF CAN-DO S CLAIM FOR EXTENSION OF TIME AND ADDITIONAL PAYMENT ARISING FROM THE COLLAPSED TEMPORARY WORKS.
9 Based on the red book FIDIC in section 20.1_contractor s claim; if the contractor considers himself to be entitled to any extension of the time of completion and or any additional payment, under any clause of these conditions or otherwise in connection with the contract, the contractor shall give notice to the engineer, describing the event or circumstances giving rise to the claim. The notice shall be given as soon as practicable, and not later than 28 days after the contractor become aware, or should have become aware, of the event or circumstance. If the contractor fails to give notice of a claim within such period of 28days, the time for completion shall not be extended, the contractor shall not be entitled to additional payment and the employer shall be discharged from all liability in connection with the claim.
10 Answer : Base on the situation, the contractor considers himself to be entitled to claim for extension for time and additional payment. The reasons behind his claim as described states that the collapse temporary works was due to the changes in design and method statement made by the engineer instruction where as their initial temporary works design would have been able to sustain during the national phenomenon, under 23.1 and 23.8(a) relevant events_force majeure of the PAM contract form Thus, they considers themselves entitled to claim for the delay 7 days given the reason that the collapsed temporary works was due to the engineer change in design and method statement towards their initial temporary work design. However, the contractor is not entitled to claim for EOT or additional payment because he failed to notify the engineer about the collapsed temporary works within 28 days of the incident that the contractor has become aware of consider as stated in section 20.1; even if the mistake of changing the design and method was done by the engineer. As a conclusion, the contractor claims for EOT is invalid
11 QUESTION 3 HOW SHOULD JAZZ RESPOND TO CAN-DO WITH REGARD TO THE LATTER S CLAIM FOR EXTENSION OF TIME FOR THE DELAY CAUSED BY THE RAIN?
12 Under Red Book FIDIC in section 8.4 (b) extension of time for completion stated that the contractor shall be entitled subject to extension of the time for completion if the completion will be delayed by the exceptionally adverse climatic conditions. In this case, the works have been suffer exceptionally heavy rain and con-do (contractor) has submitted the claim for extension of the time completion 40 days after the event. Under Red Book FIDIC in section 20.1 contractor s claims stated that extension of time for completion and additional payment, the contractor shall give notice to the engineer. The notice shall be given not later than 28 days from the event or circumstances. If the contractors fails to give notice of the claim within such period of 28 days, the extension for completion shall not be extended. In this case, the engineer still granted 7 days extension of time to the contractors although the contractors submit the notice of claim for extension of time 40 days after the event or circumstances. Therefore, the contractor shall not be entitled for any extension of time. Moreover, in the contract, the jolly has instructed gulp to delete the sub-clauses on exceptionally adverse climatic condition. As a conclusion, contractor shall not entitled for any extension of time.
13 Under PAM form clauses 23.0 submission of notice and particulars for extension of time, if the contractors think that the works will be delayed beyond the completion date by any of the relevant events stated in clauses 23.8, he may apply for an extension of time. The contractors shall give written notice within 28 days. In this case, there is exceptionally heavy rain in the site, which referred in relevant events in clause 23.8 (b) exceptionally inclement weather. The contractor submitted the notice 40 days after the event. Which mean it exceed the time period to submit the notice of extension of time.
14 QUESTION 4 IF THE STANDARD FORM OF CONTRACT IS THE AGREEMENT AND CONDITIONS OF PAM CONTRACT 2006 (WITHOUT QUANTITIES), ADVICE PICASSO, IN THEIR CAPACITY AS AN ARCHITECT, ON THE PROCEDURE FOR DEALING WITH THE EXTENSION OF TIME ARISING FROM THE INSTRUCTION FOR FURTHER CHANGES TO THE APARTMENT TYPE MIX AND HOW THEY SHOULD RESPOND TO THE REQUEST FROM CAN-DO SINCE THE COMPLETION DATE HAS PASSED AND A CERTIFICATE OF NON-COMPLETION HAD ALREADY BEEN ISSUED
15 Under standard form of contract PAM 2006 (without quantities) clause 23.9 (extension of time after the issuance of certificate of non-completion) stated that where a relevant event occurs after the issuance of the certificate of non-completion, the architect shall grant an extension of time. The extension of time granted shall be added to the completion date of the works or any section of the works. Whereas the contractor, can-do, struggled to complete the works and the time for completion already expired, as a result of CNP, he also suffered for liquidated damages. Plus, the relevant event supported by clause 23.8(e) which mentioned the contractor not having received in due time the necessary AI for which he had specifically applied in writing to the architect. The contractor s application must be submitted to the architect in sufficient time before commencement of construction of the affected works, to enable the architect to issue the necessary AI within a period which would not materially affect the progress of the affected works, having regard to the completion date. Jolly requested jazz to instruct can-do to make further changes to the apartment. In order to follow the instruction, can-do requested for extension of time as they were not prepared to carry out the additional changes and time of completion had expired. In this case, Picasso, the architect, shall grant extension of time to can-do as the additional changes will affect the works as it is one of the relevant event stated in clause 23.8(e).
16 QUESTION 5 ADVISE JOLLY ON THE CONTRACTUAL IMPLICATIONS OF REPLACING ER JAZZY AND APPOINTING THEIR OWN EMPLOYEE, ER JO-JO, AS THE NAMED ENGINEER
17 Under red book FIDIC in section 3.4 replacement of the engineer, if the employer intends to replace the engineer, the employer shall, not less than 21 days before the intended date of replacement, give notice to the contractor of the name, address and relevant experience of the intended replacement engineer. In this case, assuming jolly(client) wrote an to can-do(contractor) stated that jolly(client) want to ceased Er Jazzy(engineering) work under the contract with immediate effect. Furthermore, jolly(client) want to replace Er Jazzy to Er Jo-Jo and acted as the engineer for the purpose of the contract. Thus, jolly(client) cannot replace Er Jo-Jo with immediate effect unless given notice not less than 21days and if the con-do(contractor) considers the intended replacement engineer to be unsuitable, the Can-do(contractor) may raise reasonable objection with supporting reasons to the Jolly(client). The Engineer acts as an agent of the employer and an individual certifier who is able to acts on his own opinion. In the case where Jolly appoint Er Jo-Jo who is one of his employee, the question would arise whereby whether Er. Jo-Jo can acts on his own opinion as a certifier without being interfered by his employer (Jolly) and might act unfairly towards the contractor.
18 FIDIC 6. PROCEDURE AND CONSEQUENCES FOR SUSPENSION OF WORKS. -CLAUSE 8.8 STATES THAT ENGINEER MAY AT ANY TIME INSTRUCT TO SUSPEND PROGRESS OF PART OR ALL OF WORK AND MAY NOTIFY THE CAUSE OF SUSPENSION. -CONTRACTOR SHALL PROTECT, STORE, SECURE WORKS AGAINST DETERIORATION, LOSS, DAMAGE. -CLAUSE 8.9 CONSEQUENCES OF SUSPENSION BASED ON THIS CLAUSE WHERE CONTRACTOR SUFFERS DELAY OR INCURS COST FROM COMPLYING WITH ENGINEER INSTRUCTION UNDER CLAUSE 8.8 AND OR FROM RESUMING WORK. -CLAUSE 20.1 AN EXTENSION OF TIME FOR SUCH DELAY OR PAYMENT OF ANY COST WHICH SHALL BE INCLUDED IN CONTRACT PRICE. -CLAUSE 3.5 AFTER RECEIVING THE NOTICE, THE ENGINEER SHALL PROCEED IN ACCORDANCE WITH THIS CLAUSE TO AGREE OR DETERMINE THESE MATTERS. -CLAUSE 8.11 IF THE SUSPENSION UNDER CLAUSE 8.8 CONTINUED FOR MORE THAN 84 DAYS, CONTRACTOR MAY REQUEST THE ENGINEER'S TO PROCEED AND IF THE ENGINEER DOES NOT GIVE PERMISSION WITHIN 28 DAYS AFTER BEING REQUESTED. CONTRACTOR MAY TREAT THE SUSPENSION AS AN OMISSION UNDER CLAUSE 13 OF THE AFFECTED PARTS OF WORKS AND IF IT AFFECT THE WHOLE WORK, THE CONTRACTOR MAY GIVE NOTICE OF TERMINATION UNDER CLAUSE 16.2 (TERMINATION BY CONTRACTOR).
19 -CLAUSE IF ENGINEER FAILS TO CERTIFY IN ACCORDANCE TO CLAUSE 14.6 (ISSUE OF INTERIM PAYMENT CERTIFICATE)OR EMPLOYER FAILS TO COMPLY WITH CLAUSE 2.4 EMPLOYER'S FINANCIAL ARRANGEMENT) OR CLAUSE 14.7 (PAYMENT), THE CONTRACTOR MAY, AFTER GIVING NOT LESS THAN 21 DAYS NOTICE TO THE EMPLOYER, SUSPEND WORK UNTIL THE CONTRACTOR RECEIVE THE PAYMENT. -BASED ON THE INCIDENT GIVEN, CAN-DO CAN SUBJECT TO CLAIMS TO AN EXTENSION OF TIME FOR ANY SUCH DELAY OR PAYMENT OF ANY SUCH COST WHICH SHALL BE INCLUDED IN CONTRACT PRICE IF THE SUSPENSION OF WORK IS ORDERED BY THE ENGINEER. THEY COULD ALSO TERMINATE THEMSELVES IF THE SUSPENSIONS IS PROLONGED.
20 PAM 2006 (WITH QUANTITIES) -THERE'S NO CLAUSES WHICH SUPPORTS AN ENGINEER TO SUSPEND ANY WORK. -HOWEVER, CLAUSE 30.7 WHICH STATES THAT THE CONTRACTOR CAN SUSPEND WORK WHEN THE EMPLOYER FAILS OR NEGLECTS TO PAY THE CONTRACTOR THE AMOUNT DUE AS SHOWN IN PAYMENT CERTIFICATE. -CLAUSE STATES THAT IF THE ARCHITECT OR CONSULTANT INFORM THE CONTRACTOR IN WRITING OF THEIR WITHDRAWER FROM THE SUPERVISION OF THE EXECUTION OF THE WORKS REQUIRED UNDER THE LOCAL BUILDING BY-LAWS FOR WHATEVER REASON THE CONTRACTOR SHALL FORFEIT SUSPEND THE EXECUTION OF WORKS AND CONTINUE SUCH SUSPENSIONS UNTIL THE PRESUMPTION OF THE SAID SUPERVISION. -THE CONTRACTOR MAY SUSPEND ALL THE WORKS TILL THE HE RECEIVE THE PAYMENT OR ELSE HE CAN TERMINATE HIS OWN EMPLOYMENT.
21 7. ADVICE ON RESPONSE ON SUB-CLAUSES TO BE DELETED IN CONTRACT FORM. - GULP SHOULD ADVICE JOLLY ON THE IMPLICATION ON REMOVING THE CLAUSE WHICH WERE RELEVANT TO THE EXTENSION OF TIME. - THIS ACTION IS NOT ADVISABLE AS IF THERE'S NO EOT, THE EMPLOYER CANNOT SET A NEW COMPLETION DATE, THE CONTRACTOR OBLIGATION THEN IS TO COMPLETE IN A 'REASONABLE TIME' WHERE IT MAY TAKE A LONGER TIME TO COMPLETE BECAUSE THERE'S NO DEFINITE COMPLETION DATE TO WORK TOWARDS. - THE PROJECT MAY COST MORE THAN THE ORIGINAL PRICE SET, AND LASTLY THE TIME OF COMPLETION IS NOW 'AT LARGE' AND EMPLOYER LOSES HIS RIGHT TO IMPOSE LD. - THE PROJECT MAY COST MORE THAN THE ORIGINAL PRICE SET, AND LASTLY THE TIME OF COMPLETION IS NOW 'AT LARGE' AND EMPLOYER LOSES HIS RIGHT TO IMPOSE LD. - THE CONTRACTOR SHALL TAKE NOTE THAT HIS RISK IS NOW HIGHER AS HE BEARS THE RISK OF DELAY CAUSE BY THE NEUTRAL EVENT AND TO INCREASE HIS CONTRACT SUM.
22 - IF THERE'S EOT, THE COMPLETION DATE CAN BE EXTENDED WHEN THERE'S A DELAY WHICH WILL SET A NEW COMPLETION DATE TO WORK TOWARDS TOO. - IT ALSO PRESERVES THE EMPLOYER'S CONTRACTUAL RIGHTS SHOULD HE CAUSE WORKS TO BE DELAYED BY DEFAULT AND MOST IMPORTANTLY IT PREVENTS THE TIME FOR COMPLETION BEING AT LARGE. - IF THE DELAY IS CAUSE BY THE EMPLOYER, TIME WILL NOT BE ENLARGED.
23 8. IN EVENT CAN-DO BECOMES INSOLVENT FIDIC -CLAUSE 15.2(E) - THE EMPLOYER SHALL BE ENTITLED TO TERMINATE THE CONTRACT IF THE CONTRACTOR BECOMES INSOLVENT. IN THIS CASE, THE EMPLOYER MAY BY NOTICE TERMINATE THE CONTRACT IMMEDIATELY WITHOUT GIVING 14 DAYS NOTICE TO THE CONTRACTOR, TERMINATE THE CONTRACT AND EXPEL THE CONTRACTOR FROM THE SITE. THE EMPLOYERS ELECTION TO TERMINATE THE CONTRACT SHALL NOT PREJUDICE ANY OTHER RIGHTS OF THE EMPLOYER, UNDER THE CONTRACT OR OTHERWISE. -THE CONTRACTOR SHALL THEN LEAVE SITE AND DELIVER ANY REQUIRED GOODS, ALL CONTRACTOR S DOCUMENTS AND OTHER DESIGN DOCUMENTS MADE BY OR FOR HIM TO THE ENGINEER. HOWEVER, CONTRACTOR SHALL USE HIS BEST EFFORTS TO COMPLY IMMEDIATELY WITH ANY REASONABLE INSTRUCTIONS INCLUDED IN THE NOTICE FOR THE ASSIGNMENT OF ANY SUBCONTRACT FOR PROTECTION OF LIFE OR PROPERTY OR FOR THE SAFETY OF THE WORK
24 AFTER TERMINATION, EMPLOYER MAY COMPLETE WORKS AND/OR ARRANGE FOR ANY OTHER ENTITLES TO DO SO. THE EMPLOYER AND THESE ENTITLES MAY THEN USE ANY GOODS, CONTRACTOR S DOCUMENTS AND OTHER DESIGN DOCUMENTS MADE BY OR ON BEHALF OF THE CONTRACTOR. THE EMPLOYER SHALL THEN GIVE NOTICE THAT THE CONTRACTOR S EQUIPMENT AND TEMPORARY WORKS WILL BE RELEASED TO THE CONTRACTOR AT OR NEAR THE SITE. THE CONTRACTOR SHALL PROMPTLY ARRANGE THEIR REMOVAL, AT THE RISK AND COST OF CONTRACTOR. IF CONTRACTOR FAILS TO MAKE PAYMENT BY THIS TIME TO THE EMPLOYER, THESE ITEMS MAY BE SOLD BY THE EMPLOYER TO RECOVER THIS PAYMENT. ANY BALANCE OF THE PROCEEDS SHALL THEN BE PAID TO THE CONTRACTOR.
25 PAM 2006 (WITH QUANTITIES) -CLAUSE 25.4-IN THE EVENT THE CONTRACTOR BECOMING INSOLVENT, THE EMPLOYMENT OF THE CONTRACTOR SHALL BE FORTHWITH AUTOMATICALLY DETERMINED. -CLAUSE 25.4 (A) - THE CONTRACTOR SHALL VACATE THE SITE AND RETURN POSSESSION OF THE SITE TO THE EMPLOYER WHO MAY EMPLOY AND PAY OTHER PERSON TO CARRY OUT AND COMPLETE THE WORKS AND TO MAKE GOOD ANY DEFECTS. SUCH PERSON MAY ENTER UPON THE WORKS AND USE ALL TEMPORARY BUILDINGS, CONSTRUCTION PLANT, TOOLS, MATERIALS AND GOODS INTENDED FOR, DELIVERED TO AND PLACED ON OR ADJACENT TO THE SITE (EXCEPT CONSTRUCTION PLANTS HIRED BY CONTRACTOR) AND MAY PURCHASE ALL MATERIALS AND GOODS NECESSARY FOR CARRYING OUT AND THE COMPLETION OF THE WORKS. THE CONTRACTOR IF SO REQUIRED BY THE EMPLOYER OR BY THE ARCHITECT ON BEHALF OF THE EMPLOYER SHALL WITHIN 21 DAYS OF THE DATE OF DETERMINATION, ASSIGN TO THE EMPLOYER THE BENEFIT OF ANY AGREEMENT FOR THE CONTINUATION OF THE HIRE OF CONSTRUCTION PLANT AND EQUIPMENT ALREADY ON THE SITE.
26 CLAUSE 25.4 (B) - THE CONTRACTOR IS SO REQUIRED BY THE EMPLOYER OR ARCHITECT, SHALL WITHIN 21 DAYS OF DETERMINATION, ASSIGN THE EMPLOYER WITHOUT PAYMENT THE BENEFIT OF ANY AGREEMENT FOR THE SUPPLY OF MATERIALS, GOODS AND/OR FOR THE EXECUTION OF ANY WORK FOR THE PURPOSES OF THE CONTRACT TO THE EXTENT THAT THE SAME IS ASSIGNABLE. CLAUSE 25.4 ( C ) - THE CONTRACTOR WHEN INSTRUCTED IN WRITING BY ARCHITECT SHALL REMOVE THE WORKS ANY TEMPORARY BUILDINGS, CONSTRUCTION PLANT, TOOLS, EQUIPMENT, MATERIALS AND GOODS BELONGING TO OR HIRED BY HIM. IF WITHIN A REASONABLE TIME AFTER ANY SUCH INSTRUCTION HAS BEEN ISSUED TO CONTRACTOR, HE HAS NOT COMPLIED WITH, THE EMPLOYER MAY WITHOUT LIABILITY REMOVE AND SELL ANY SUCH PROPERTY BELONGING TO THE CONTRACTOR EXCEPT THOSE THAT ARE ON HIRE AND HOLD THE PROCEEDS LESS ALL COSTS INCURRED TO THE CREDIT OF THE CONTRACTOR.
27 CLAUSE 25.4 (D) - THE CONTRACTOR SHALL ALLOW OR PAY TO THE EMPLOYER ALL COST INCURRED TO COMPLETE THE WORKS INCLUDING ALL LOSS AND/OR EXPENSE SUFFERED BY THE EMPLOYER. UNTIL AFTER THE COMPLETION OF THE WORKS UNDER CLAUSE 25.4(A), THE EMPLOYER SHALL NOT BE BOUND BY ANY PROVISION IN THE CONTRACT TO MAKE ANY FURTHER PAYMENT TO THE CONTRACTOR, INCLUDING PAYMENTS WHICH HAVE BEEN CERTIFIED BUT YET PAID WHEN THE EMPLOYMENT OF THE CONTRACTOR WAS DETERMINED. UPON COMPLETION OF THE WORKS, AND ACCOUNT TAKING INTO CONSIDERATION THE VALUE OF WORKS CARRIED OUT BY THE CONTRACTOR AND ALL COST INCURRED BY EMPLOYER TO COMPLETE THE WORKS INCLUDING LOSS AND/OR EXPENSES SUFFERED BY THE EMPLOYER SHALL BE INCORPORATED IN A FINAL ACCOUNT PREPARED IN ACCORDANCE WITH CLAUSE 25.6
28 QUESTION 9 ADVISE JAZZ ON THE MANNER IN WHICH THE EXTENSION OF TIME WAS PURPORTEDLY GIVEN FOR THE RECONFIGURATION OF THE BEDROOMS.
29 ACCORDING TO PAM FORM 2006, JAZZ IS THE CIVIL AND STRUCTURAL ENGINEER APPOINTED FOR THIS PROJECT. CLAUSE 2.1 STATES THAT THE ARCHITECT IS EMPOWERED BY THE CONDITIONS TO ISSUE INSTRUCTIONS THUS, THE ARCHITECT IS THE CONTRACT ADMINISTRATOR JAZZ DOES NOT HAVE ANY CONTRACTUAL RIGHTS TO ADMINISTRATE THE CONTRACT, THUS CANNOT GRANT EXTENSION OF TIME
30 ACCORDING TO PAM FORM 2006, ASSUME PICASSO WHICH IS THE CONTRACT ADMINISTRATOR IS THE ONE WE ARE ADVISING. SCENARIO: CAN-DO (CONTRACTOR) GAVE NOTICE OF DELAY AND REQUESTED FOR AN EOT FOR RECONFIGURATION OF THE BEDROOM 6 MONTHS AFTER THE VARIATION WORKS WERE ORDERED. CLAUSE 23.1 (A) STATES THAT THE CONTRACTOR SHALL GIVE WRITTEN NOTICE TO THE ARCHITECT HIS INTENTION TO CLAIM FOR SUCH EOT WITHIN 28 DAYS FROM THE DATE OF THE AI CLAUSE 23.1 (B) STATES THAT IF THE CONTRACTOR FAILS TO SUBMIT SUCH PARTICULARS WITHIN THE STATED TIME, IT SHALL BE DEEMED THAT THE CONTRACTOR HAS ASSESSED THAT SUCH RELEVANT EVENT WILL NOT DELAY THE COMPLETION OF THE WORKS
31 ACCORDING TO FIDIC FORM, SCENARIO: CAN-DO (CONTRACTOR) GAVE NOTICE OF DELAY AND REQUESTED FOR AN EOT FOR RECONFIGURATION OF THE BEDROOM 6 MONTHS AFTER THE VARIATION WORKS WERE ORDERED. SUB-CLAUSE 20.1 STATES THAT IF THE CONTRACTOR FAILS TO GIVE NOTICE OF A CLAIM WITHIN SUCH PERIOD OF 28 DAYS, THE TIME FOR COMPLETION SHALL NOT BE EXTENDED
32 ACCORDING TO PAM FORM 2006 & FIDIC FORM, CAN-DO (CONTRACTOR) IS NOT ENTITLED FOR EOT, AS THE CONTRACTOR GAVE LATE NOTICE OF DELAY (6 MONTHS INSTEAD OF 28 DAYS FROM THE DATE OF THE EVENT) NOTICE OF DELAY IS A CONDITION PRECEDENT OF ANY EOT ENTITLEMENT JAZZ SHOULD NOT HAVE GRANTED THE EOT REQUESTED. HOWEVER, AS THE CLAUSES FOR EOT IN THE FIDIC HAS NOW BEEN DELETED ON JOLLY S INSTRUCTION AND VARIATION FALLS UNDER THE CATEGORY OF DELAY BY EMPLOYER, THE TIME WOULD BE AT LARGE WHEN TIME IS AT LARGE, JAZZ SHOULD ASSESS THE REASONABLE TO COMPLETE SUCH WORKS AND IF SUCH WORK IS NOT COMPLETED IN TIME, JOLLY CAN SUE THE CONTRACT UNDER COMMON LAW AS THE DELAY DAMAGES NO LONGER APPLIES. IN THIS CASE, JAZZ SHOULD ACT ON HIS OWN OPINION AS AN INDEPENDENT CERTIFIER AND NOT SUBJECT TO APPROVAL OF JOLLY (THE EMPLOYER).
33 QUESTION 10 a) ADVISE JAZZ ON WHAT THEY HAVE TO DO AND ON THE CONSEQUENTIAL EFFECTS IF JOLLY WISHES TO TAKE OVER PART OF THE WORKS BEFORE COMPLETION OF THE WHOLE WORKS. b) IF THE CONTRACT FORM IS THE AGREEMENT AND CONDITIONS OF PAM CONTRACT 2006 (WITH QUANTITIES), HOW WILL YOU ADVISE PICASSO? ANSWER THE QUESTION ON THE ASSUMPTION THAT NO CERTIFICATION OF NON-COMPLETION HAS BEEN ISSUED BY PICASSO.
34 QUESTION 10 (A) THIS QUESTION IS RELEVANT TO SUB-CLAUSE 10.2 OF FIDIC CONDITIONS OF CONTRACT FOR CONSTRUCTION. JAZZ SHALL ISSUE A TAKING-OVER CERTIFICATE FOR THE PART OF WORK THAT JOLLY WISHES TO TAKE OVER BEFORE THE COMPLETION OF WHOLE WORK UPON ISSUANCE, CAN-DO SHALL BE GIVEN EARLIEST OPPORTUNITY AND SHALL CARRY OUT TESTS ON COMPLETION AS SOON AS PRACTICABLE BEFORE THE END OF DEFECTS NOTIFICATION PERIOD. JOLLY SHALL NOT USE PART OF THE WORK BEFORE THE ISSUANCE OF TAKING-OVER CERTIFICATE
35 QUESTION 10 (A) WHAT IF JOLLY USED THE PART OF WORK BEFORE THE ISSUANCE? THE PART WHICH IS USED WILL BE DEEMED TO HAVE BEEN TAKEN OVER THE RESPONSIBILITY NOW LIES ON JOLLY, NOT CAN-DO CAN-DO CAN REQUEST JAZZ TO ISSUE THE TAKING-OVER CERTIFICATE
36 QUESTION 10 (A) CONSEQUENTIAL EFFECT: DAILY RATE OF DELAY DAMAGES PROPORTIONATELY REDUCED DEFECTS NOTIFICATION PERIOD STARTS [SUB-CLAUSE 11.1] CARE OF PARTS ENDS EXCEPT IN RESPECT OF ANY OUTSTANDING WORK SITE POSSESSION RETURNS TO EMPLOYER EXCEPT ACCESS TO COMPLETE OUTSTANDING WORK OBLIGATION TO INSURE AND MAINTAIN INSURANCE COVER ENDS
37 CONSEQUENTIAL EFFECT (CONT D) QUESTION 10 (A) FIRST HALF OF THE RETENTION MONEY CERTIFIED AND PAID FOR THE PART [SUB-CLAUSE 14.9] 84-PERIOD FOR SUBMISSION OF STATEMENT AT COMPLETION STARTS [SUB-CLAUSE 14.10] NO FURTHER VARIATION CAN BE ISSUED [SUB-CLAUSE 13.1]
38 QUESTION 10 (B) THIS QUESTION IS RELEVANT TO CLAUSE 16 OF PAM CONTRACT PICASSO SHALL GIVE WRITTEN NOTICE OF INTENTION TO TAKE PARTIAL POSSESSION TO CAN- DO PICASSO SHALL IDENTIFY PART TO BE TAKEN OVER HE SHALL MAKE SURE THAT THE CONTRACTOR HAS GIVEN HIS CONSENT HE SHALL ALSO ISSUE THE CERTIFICATE OF PARTIAL COMPLETION WITHIN 14 DAYS OF TAKING PARTIAL POSSESSION AS STATED IN CLAUSE 16.1(A)
39 QUESTION 10 (B) CERTIFICATE OF PARTIAL COMPLETION SHALL INCLUDE DATE OF PARTIAL POSSESSION LAYOUT PLAN TO IDENTIFY THE OCCUPIED PART ESTIMATED VALUE OF OCCUPIED PART
40 QUESTION 10 (B) CONSEQUENTIAL EFFECTS: EFFECT OF PRACTICAL COMPLETION IS APPLIED ON THE TAKEN PART [CLAUSE 16.1(B)] DEFECT LIABILITY PERIOD COMMENCED FOR THE OCCUPIED PART LIQUIDATED DAMAGES REDUCED BY RATIO OF ESTIMATED VALUE OF OCCUPIED PART TO CONTRACT SUM [CLAUSE 16.1(C)] ISSUE PAYMENT CERTIFICATE TO RELEASE HALF OF RETENTION SUM WITHIN 14 DAYS BY RATIO OF ESTIMATED VALUE OF OCCUPIED PART TO CONTRACT SUM [CLAUSE 16.1(D)]
41 QUESTION 10 (B) CONSEQUENTIAL EFFECTS: DLP ENDS EARLIER, ISSUANCE OF CERTIFICATE OF MAKING GOOD DEFECTS UPON ENDING OF DLP FOR OCCUPIED PART ISSUE PAYMENT CERTIFICATE OF 2 ND HALF OF RETENTION SUM WITHIN 14 DAYS AFTER CMGD
42 CALCULATION ON RETENTION SUM/MONEY ASSUMING THE PART TAKEN OVER HAS AN ESTIMATED VALUE OF RM 20,200, MAXIMUM RETENTION ASSUMED TO BE 5 %, CALCULATION FOR FIDIC WILL BE AS FOLLOWED: AS FOR PAM, THE CALCULATION WILL BE RM20,200,200.00/RM80,800, X RM4,040, X ½ =RM505, RM20,200,200.00/RM80,800, X RM4,040, X 40% = RM404,004.00
43 CALCULATION FOR DELAY/LIQUIDATED DAMAGE FOR FIDIC AND PAM RM20,200,200.00/RM80,800, X RM1,000, = RM250, THE DELAY DAMAGE TO BE IMPOSED = RM1,000, RM250, = RM750,000.00
44 QUESTION 11 DISCUSS JAZZ S ACTION TO ISSUE AN INSTRUCTION TO OMIT PORTIONS OF THE WORKS FROM CAN-DO S CONTRACTED SCOPE SO THAT ANOTHER CONTRACTOR CAN BE ENGAGED TO CARRY OUT THE OMITTED PORTIONS.
45 PAM Form 2006 (With Quantities) assume Engineer is Architect A certain portion of works have been omitted from the Engineer s Instructions assigned to Can-Do and have been arranged for another contractor to carry out the omitted works. From the point of view of the Contractor: As stated in Clause 6.1, all works, materials, goods and workmanship shall be of the respective quality and standards described in the Contract Document. According to Clause 6.5, In the case where it is not up to quality, the consultant admin may a) Remove the materials from site b) To demolish and reconstruct c) To rectify such work as AI d) To submit a method statement within 7 days of receipt of the written instructions e) To leave all works with the consent of the employer together with the appropriate set-off As stated in Clause 15.3(b), 15.4, 15.5, 29.1, 30.4 if the Contractor, Can-Do fails to attend to the defects, the employer may employ and pay other Person to rectify the defects. All defects not made good by the Contractor shall be set-off.
46 11.Discuss Jazz s action to issue an instruction to omit portions of the works from Can-Do s contracted scope so that another contractor can be engaged to carry out the omitted portions. FIDIC Contract Form Based on Clause 4.9, the contractor shall institute a quality assurance system to demonstrate compliance with the requirements of the Contract. Compliance with the quality assurance system shall not relieve the Contractor of any of his duties, obligations or responsibilities under the Contract, which in this case Can-Do did not comply with the quality assurance system. Based on Clause 7.6, if the Contractor fails to comply with the instructions, the Employer, Jolly is entitled to employ and pay other Person to carry out the work. Except to the extent that the Contractor would have been entitled to payment for the work, the Contractor shall subject to Sub-Clause 2.5 pay to the Employer all costs arising from this failure.
47 QUESTION 12 ADVISE JOLLY (EMPLOYER) ON THEIR RIGHTS IN RESPECT OF THE FAILURE OF THE MEMBRANE ROOFING WORKS.
48 12. Advise Jolly (Employer) on their rights in respect of the failure of the membrane roofing works. PAM Form 2006 (With Quantities) Due to the failure of the membrane roofing works, Jolly has the rights to set-off all cost incurred for loss and expense which such as stated Clause 30.4 where the contractor is in breach of the followings: a) Under clause 15.3(b) where failure to comply with his undertaking to rectify minor defects, Jolly is able to engage other Person to execute the works to give effect to the contractor s said undertaking. All cost including loss and expense shall be set-off by the employer. b) Besides, under clause 15.3(c), Jolly can accept the defects as it is, but subject to an appropriate set-off against the contractor, Can-Do.
49 12. Advise Jolly (Employer) on their rights in respect of the failure of the membrane roofing works. FIDIC Contract Form Under Clause 11.3, Jolly shall be entitled subject to Sub-Clause 2.5 to an extension of the Defects Notification Period for the Works or a Section if and to the extent that the Works, Section or a major item of Plant cannot be used for the purposes for which they are intended by reason of a defect or damage. However, a Defects Notification Period shall not be extended by more than two years. Since the Defects Notification Period had expired, under Clause also stated that each Party shall remain liable for the fulfilment of any obligation which remains unperformed at that time; and as for the purposes of determining the nature and extent of unperformed obligations, the Contract shall be deemed to remain in force.
50 QUESTION 13 WHAT ARE THE DUTIES AND OBLIGATIONS OF JAZZ AND CAN DO FOLLOWING RECEIPT OF THE NOTICES FROM THE LATTER ON THEIR CLAIM FOR EXTENSION OF TIME AND ADDITIONAL PAYMENT.
51 FIDIC IN ACCORDANCE TO CLAUSE 20.1
52 JAZZ HAS 42 DAYS FROM RECEIPT OF FULLY DETAILED CLAIM TO RESPOND WITH HIS APPROVAL, DISAPPROVAL OR DETAILED COMMENTS, AND MAY ALSO REQUEST FURTHER PARTICULARS. CAN DO (CONTRACTOR) IS OBLIGED TO KEEP CONTEMPORARY RECORDS TO SUBSTANTIATE THE CLAIM. JAZZ (ENGINEER) MAY MONITOR RECORD KEEPING AND INSTRUCT IF NECESSARY, FURTHER RECORDS FROM CAN DO. CAN DO SHOULD ALLOW INSPECTION OF RECORDS AND IF REQUESTED, SUBMIT COPIES TO JAZZ. IF DELAYING EVENT HAS NO CONTINUING EFFECTS, CAN DO SUBMITS FINAL ACCOUNT OF CLAIM WITHIN 28 DAYS OF CESSATION OF EFFECTS ( OR SUCH PERIOD APPROVED BY JAZZ)
53 IF EVENT IS CONTINUING, CONTRACTOR SUBMITS INTERIM ACCOUNT AT INTERVALS AS REQUIRED BY JAZZ. IN THE ABSENCE OF ANY AGREEMENT BETWEEN JOLL (EMPLOYER) AND CAN DO, JAZZ DETERMINES FAIR EXTENSION AND NOTIFIES CONTRACTOR. JAZZ HAS TO TAKE INTO ACCOUNT DELAY CAUSES AND EFFECT OF A REVIEW OF ANY PREVIOUS DETERMINATIONS OF TIME EXTENSIONS WHICH MAY RESULT IN AN INCREASE, BUT NOT A DECREASE, IN THE TOTAL TIME EXTENSION. AGREE OR MAKE FAIR DETERMINATION OF EOT NO TIME LIMIT FOR MAKING DETERMINATION BUT MUST NOT UNREASONABLY BE WITHHELD OR DELAYED BY JAZZ.
54 PAM (2006)
55 EOT AND LOSS AND/OR EXPENSE IS IN TWO DIFFERENT CLAUSES 23.0 AND 24.0 RESPECTIVELY IN THE PAM FORM UNLIKE IN FIDIC WHICH IS BOTH UNDER ONE CLAUSE.
56 ASSUMING PICASSO IS THE CONTRACT ADMINISTRATOR EXTENTION OF TIME CLAUSE 23.0 BEFORE GRANTING EOT THE JAZZ SHALL CONSIDER THE FOLLOWING : THE APPLICATION MUST BE IN WRITING THE CAUSE OF DELAY MUST BE WITHIN THE PROVISIONS OF THE CONTRACT (I.E. RELEVANT EVENTS STATED IN CLAUSE 23.8) CAN DO MUST HAVE TAKEN ALL PRACTICAL STEPS TO MITIGATE (PREVENT OR REDUCE) DELAY THE DELAYS MUST HAVE MATERIALLY DISRUPTED THE REGULAR PROGRESS OF THE WORKS, RESULTING IN THE COMPLETION DATE BEING BREACHED THE NETT EFFECTIVE DELAY MUST BE ASSESSED BASED ON APPROVED WORK PROGRAMME IN RELATION TO THE WHOLE OF THE WORKS.
57 AFTER PICASSO HAS COMPLETED HIS ASSESSMENT, HE HAS TO MAKE EITHER OF 2 DECISIONS: 1) REJECT THE CONTRACTOR S APPLICATION, STATING THE REASONS; OR 2) GRANT AN APPROPRIATE EXTENSION OF TIME AND ISSUE THE CERTIFICATE OF EOT, STATING THE FOLLOWING: AN ANALYSIS OF EACH EVENT CAUSING THE DELAY THE NO. OF DAYS GRANTED FOR EACH EVENT THE TOTAL NO. OF EOT AND THE NEW COMPLETION DATE A BREAK-DOWN OF THE EVENT-BY EVENT WITH THE RELEVANT REASONS.
58 TIMING OF ISSUE : WITHIN 6 WEEKS FROM THE DATE OF RECEIPT OF SUFFICIENT PARTICULARS; OR IF PICASSO CANNOT ISSUE EOT WITHIN 6 WEEKS, HE SHALL INFORM CAN DO FOR AN EXTENSION AND GET HIS CONSENT; OR IF PICASSO CANNOT DETERMINE THE EOT REQUIRED, HE MAY ISSUE A PROVISIONAL EOT AND LEAVE IT FOR REVIEW AFTER PRACTICAL COMPLETION (CLAUSE 23.10)
59 LOSS AND/OR EXPENSE - CLAUSE 24.0 BY RELEVANT EVENTS LISTED IN CLAUSE 24.3 PICASSO SHALL ASCERTAIN THE AMOUNT OF LOSS AND/OR EXPENSE. THE AMOUNT ASCERTAINED FROM TIME TO TIME SHALL BE ADDED TO THE CONTRACT SUM IF INTERIM CERTIFICATE IS ISSUED AFTER THE DATE OF ASCERTAINMENT, IT SHALL BE INCLUDED IN THE CERTIFICATE.
60 CONTRACTOR S COMMON LAW RIGHTS UPON REJECTION OF HIS CLAIMS: CAN DO MAY BE ABLE TO PURSUE HIS CLAIM UNDER COMMON LAW FOR DAMAGES. HE CAN ONLY DO THIS, PROVIDED HE HAS SATISFIED THE CONDITION PRECEDENT UNDER CLAUSE 24.1(A) REGARDING WRITTEN NOTICE
61 QUESTION 14 IF THE STANDARD FORM OF CONTRACT IS THE AGREEMENT AND CONDITIONS OF PAM 2006 (WITH QUANTITY), DISCUSS THE RULES TO BE CONSIDERED BY GULP (IN THEIR CAPACITY AS THE NAMED QUANTITY SURVEYOR) WHEN VALUING THE VARIATIONS RELATING TO THE RECONFIGURATION OF THE BEDROOMS.
62 PAM 2006 (WITH QUANTITIES) Clause 11.5 Valuation Of Variations And Provisional Sums All variations shall be measured and valued by the Quantity surveyor. Where any recording of the site information and/or site measurements are carried out at the site, the Contractor shall provide the Quantity Surveyor with such assistance as may be necessary to carry out the works and the Contractor shall be given opportunity to be present to take such notes and measurements as he may require Clause 11.6(a) Valuation Rules Where work is of similar character to, is executed under similar conditions as, and does not significantly change the quantity of work as set out in the contract documents, the rates and the prices in the contract documents shall determine the valuation Clause 11. 6(b) Valuation Rules Where work is of similar character to work as set out in the contract documents but is not executed under similar conditions or is executed under similar conditions but there is a significant change in the quantity of work carried out, the rates and prices in the contract documents shall be the basis for determining the valuation which shall include a fair adjustment to the rates to take into account such difference Clause 11.6 (C) Valuation Rules Where work is not of similar character to work as set out in the contract documents, the valuation shall be at fair market rates and prices determined by the quantity surveyor
63 Rules to be considered by gulp in when valuing the variation relating to the reconfiguration of the bedrooms: 1. Re-measure the site on the variation work 2. Establish nature of work: i. Works of similar character and executed under similar conditions and does not significantly change quantity of work ii. iii. Works of similar character to work set out in contract documents but not executed under similar conditions OR works of similar character to work set out in the contract document, executed under same conditions but there is a significant change in the quantity of work involved Work is not of similar character to work set out in contract document 3. Value variations according to the valuation rules of the nature of work. i. Rates and prices in contract documents shall determine valuation ii. iii. Rates and prices in contract documents shall be the basis for determining the valuation; including fair adjustment in the rates to take into account such difference Fair market rates and prices determined by the quantity surveyor
64 QUESTION 15 YOU HAVE BEEN REQUESTED BY JOLLY TO ASSIST IN DRAFTING THE LETTER OF ACCEPTANCE. ON THE ASSUMPTION THAT THE CONTRACT FORM IS THE AGREEMENT AND CONDITIONS OF PAM CONTRACT WITH QUANTITIES), PREPARE A DRAFT LETTER OF AWARD TO BE ISSUED BY PICASSO AND PRESENT IT TO THE CLASS
65 *** REFER TO ATTACHMENT***../DOWNLOADS/QUESTION 15- REVISED LOA.PDF
66 QUESTION 16 (A) OUTLINE THE PROCEDURE THAT JAZZ AND CAN-DO MUST COMPLY WITH WHEN DEALING WITH THE CLAIM FOR ADDITIONAL PAYMENT ARISING FROM THE COLLAPSED TEMPORARY WORKS
67 CLAUSE 20.1 FIDIC Procedure for Can-Do ( contractor) 1. Contractor shall give notice within 28 days after the date on which the contractor become aware, or should have become aware of the relevant event or circumstances 2. *After 28 days, the contractor is deemed to have waived his rights to: i. Claim for extension of time ii. iii. Additional payment And employer is discharged from all liability connected with the claim. 3. Supporting particulars should be provided by the contractor and the contractor should also maintain such contemporary records as may be needed to substantiate claims. 4. Contractor to allow inspection of records and if requested, submit copies. 5. A claim with continuing effects, contractor should submit an interim claim at intervals as required by engineer
68 *Case law Supported by case of Bremer Handelgesellschaft Mbh V Vanden Avenne Izegem Nv, House Of Lords held that provisions should be construed as a condition precedent, and so would be binding if: It states the precise time within which the notice is to be served, and It makes plain by express language that unless the notice is served within that time, the party making the claim will lose its rights under the clause.
69 Procedure For Jazz (Engineer/Contract Administrator) 1. Engineer may monitor record-keeping and instruct for further records if necessary 2. Engineer has 42 days from receipt of fully detailed claim to respond his approval, disapproval or detailed comments. 3. Engineer may also request further particulars. 4. No time limit for making decision, but must not unreasonably withheld or delayed However, in this case, there was an absence of agreement of extension of time because Employer has instructed for the sub-clauses to be omitted from the Contract. Hence, the Engineer will determine a fair extension while considering; i. Causes of delay, ii. iii. Effect of a review of any previous determinations of time extension which may result in in an increase, but not decrease in total time of extension Notifies contractor
70 16 (B) IF THE CONTRACT FORM IS THE AGREEMENT AND CONDITIONS OF PAM CONTRACT 2006 (WITH QUANTITIES) HOW WILL YOU ADVICE PICASSO AND CAN-DO ON THE CLAIM FOR LOSS AND EXPENSE?
71 1. Clause 24.1 Loss And/Or Expense Caused By Matters Affecting The Regular Progress Of The Works i (A) ii (B) 2. Clause 24.3 (a-n) Matters Materially Affecting The Regular Progress Of The Works
72 ADVICE FOR CAN-DO If Can-do (contractor) expects that the regular progress of works is likely to be materially affected by matters expressly referred in clause 24.3, and he is likely to incur loss and/expense which cannot be reimbursed by payment made under other provisions in the contract he may make a claim for such loss and/or expense The Contractor has to submit written notice to architect (Picasso) on his intention to claim for loss and/or expense with initial estimate of his claims, duly supported by documents Notice shall be given within 28 (days) from date of AI, CAI or start of occurrence of matters stated in clause 24.3 Within 28 (days) after matters referred to in clause 24.3 have ended, Contractor shall send to the Architect and Quantity Surveyor complete particulars of his claims for loss and/or expense together with all the necessary calculations to substantiate his claims If contractor fails to do (4) within the stated time or within periods as agreed in writing by Architect, it is deemed that he has waived his rights for loss and/or expense
73 ADVICE FOR PICASSO 1. Architect must ensure that Contractor submitted his notice of intention to claim in writing 2. Architect must ensure the notice is submitted within 28 (days) upon the occurrence of matters in 24.3 and date of the AI and CAI 3. Architect must ensure the Contractor submits the complete particulars of his claim for loss and/or expense together will all necessary calculations to substantiate his claims within time stated or agreed period in writing by architect 4. Architect must assess if the matters claimed by the Contractor is expressed in clause 24. 3
CONTINUING PROFESSIONAL DEVELOPMENT 2013
CONTINUING PROFESSIONAL DEVELOPMENT 2013 Certificates and Certifications by Architects under the PAM Form of Building Contract 2006 Prepared by Ar Mohd Zulhemlee An CERTIFICATES The need for Certificates:
More informationConditions of Contract for PLANT and Design-Build
Conditions of Contract for PLANT and Design-Build FOR ELECTRICAL AND MECHANICAL WORKS AND FOR BUILDING AND ENGINEERING WORKS DESIGNED BY THE CONTRACTOR General Conditions 1st Edition 1999 FEDERATION INTERNATIONALE
More informationFIDIC CONTRACTS A COMPARATIVE. Uttam Sengupta Sr. GM Contracts & Risk Management
FIDIC CONTRACTS A COMPARATIVE Uttam Sengupta Sr. GM Contracts & Risk Management FIDIC AND INTRODUCTION TO FIDIC CONDITIONS OF CONTRACT 2 OUTLINE What is FIDIC? Characteristics of FIDIC Conditions of Contract
More informationSession 3 by Zoltán Záhonyi, FIDIC AIT,
Session 3 by Zoltán Záhonyi, FIDIC AIT, zoltan.zahonyi@zandpartners.com Contents of Session 3 Session 3: FIDIC 1999 Red Book Part 2 The Quality Issues (Plant, Materials and Workmanship) The Time is of
More informationAppendix K Model Letters for Use by the Engineer
175 Model Letters for Use by the Engineer Introduction This Appendix provides model letters for use by the Engineer primarily for formal correspondence with the Contractor. These model letters do not distinguish
More informationSuspension and Termination
Suspension and Termination Nicholas Gould Partner, Fenwick Elliott LLP Visiting Professor, King s College London Termination Typical contract provisions (dual notices) Suspension The grounds for suspension
More information1.5 Priority of Documents
FIDIC Construction Contract MDB Harmonised Edition Version June 2010 Changes to the March 2006 Version 1.1.3.1 Base Date means the date 28 days prior to the latest date for submission and completion of
More information2 THE EMPLOYER Provision of Site 2.2 Permits and Licenses 2.3 Employer s Instructions 2.4 Approvals
GENERAL CONDITIONS 1 GENERAL PROVISIONS.................................... 1 1.1 Definitions The Contract Persons Dates, Times and Periods Money and Payments Other Definitions 1.2 Interpretation 1.3 Priority
More informationForm of Agreement Between the Client And the Quantity Surveyor
Form of Agreement Between the Client And the Quantity Surveyor Second ACQS Edition (May 2009) Contents Agreement 1 Terms of Appointment 1. Quantity Surveyor's obligations 2 2. Client's obligations 2 3.
More informationSECTION 2 : JURONG HEALTH SERVICES PTE LTD STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WORKS
SECTION 2 : JURONG HEALTH SERVICES PTE LTD STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WORKS 1. DEFINITIONS AND INTERPRETATION 1.1 Definitions In this Contract (as hereinafter defined)
More informationBIDP Standard FORMS & JBCC Minor WORKS Commentary. ARCPE SEMINAR compiled BY FRED PHIRI Arch.BW th NOVEMBER 2017
BIDP Standard FORMS & JBCC Minor WORKS Commentary ARCPE SEMINAR compiled BY FRED PHIRI Arch.BW 01160007 04 th NOVEMBER 2017 Types of Contract Fixed Price Contracts For Specified work for a sum not adjustable
More informationConstruction Management Approach based on FIDIC Conditions of Contract for Construction, st Edition. Dr. Munther M.
Construction Management Approach based on FIDIC Conditions of Contract for Construction, 1999 1st Edition Dr. Munther M. Saket March 2015 1 Traditional Construction Contracts Owner of a construction project
More informationAH: STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WOPKS SCC.1
COMPLIANCE TO CONDITIONS OF CONTRACT - SCC.1(Renovation) Please indicate clearly below your compliance to each clause of the Conditions of Contract. Where you are not in agreement, you should give your
More informationAGREEMENT AND CONDITIONS OF SUB-CONTRACT (DOMESTIC)
AGREEMENT AND CONDITIONS OF SUB-CONTRACT (DOMESTIC) FOR USE IN CONJUNCTION WITH THE FORMS OF MAIN CONTRACT FOR PUBLIC WORKS ISSUED BY THE OFFICE OF GOVERNMENT PROCUREMENT, DEPARTMENT OF PUBLIC EXPENDITURE
More information(1) In these sub-contract conditions of agreement, the following words and phrases shall have the following meanings:-
Anti-Bribery & Corruption Policy of Intent STONBURY LIMITED TERMS AND CONDITIONS FOR SUBCONTRACTORS 1. INTERPRETATION (1) In these sub-contract conditions of agreement, the following words and phrases
More informationAIRPORT AUTHORITY HONG KONG
AIRPORT AUTHORITY HONG KONG GENERAL CONDITIONS OF CONTRACT BUILDING AND CIVIL WORKS ISSUE NO. 10 August 2011 [this page not used] GENERAL CONDITIONS OF CONTRACT FOR BUILDING AND CIVIL WORKS TABLE OF CONTENTS
More informationDOUKPSC04 Rev Feb 2013
DOUKPSC04 Purchasing Standard conditions for the Purchase of Consultancy Services 1 DEFINITIONS In the Contract (as hereinafter defined) the following words and expressions shall have the meanings hereby
More informationThe Standard Form of Minor Works Building Contract Edition. Issued by
The Standard Form of Minor Works Building Contract 2017 Edition Issued by First published: 2017 Published by: Kuala Lumpur Regional Centre of Arbitration Banguan Sulaiman, Jalan Sultan Hishamuddin, 50000
More informationThe New NZS 3910:2013
The New NZS 3910:2013 Introduction On the 1 st of October 2013, NZS 3910:2013 Conditions of Contract for Building and Civil Engineering Construction was released by New Zealand Standards. This is the first
More informationMDB Harmonised Particular Conditions
FIDIC Plant and Design-Build Contract MDB Harmonised Particular Conditions 1. Introduction There is a need for FIDIC to provide sample Particular Conditions that render the General Conditions of the 1st
More informationNPO General Terms and Conditions for Service Contracts 2014
NPO General Terms and Conditions for Service Contracts 2014 I GENERAL 1 Definitions The following terms are written with initial capitals in these general terms and conditions and are defined as follows:
More informationDRAWINGS AND DESCRIPTIONS GENERAL CONDITIONS CONCLUSION OF THE CONTRACT, MINIMUM ORDER VALUE & PURCHASE ORDER CHANGES/CANCELLATION DEFINITIONS
GENERAL CONDITIONS PREAMBLE 1. The General Conditions, which can also be found on the Supplier s website www.cet-power.com, shall apply to all offers, Purchase Orders, invoices and other documents produced
More informationStandard Form Project Agreement (hub DBFM Projects)
Standard Form Project Agreement (hub DBFM Projects) Version 2: June 20122.1: October 2013 . THIS STANDARD FORM PROJECT AGREEMENT MUST BE USED IN CONJUNCTION WITH THE STANDARD PROJECT AGREEMENTS USER S
More informationGENERAL PURCHASE CONDITIONS. entered into as defined in 1751 subpar. 1, Act No. 89/2012 Coll., Civil Code, as amended (the Civil Code" hereinafter)
GENERAL PURCHASE CONDITIONS entered into as defined in 1751 subpar. 1, Act No. 89/2012 Coll., Civil Code, as amended (the Civil Code" hereinafter) of trading company Parker Hannifin Europe Sàrl, Luxembourg,
More information1 In these Domestic Sub-Contract Conditions the following expressions and terms shall have the meanings given below:
DOMESTIC SUB-CONTRACT CONDITIONS These are the Domestic Sub-Contract Conditions referred to by the Articles of Agreement to which they are attached. In the event that these Domestic Sub-Contract Conditions
More informationINTRODUCTORY NOTE ORGALIME GENERAL CONDITIONS FOR MAINTENANCE - M Scope of use. No guarantee as to results. Contents of the individual contract
INTRODUCTORY NOTE ORGALIME GENERAL CONDITIONS FOR MAINTENANCE - M 2000 Scope of use The General Conditions for Maintenance are intended to be used where one company. the Customer, employs another company,
More information2 CONTRACT 3 SPECIFIC ITEMS INCLUDED AND EXCLUDED FROM QUOTE. Balclutha. Cromwell
TERMS OF TRADE 1 DEFINITIONS (a) Quote means the quotation provided by Balcrom for the supply of Products. (b) Products means all goods and materials provided by Balcrom to the Customer under the Contract.
More informationComparison between the Red Book 1999 and the MDB Harmonised Edition 2010
Comparison between the Red Book 1999 and the MDB Harmonised Edition 2010 Please note that this comparison is for guidance only and does not purport to be complete and exhaustive. All corrections and improvements
More informationAGREEMENT AND SCHEDULE OF CONDITIONS OF BUILDING SUB-CONTRACT (with Quantities)
FOR USE WHERE THE SUB-CONTRACTOR IS NOMINATED UNDER SUB-CLAUSE 31.2 OF THE NATIONAL CONSTRUCTION COUNCIL AGREEMENT AND SCHEDULE OF CONDITIONS OF BUILDING CONTRACT (WITH QUANTITIES), 2000 EDITION NATIONAL
More informationCHAPTER 1 25 INTRODUCTION
CHAPTER 1 25 INTRODUCTION 1.1 Introduction Construction project is unique production due to its natural condition, which is produced by the contractor for the owner/client/employer within specified time
More informationInsert heading depending. Insert heading depending on line on line length; please delete cover options once
Insert Insert heading depending Insert heading depending on line on line length; please delete on NHS on line length; line Standard length; please Contract please delete delete other other cover cover
More informationWhereas the Contractor has entered into an agreement (the "Prime Contract") dated the, 20 with:
SUBCONTRACT Job AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR This subcontract agreement (the "Agreement") made on this day of, 20. between: Aim Waste Management Inc. 400 Jones Road Stoney Creek, ON L8E
More informationGeneral Conditions for Purchase (CG-2)
Page: 2 of 5 1 Definitions - CLIENT means the party placing an order, being the legal entity as mentioned in the Purchase Order, as well as his legal successors in title; - VENDOR means the party who delivers
More informationGENERAL TERMS AND CONDITIONS. Researchpark Haasrode, Romeinsestraat 10, 3001 Heverlee, Belgium VAT (BE) RLP Leuven
GENERAL TERMS AND CONDITIONS Researchpark Haasrode, Romeinsestraat 10, 3001 Heverlee, Belgium VAT (BE) 0840.120.364 RLP Leuven 1. SCOPE OF APPLICATION 1.1 Notwithstanding any communications to the contrary
More informationSECTION 3 GENERAL CONDITIONS OF CONTRACT FOR CONSULTANCY SERVICES
SECTION 3 GENERAL CONDITIONS OF CONTRACT FOR CONSULTANCY SERVICES CONSULTANCY SERVICES. Page 3 / 1 TABLE OF CONTENTS CLAUSE DESCRIPTION PAGE 1. DEFINITIONS 3/3 2. INTERPRETATION OF THE CONTRACT 3/4 3.
More informationByte Paradigm General Conditions ( Design version)
Byte Paradigm General Conditions ( Design version) Article I General 1. When these General Conditions for Delivery are part of tenders and agreements concerning the performance of deliveries and/or services
More informationWESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT
WESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT This Equipment Purchase Agreement ( Agreement ) is entered into this day of, 20, by and between the Western Riverside Council of Governments,
More informationGeneral Purchase Conditions of Avans University of Applied Sciences
General Purchase Conditions of Avans University of Applied Sciences page 2 of 16 Table of Contents 1 Definitions 3 2 Applicability 4 3 Quotation, Instruction and formation of the Agreement 4 4 Execution
More informationProMinent Verder B.V.
Terms & Conditions ProMinent Verder B.V. (30100444) Filed at the Chamber of Commerce on 29-01-2015 1. General 1.1 These terms and conditions use the following terms and definitions: Product: items, as
More informationTerms and Conditions
Terms and Conditions SERVICES Taking such steps as are reasonable to enable MFA to be satisfied within the limits of the professional skill and care set out in clause 2-1 that the plans and works comply
More informationCzech Republic. Contributor: Alena Bányaiová. Editor: Philip Britton
CZ Czech Republic Contributor: Alena Bányaiová Editor: Philip Britton Czech Republic General questions 769 Topics 773 1 General obligations of the employer 773 1.1 Traditional procurement 773 1.2 Design
More informationSub Contract Agreement
Sub Contract Agreement In a building project there is always a contractor. There need not be any sub-contractors However there will invariably be sub-contractors. There are two types of sub-contractors
More informationSection 8- Special Conditions of Contract
Part 4: Section 8. of Contract Section 8- of Contract The following of Contract (SCC) shall supplement the General Conditions of Contract (GCC). Whenever there is a conflict, the provisions herein shall
More informationThese Standard Terms and Conditions form a contract between the Company and the Supplier. SUPPLY OF GOODS / SERVICES QUALITY PRICE AND PAYMENT
These Standard Terms and Conditions form a contract between the Company and the Supplier. SUPPLY OF GOODS / SERVICES 1. The Supplier shall supply and deliver to the Company all the goods/services set out
More informationSTANDARD PROFESSIONAL SERVICES CONTRACT. July, 2009: Edition 3 of CIDB document 1015
STANDARD PROFESSIONAL SERVICES CONTRACT (July 2009) (Third Edition of CIDB document 1014) Construction Industry Development Board Pretoria - Head Office Tel: 012 482 7200 Fraudline: 0800 11 24 32Call Centre:
More informationNutreco General Purchase Terms and Conditions
Nutreco General Purchase Terms and Conditions Article 1 - Definitions Agreement Conditions Contract Nutreco Order Products Seller : The purchase agreement between Nutreco and the Seller : The General Purchase
More informationConditions of Contract
Conditions of Contract 1. Responsibilities of Builder and Results of Construction (a) The Builder will, subject to these Conditions and the contract work details in Schedule 3, execute and complete the
More informationSubcontract Agreement
Subcontract Agreement SA - 2009 Project: Trade: Subcontractor: SA - 2009 Number: FOREWORD A good working relationship between the Contractor and Subcontractor is critical to ensuring construction projects
More informationGeneral Conditions of Contract for the Hire of Plant With or Without an Operator
General Conditions of Contract for the Hire of Plant With or Without an Operator CC7 April 1991 (Revised September 2010) Table of Clauses 1. Definition of Terms 2. Contractor s Proper Performance of the
More informationETTORE ZANON S.p.A. GENERAL CONDITIONS OF PURCHASE
1. SCOPE ETTORE ZANON S.p.A. GENERAL CONDITIONS OF PURCHASE 1.1 These general conditions of purchase published at www.zanon.com -shall be deemed as an integral part of any order issued by Ettore Zanon
More informationCONDITIONS OF CONTRACT. The Builder must execute and complete the Works in a workmanlike manner and ensure the Works are adequately supervised.
CONDITIONS OF CONTRACT 1. RESPONSIBILITY OF BUILDER The Builder must execute and complete the Works in a workmanlike manner and ensure the Works are adequately supervised. 2. WORK PERFORMED OR MATERIALS
More informationPleece&Co LTD. Terms and Conditions +44 (0)
Pleece&Co LTD Terms and Conditions +44 (0)1273 921 772 gary@pleeceandco.com 1. APPLICABILITY OF THESE GENERAL CONDITIONS 1.1 Except as set out below, or as otherwise agreed in writing, these General Conditions,
More informationCosmos Projects - Standard Terms and Conditions of Sub-Contract
Cosmos Projects - Standard Terms and Conditions of Sub-Contract These standard terms and conditions shall apply to any Sub Contract between Cosmos Projects Limited ( CPL ) and any Sub-Contractor following
More informationLifesize, Inc. Data Processing Addendum
Last updated May 1, 2018 Lifesize, Inc. Data Processing Addendum This Lifesize, Inc. Data Processing Addendum ( Addendum ) forms part of the Terms of Service (the Agreement ) between Lifesize, Inc. ( Lifesize
More informationAGREEMENT TO DEMOLISH THE STRUCTURE, CLEAR THE SITE AND TO CONSTRUCT NEW BUILDING ON THE PLOT. THIS AGREEMENT made at... on this... day of...
AGREEMENT TO DEMOLISH THE STRUCTURE, CLEAR THE SITE AND TO CONSTRUCT NEW BUILDING ON THE PLOT THIS AGREEMENT made at... on this... day of... 2000, between A son of Shri... resident of... (hereinafter called
More informationWorks Appointment: We, on behalf of the Employer, would like to inform you that your quotation, Reference Number
6/F Dorset House, Taikoo Place, 979 King's Road, Quarry Bay, Hong Kong Project Works Order Works Order No.: Name of Contractor: Description of the works: Date: "Contractor") "Works") Address of premises:
More informationWestern Water Development Consultant Accreditation Deed
Western Water Development Consultant Accreditation Deed Western Water ABN 67 433 835 375 and Company name: ABN : February 2018 TABLE OF CONTENTS 1. DEFINITIONS AND INTERPRETATION... 1 1.1 Definitions...
More information4.4 Except for insofar as these general terms and conditions foresee
GENERAL TERMS AND CONDITIONS OF SALE AND SUPPLY OF PARTS COMPANY B.V., ALSO TRADING UNDER THE NAMES BAS PARTS AND PARTS FACTORY (2013). If necessary Parts Company B.V. will submit on first request a translation
More informationMODEL CONTRACT. Marie Curie individual fellowships
MODEL CONTRACT Marie Curie individual fellowships CONTRACT NO The [European Community] [European Atomic Energy Community] ( the Community ), represented by the Commission of the European Communities (
More informationNPO GENERAL PURCHASING CONDITIONS 2014
NPO GENERAL PURCHASING CONDITIONS 2014 I General Article 1 Definitions The following terms in these Purchasing Conditions are written with initial capitals and are defined as follows: 1.1 Schedule: a document
More informationAmendments to Core Clauses
Option Z: Additional conditions of contract Amendments to Core Clauses New z clause Core Clause Z2.1 The Core Clauses are amended, by reference to the core clause indiciated (and where relevant) as follows:
More informationConditions of Contract for Construction
Fédération Internationale des Ingénieurs-Conseils International Federation of Consulting Engineers Internationale Vereinigung Beratender Ingenieure Federación Internacional de Ingenieros Consultores Conditions
More informationAKD TIMBER TRADING PTY LTD ACN TERMS OF SALE
AKD TIMBER TRADING PTY LTD ACN 623 057 429 TERMS OF SALE 1 Definitions 1.1 In this Agreement: (1) terms defined in the Credit Application have the same meaning when used unless the context requires otherwise;
More informationStandard Contracts for the UK Offshore Oil & Gas Industry
Standard Contracts for the UK Offshore Oil & Gas Industry General Conditions of Contract (including Guidance Notes) for Supply of Major Items of Plant and Equipment Edition 2 - December 2005 General Conditions
More informationSOUTHERN RESPONSE CANTERBURY EARTHQUAKE RECONSTRUCTION PROJECT GENERAL CONDITIONS OF CONTRACT FOR HOUSING REBUILD AND REPAIRS
SOUTHERN RESPONSE CANTERBURY EARTHQUAKE RECONSTRUCTION PROJECT GENERAL CONDITIONS OF CONTRACT FOR HOUSING REBUILD AND REPAIRS TABLE OF CONTENTS Background 1 1. Introduction 1 2. Contract Works 1 3. Project
More informationGeneral Conditions for Sale and Delivery
General Conditions for Sale and Delivery Seite 1 von 3 These General Conditions for Sale and Delivery shall apply in full unless otherwise agreed in Writing. Any other conditions of the Purchaser shall
More informationCOUNTY GOVERNMENT OF NYERI BILLS OF QUANTITIES
COUNTY GOVERNMENT OF NYERI DEPARTMENT OF INFRASTRUCTURE DEVELOPMENT PROPOSED CONSTRUCTION OF GUMBA GICHAGI FOOTBRIDGE IN RUGI WARD CGN/INF/62/16-17 BILLS OF QUANTITIES ISSUED BY: COUNTY WORKS OFFICER COUNTY
More informationBIBBY FINANCIAL SERVICES STANDARD CONDITIONS FOR THE PURCHASE OF DEBTS (EDITION A/2004 SCOTLAND) INCORPORATED INTO THE AGREEMENT MADE WITH
BIBBY FINANCIAL SERVICES STANDARD CONDITIONS FOR THE PURCHASE OF DEBTS (EDITION A/2004 SCOTLAND) INCORPORATED INTO THE AGREEMENT MADE WITH 1 CONTENTS 1. Introduction... 3 2. Duration of this Agreement...
More informationARCHITECTURAL CONSULTANCY AGREEMENT TERMS AND CONDITIONS
TERMS AND CONDITIONS K20 ARCHITECTURE 325 COVENTRY STREET SOUTH MELBOURNE VICTORIA, 3205 AUSTRALIA t: +61 3 9699 4440 f: +61 3 9699 5550 e: melboffice@k20architecture.com www.k20architecture.com K2O.AU
More informationEU Data Processing Addendum
EU Data Processing Addendum This EU Data Processing Addendum ( Addendum ) is made and entered into by and between AlienVault, Inc., a Delaware corporation ( AlienVault ) and the customer specified in the
More informationKENYA SAFARI LODGES AND HOTELS LIMITED (KSLH) TENDER DOCUMENT FOR REFURBISHMENT WORK AT MOMBASA BEACH HOTEL TENDER NO. MBH/RW/001(A)/
MOMBASA Beach Hotel NGULIA Safari Lodge VOI Safari Lodge KENYA SAFARI LODGES AND HOTELS LIMITED (KSLH) TENDER DOCUMENT FOR REFURBISHMENT WORK AT MOMBASA BEACH HOTEL TENDER NO. MBH/RW/001(A)/2017-2018 KENYA
More informationAustralian/New Zealand Standard
Water Corporation July 2012 Version AS/NZS 4911:2003 (Incorporating Amendment No. 1) AS/NZS 4911:2003 Australian/New Zealand Standard Water Corporation General conditions of contract amended from Australian
More informationUNCITRAL ARBITRATION RULES
UNCITRAL ARBITRATION RULES (as revised in 2010) Section I. Introductory rules Scope of application* Article 1 1. Where parties have agreed that disputes between them in respect of a defined legal relationship,
More informationGeneral Terms and Conditions of Sales
General Terms and Conditions of Sales ALPLA ITALIA S.r.l. Unipersonale Società soggetta all attività di direzione e coordinamento della ALPLA WERKE LEHNER GmbH & Co KG Sede legale: S.S. per Alessandria,
More informationOREGON STATE UNIVERSITY CM/GC CONTRACT. (Construction Manager/General Contractor)
OREGON STATE UNIVERSITY CM/GC CONTRACT (Construction Manager/General Contractor) THE CONTRACT IS BETWEEN: OWNER: Oregon State University And CONSTRUCTION MANAGER/ GENERAL CONTRACTOR (referred to as Contractor
More informationContracts Management and Administration (Based on FIDIC Standard)
Contracts Management and Administration (Based on FIDIC Standard) PMI, PMP, PMBOK and the PMI Registered Education Provider logo are registered marks of the Project Management Institute, Inc. INSURANCE
More informationGeneral Terms and Conditions for Purchasing
General Terms and Conditions for Purchasing 1. Applicability and Conclusion of Contract These Terms and Conditions for Purchasing apply to all business transactions with the supplier or other contractors
More informationGeneral conditions of contract for the supply of machinery and spare parts (2006)
General conditions of contract for the supply of machinery and spare parts (2006) 1. General 1.1 The contract shall be deemed to have been entered into upon receipt of supplier's written acknowledgement
More informationGeneral conditions of contract 2016 for the supply of spare parts
General conditions of contract 2016 for the supply of spare parts AMT AG, Badstrasse 34, 5312 Döttingen (Switzerland) 1 General 1.1 The contract shall be deemed to have been entered into upon receipt of
More informationPERMIT TO ENTER YOU ARE REQUIRED TO COMPLY WITH THE ENDORSEMENTS AND DETAILS SHOWN ON THIS PERMIT
PERMIT TO ENTER PERMIT NO: YOU ARE REQUIRED TO COMPLY WITH THE ENDORSEMENTS AND DETAILS SHOWN ON THIS PERMIT KIWIRAIL OFFICE DETAILS OFFICE: Area Office, KiwiRail Network, CONTACT: PHONE NO: Mob Fax PROTECTION
More informationFOR WORKS OF CIVIL ENGINEERING CONSTRUCTION
Cça -I II FEDERATION INTERNATIONALE DES INGENIEURS-CONSFILS INTERNATIONAL FEDERATION OF CONSULTING ENGINEERS INTERNATIONALE VEREINIGUNG BERATENI)ER INGENIEIJRE FEDERACION INTERNACIONAL DE INGENIEROS CONSULTORES
More informationCONTENTS. KLRCA ARBITRATION RULES (As revised in 2017) UNCITRAL ARBITRATION RULES (As revised in 2013) SCHEDULES. Part I. Part II.
CONTENTS Part I KLRCA ARBITRATION RULES (As revised in 2017) Part II UNCITRAL ARBITRATION RULES (As revised in 2013) Part III SCHEDULES Copyright of the KLRCA First edition MODEL ARBITRATION CLAUSE Any
More informationHeads of Terms of the Design Agreement for the Moscow Kazan Section of the Moscow Kazan Ekaterinburg High-Speed Railway Line
Heads of Terms of the Design Agreement for the Moscow Kazan Section of the Moscow Kazan Ekaterinburg High-Speed Railway Line October 2013 Moscow Key Information These heads of terms (the Heads of Terms)
More informationCDBG/HOME CONTRACT DOCUMENTS NEW HOUSING CONSTRUCTION
CDBG/HOME CONTRACT DOCUMENTS NEW HOUSING CONSTRUCTION 2013 CDBG/HOME HOUSING NEW CONSTRUCTION CONTRACT THIS CONSTRUCTION CONTRACT is made and entered into this day of 2013, by and between, (marital status),
More information1.1 In these General Terms and Conditions, the terms below will have the following meaning:
1 Definitions 1.1 In these General Terms and Conditions, the terms below will have the following meaning: a. Gerco: Gerco Brandpreventie B.V., which has its principal place of business at Vrouwenmantel
More informationCONDITIONS OF CONTRACT FOR QUOTATION
CONDITIONS OF CONTRACT FOR QUOTATION Version 6.0 Page 1 of 18 CONTENTS Clause Subject matter 1 Definitions and Interpretation 2 Scope of Contract 3 Delivery 4 Removal and Replacement 5 Financial Provisions
More informationSTONE INTERIORS Terms of Trade. 1 Definitions. 2 Estimate Validity and Existence of Contract. 3 Cancellations
1 Definitions 1.1 The Company means Stone Interiors Ltd 1.2 The Customer means the customer named on the Company s acknowledgement of order 1.3 The Contract means the contract for the sale of goods and/or
More informationW-5 PROCUREMENT OF CIVIL WORKS UNDER SHOPPING PROCEDURES
W-5 PROCUREMENT OF CIVIL WORKS UNDER SHOPPING PROCEDURES INVITATION FOR QUOTATIONS FOR CONSTRUCTION OF CIVIL WORKS UNDER SHOPPING PROCEDURES To Dear Sirs, Sub : INVITATION FOR QUOTATIONS FOR CONSTRUCTION
More informationIssued by the Association FME-CWM, P.O. Box 190, 2700 AD ZOETERMEER
TRANSLATION of the "Algemene verkoop- en leveringsvoorwaarden voor de technologische industrie". Only the Dutch text of these conditions is authentic. In case of ambiguities or doubts as to the meaning
More informationROYAL DUTCH SHELL PLC. Rules of the Global Employee Share Purchase Plan.
Draft 18 October, 2010 ROYAL DUTCH SHELL PLC Rules of the Global Employee Share Purchase Plan. Approved by MDC under delegated authority: 21 October 2008 Amended by Hugh Mitchell and Michael Reiff under
More informationAN ISO 9001 & ISO COMPANY TENDER DOCUMENT. NIT No.: NRO/CON/738/667 date : FOR
AN ISO 9001 & ISO 14001 COMPANY TENDER DOCUMENT NIT No.: NRO/CON/738/667 date : 12.10.2018 FOR Supply, Installation, Testing, Commissioning & Handing- over of Medical equipments (Group-7F) for Government
More informationCAVOTEC GROUP GENERAL CONDITIONS. Document reference: CGGC 2.0 (version June 6, 2016)
CAVOTEC GROUP GENERAL CONDITIONS Document reference: CGGC 2.0 (version 2.0 - June 6, 2016) PREAMBLE & DEFINITIONS 1. These General Conditions shall apply to any Offer Order for the supply of Products by
More informationThe Standard Form of Building Sub-Contract Edition
The Standard Form of Building Sub-Contract 2018 Edition Issued by After the date when Arbitration (Amendment) Act 2018 (the Act ) comes into operation, the Kuala Lumpur Regional Centre for Arbitration
More informationGENERAL CONDITIONS for the SUPPLY AND INSTALLATION OF MECHANICAL, ELECTRICAL AND ELECTRONIC PRODUCTS. Brussels, January 2014
ORGALIME SI 14 Lenntech info@lenntech.com Tel. +31-152-610-900 www.lenntech.com Fax. +31-152-616-289 GENERAL CONDITIONS for the SUPPLY AND INSTALLATION OF MECHANICAL, ELECTRICAL AND ELECTRONIC PRODUCTS
More informationSTANDARD TERMS FOR SPARE PARTS AND/OR SITE SERVICES
STANDARD TERMS FOR SPARE PARTS AND/OR SITE SERVICES Definitions Term Contract Meaning the contract formed between Client and Contractor for the supply by Contractor of the Scope of Supply. Contractor 7
More informationGeneral Terms and Conditions of Delivery and Payment
Seite 1 von 7 1. Scope These General Terms and Conditions apply to all our offers, contracts, deliveries and other services (hereinafter delivery ), including all future business relations, even if not
More informationSupply Contract Channel and Pipeline Standard Conditions Schedule 3. Version 2
Supply Contract Channel and Pipeline Standard Conditions Schedule 3 Version 2 Table of Contents 1. Diversion and Acceptance of Water 1 2. Overall Statutory Framework for Services 1 3. SunWater s Obligations
More informationAFNOR CERTIFICATION GENERAL TERMS AND CONDITIONS OF BRC AND/OR IFS CERTIFICATION
AFNOR CERTIFICATION GENERAL TERMS AND CONDITIONS OF BRC AND/OR IFS CERTIFICATION ARTICLE 1: FRAMEWORK AGREEMENT The contract governing the relations between and the entities applying for or holding a BRC
More informationFan and Ventilation Ltd, Terms & Conditions
What you need to know before you order from Fan and Ventilation Ltd... 1 Definitions 1.1 In these Conditions the following words have the following meanings: "Fan and Ventilation Ltd."- Fan and Ventilation
More informationConsultancy Services Contract
SERVICES AND RESOURCES INFRASTRUCTURE Consultancy Services Contract Based on AS 4122 2010 General Conditions of Contract for Consultants The University of Adelaide and The Consultant For Insert Project
More information