Whereas the Contractor has entered into an agreement (the "Prime Contract") dated the, 20 with:

Size: px
Start display at page:

Download "Whereas the Contractor has entered into an agreement (the "Prime Contract") dated the, 20 with:"

Transcription

1 SUBCONTRACT Job AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR This subcontract agreement (the "Agreement") made on this day of, 20. between: Aim Waste Management Inc. 400 Jones Road Stoney Creek, ON L8E 5P4 ( the "Contractor") and: (the "Subcontractor") Whereas the Contractor has entered into an agreement (the "Prime Contract") dated the, 20 with: day of for the construction of: (the "Owner") (the "Project") Whereas the Prime Contract includes the work (the "Subcontract Work") to be performed under the Agreement in accordance with the instructions of and documents of and for: (the "Consultant") THE PARTIES AGREE as follows: ARTICLE 1 - WORK TO BE PERFORMED 1.1 The Subcontractor shall supply all material, labour, tools and equipment necessary for the proper performance of the Subcontract Work as set out in Schedule "B". Page 1

2 1.2 The Subcontractor shall perform the Subcontract Work in accordance with and, in case of conflict, in the following order of precedence (highest to lowest): a) the Agreement; b) all contract documents (the "Contract Documents") comprising and set out in the Prime Contract, plus, if not part of the Contract Documents, the instructions to bidders, general conditions, and supplementary general conditions for the Prime Contract; and c) if not already included in the Contract Documents, the plans, specifications and addenda prepared by and for the Consultant and the Contractor. All of these documents shall be referred to as the Specifications. The Specifications include, without limitation, those documents set out in Schedule "A". ARTICLE 2 - SCHEDULE 2.1 The Subcontractor will perform the Subcontract Work: a) In accordance with a schedule provided by the Contractor at the time of signing the Agreement; or b) If no schedule is provided by the Contractor then starting on or about, and substantially completing the Subcontract Work by ; 2.2 The Contractor may, for any reason, reasonably adjust or impose any schedule or specified timing during the course of the Project after consulting with the Subcontractor. If the Subcontractor is not able to meet the schedule, the Contractor may subcontract to others to perform a portion of the Subcontract Work; the Subcontract Price shall be reduced by the Contractor's cost in doing so. 2.3 If the Subcontractor does not perform the Subcontract Work in accordance with the Contractor's schedule, regardless whether the Contractor subsequently extends the schedule, the Subcontractor shall be liable to the Contractor for all costs that the Contractor incurs due to the delay. These costs include, without limitation, liquidated or other damages to the Owner arising out of the Prime Contract. If more than one subcontractor of the Contractor at the Project causes the delay, the Contractor, acting reasonably, shall calculate the Subcontractor's proportionate share of the delay and the costs and the Subcontractor shall be liable for the proportion so calculated. 2.4 In case of delay caused by circumstances beyond the control of the Contractor, it may suspend the Subcontractor's performance of the Agreement in whole or in part. The Contractor may then call upon the Subcontractor to resume performance at any subsequent time and the Subcontractor shall do so and execute the balance of its obligations. The Contractor shall not be liable to the Subcontractor for any damages or costs that the Subcontractor suffers or incurs because of the suspension or resulting delay. However, the time to complete the Subcontract Work shall be extended by the period during which it was inactive due to the suspension of Subcontract Work or by whatever lesser time as would be reasonable in the circumstances. ARTICLE 3 - SUBCONTRACT PRICE 3.1 The Subcontract Price is the sum of: and 00/100 Dollars ($ ) in Canadian funds plus applicable GST and HST. The Subcontract Price includes all other taxes, customs duties, patent fees and other applicable charges or fees in effect at the time of the execution of the Subcontract. Page 2

3 ARTICLE 4 PAYMENT 4.1 The Contractor shall make progress payments to the Subcontractor on account of the Subcontract Price. The Contractor need not make a progress payment under any of the following circumstances: a) until the Consultant/Owner, as the case may be, has certified that the Subcontractor has completed the portion of the Subcontract Work claimed in the progress application; b) if any person doing a portion of the Subcontract Work and claiming through or under the Subcontractor (a "Subsub"), has encumbered the Project by way of a lien. The Contractor need not make the payment for as long as the Project is so encumbered or any security posted by the Contractor to vacate the lien is still outstanding; c) if a Subsub has notified the Contractor that the Subsub is claiming against the Contractor for monies the Subcontractor owes for the Subsub's work on the Project. The Contractor may hold back the amount of the claim for as long as the claim is still outstanding; d) until the Subcontractor has delivered an executed copy of the Agreement to the Contractor; and e) until the Subcontractor has delivered proof that it has complied with the insurance provisions of article 10. Use if cannot get schedule of values completed before contract signed 4.2 The Subcontractor shall submit a schedule of values of the various parts of the Subcontract Work to facilitate the evaluation of each application for payment. The schedule shall be in the format annexed as Schedule "C". The sum of the values shall be the Subcontract Price. The completed schedule shall be submitted to the Contractor as soon as possible, but prior to the first application for payment. The Contractor is under no obligation to process any application for payment until it receives and approves the schedule. 4.3 To make an effective application for payment, the Subcontractor must submit all invoices for work done in the current month, together with evidence of compliance with applicable workers compensation legislation, supporting statutory declarations, and any other documents that the Contractor requires, on or before the 25 th day of the current month. The application shall cover the value for the part of the Subcontract Work that the Subcontractor has performed up to the last day of the current month. It must be in accordance with the approved schedule of values. Use if can get the schedule of values completed before contract is signed 4.2 To facilitate the evaluation of each application for payment, a schedule of values of the various parts of the Subcontract Work is annexed as Schedule "C". The sum of the values equals the Subcontract Price. Applications for payment shall be based on the schedule of values and the Contractor is under no obligation to process any application for payment that is not based on the schedule of values. 4.3 To make an effective application for payment, the Subcontractor must submit all invoices for work done in the current month, together with evidence of compliance with applicable workers compensation legislation, supporting statutory declarations, and any other documents that the Contractor requires, on or before the 25th day of the current month. The application shall cover the value for the part of the Subcontract Work that the Subcontractor has performed up to the last day of the current month. 4.4 If the Contractor, or the Consultant/Owner, as the case may be, makes any changes to any amount in a payment application, the Contractor shall promptly notify the Subcontractor, orally or in writing, of the reasons. The Contractor shall give the Subcontractor the opportunity to defend the submission. Page 3

4 4.5 Subject to the provisions in this article 4 and applicable lien and maintenance holdbacks, the Contractor shall pay the amount owing from each payment application within 30 days of the end of the current month or 10 days after certification of the payment by the Consultant/Owner, as the case may be, whichever is later. 4.6 Subject to the provisions of this article 4 and upon the Subcontractor submitting evidence of compliance with applicable workers compensation legislation, supporting statutory declarations, and any other documents that the Contractor requires, the Contractor shall pay statutory holdback monies in accordance with applicable lien legislation, the Specifications, and the Prime Contract. 4.7 The release of statutory holdback monies shall not be due until authorised by the certificate of the Consultant/Owner, as the case may be, and are not due until the later of: a) the expiration of all rights to claim for lien arising from the performance of the Subcontract Work; b) 10 days after the issue of the certificate; and c) the number of days stipulated in the Specifications and the Prime Contract when holdback monies may be released after the issue of the certificate. 4.8 Notwithstanding any other provisions in article 4, if there are any items of the Subcontract Work that the Subcontractor has not performed, or has performed with deficiencies, the Contractor may withhold money from payments made on the Subcontract Price until the items and deficiencies are completed and rectified. The Contractor may withhold those monies that the Contractor determines are sufficient and reasonable to cover the cost of performing the items and deficiencies and to adequately protect the Contractor from claims. 4.9 Notwithstanding any other provisions of the Agreement, as a condition precedent to the Contractor s obligation to make any payment to the Subcontractor under the Agreement, the Contractor must have received a corresponding amount from the Owner that includes the amount otherwise payable to the Subcontractor. The requirement for a "corresponding amount" also applies to amounts for changes in the Subcontract Work that are changes in the work of the Prime Contract. Without limitation, a payment includes a progress, holdback, final, and maintenance payment The Contractor may set off, against any money it owes to the Subcontractor, any money that the Subcontractor owes to the Contractor or any damages, liquidated or not, for which the Subcontractor is responsible to the Contractor, whether the monies owing or the damages arise out of the Agreement or any other agreement between the parties If the Subcontractor so directs in writing, the Contractor may, but need not, pay any invoice towards the Subcontract Price earlier than otherwise due and receive a 2% discount towards the quantum of the invoice and a corresponding reduction in the Subcontract Price. An invoice for a particular month that the Contractor pays within the first 16 days of the following month qualifies for the discount. The parties must agree in advance on a case-by-case basis to any other pre-payment that would qualify for the discount. Page 4

5 ARTICLE 5 - CONTRACTOR'S RIGHT TO PERFORM THE WORK, STOP THE WORK OR TERMINATE THE SUBCONTRACT 5.1 If the Subcontractor is adjudged bankrupt, has breached the trust fund provisions of the applicable lien legislation, or makes a general assignment for the benefit of creditors or if a receiver is appointed on account of the Subcontractor's insolvency, then the Contractor may, without prejudice to any other right or remedy the Contractor may have, terminate the Agreement, by giving written notice to the Subcontractor, receiver, or trustee in bankruptcy, as the case may be. 5.2 If the Subcontractor neglects to prosecute the Subcontract Work properly or fails to perform any provisions of the Agreement, the Contractor may notify the Subcontractor in writing that the Subcontractor is in default of the Subcontractor's contractual obligations and instruct the Subcontractor to correct the default within two (2) working days of receiving the notice. 5.3 If the work or action stated in the notice as requiring correction cannot be completed within two (2) working days, the Subcontractor shall be considered to be in compliance with the Contractor's instructions if the Subcontractor commences the work or action within the specified time, provides the Contractor with a schedule for performance acceptable to the Contractor, and proceeds to perform in accordance with the schedule. 5.4 If the Subcontractor fails to comply with the provisions of sections 5.2 or 5.3, the Contractor may, without prejudice to any other right or remedy the Contractor may have, do one or both of the following: a) Correct the default and deduct its cost from the Subcontract Price and any payment then due to the Subcontractor. For purposes of this section, if the Subcontractor has abandoned its Work or has failed to comply with section 8.3, cost includes the reasonable allowance referred to in section 5.5(c), to be dealt with pursuant to section 5.5(d). b) Terminate the Subcontractor's right to continue with the Subcontract Work in whole or in part or terminate the Agreement. 5.5 If the Contractor terminates the Agreement or the Subcontractor's right to continue with the Subcontract Work under the conditions set out in sections 5.1 and 5.4, the Contractor is entitled to do any or all of the following: a) Take possession of the Subcontractor's products and use the Subcontractor's construction machinery and equipment, subject to the rights of third parties, and to finish the Subcontract Work by whatever method the Contractor deems expedient. b) Withhold any further payments to the Subcontractor until the Subcontract Work is finished. c) Charge the Subcontractor the amount by which the cost of finishing the Subcontract Work, together with a reasonable allowance, of at least 2% of the Subcontract Price, to cover the cost of any corrections required by the warranties for which the Subcontractor is liable, exceeds the unpaid balance of the Subcontract Price. If the cost of finishing the Subcontract Work is less than the unpaid balance of the Subcontract Price, the Contractor shall, subject to article 4, pay the Subcontractor the difference. Page 5

6 d) On the expiry of any warranty period that might exist, charge the Subcontractor the amount by which the cost of corrections under warranty exceeds the allowance provided for these corrections or, if the cost of the correction is less than the allowance, credit the difference to the Subcontractor. 5.6 If the Owner suspends the Prime Contract work, then the Subcontract Work shall also be suspended for the same period of time. If the Owner terminates the Prime Contract without cause, then the Contractor may terminate the Agreement without cause. If the Contractor suspends the Subcontract Work or terminates the Agreement under the provisions of section 5.6, then the only remedy of the Subcontractor is for the Contractor to compensate it for in the same manner as the Owner is to compensate the Contractor under the Prime Contract and only to the extent that the Contractor receives compensation from the Owner that encompasses the compensation due to the Subcontractor. 5.7 The preceding provisions in this article do not exclude any right to terminate that the Contractor might have at law. ARTICLE 6 - SUBCONTRACTOR'S RIGHT TO STOP THE WORK OR TERMINATE THE SUBCONTRACT 6.1 If the Contractor is adjudged bankrupt or makes a general assignment for the benefit of creditors or if a receiver is appointed on account of the Contractor's insolvency, the Subcontractor may, without prejudice to any other right or remedy the Subcontractor may have, terminate the Agreement, by giving written notice to the Contractor, receiver, or trustee in bankruptcy, as the case may be. 6.2 a) The Subcontractor may notify the Contractor in writing that the Contractor is in default of the Contractor's contractual obligations, if the Contractor fails to pay any sum due to the Subcontractor in accordance with article 4. b) This notice shall advise the Contractor that if the default is not corrected within ten (10) working days from the receipt of the written notice, the Subcontractor may ultimately terminate the Agreement. c) If the Contractor has not corrected the Contractor's default in payment in response to the Subcontractor's notice within ten (10) working days from the receipt of the notice, the Subcontractor may give the Contractor a further notice in writing to correct the default. d) If the Contractor fails to pay the Subcontractor within ten (10) working days following receipt of the further notice, the Subcontractor may terminate the Agreement. Until the Subcontractor terminates the Agreement in accordance with the notice provisions, the Subcontractor must continue performing the Subcontract Work. ARTICLE 7 - ASSIGNMENT 7.1 Neither party shall assign the Agreement or any portion of it without the written consent of the other, which consent shall not be unreasonably withheld. ARTICLE 8 - SUB-SUBCONTRACTORS AND SUPPLIERS 8.1 The Subcontractor agrees to employ only those Subsubs and supply only those materials that the Subcontractor has proposed in writing by the time the Contractor has accepted the Subcontractor's tender. The Subcontractor shall not subcontract any other aspects that are Page 6

7 included in the Subcontract Work without first obtaining the Contractor's written consent, which may not unreasonably be withheld. 8.2 The Contractor may arbitrarily order the Subcontractor to change any one or more of its Subsubs that it had previously proposed and the Contractor had agreed upon. However, the Contractor must then increase the Subcontract Price by the amount, if any, by which the price of the Contractor s choice of Subsub exceeds the price of the Subcontractor s choice of Subsub. 8.3 Within 15 days of the registration of a Subsub's claim for lien against title to the Project, the Subcontractor shall vacate the lien from title. In default, the Contractor has the right, at its option, either to vacate or to pay and discharge any such lien claim and recover from the Subcontractor all amounts and costs in doing so, including interest charges and legal, administrative, and bonding costs. 8.4 The Subcontractor is liable for the acts, omissions, and work of its Subsubs as if the acts, omissions, and work were that of the Subcontractor. ARTICLE 9 - CHANGES IN THE WORK 9.1 The Contractor, without invalidating the Agreement, may make changes by altering, adding to, or deducting from the Subcontract Work. The Subcontract Price and the schedule will be amended pursuant to the provisions set out in the Prime Contract. 9.2 The Subcontractor shall perform no work additional to the Subcontract Work and shall make no changes without a written order from the Contractor. ARTICLE 10 INSURANCE AND BONDING 10.1 The Subcontractor shall provide, maintain and pay for general liability insurance, automobile liability insurance, aircraft and watercraft liability insurance, and any other insurance specified in the Prime Contract, other than property insurance. The amounts of the insurance coverage for the Subcontractor shall be commercially reasonable, but at least as much as called for in the Prime Contract a) Unless specified otherwise in the Prime Contract, the duration of each insurance policy shall be from the date of commencement of the Subcontract Work until the date of the final certificate for payment of the Prime Contract. b) The Contractor shall be shown as an additional named insured on each policy as it affects the Project. c) The policies shall be endorsed with the insurer's undertaking to provide the Contractor with not less than thirty (30) days written notice in advance of cancellation, change, or amendment restricting coverage The Subcontractor must supply the Contractor with certificates of insurance, or the actual policy if the Contractor so requests, showing compliance with this article before the first application for payment of the Subcontract Price and upon the placement, renewal, amendment, or extension of all or any part of the insurance. Page 7

8 10.4 Either the Contractor or the Owner will arrange for and maintain property insurance in accordance with the Prime Contract. If the Subcontractor, or any of its Subsubs, causes a loss that is insured under the property insurance policy, the Subcontractor shall only be responsible to pay for any deductible amounts under the policy The Subcontractor shall be responsible for securing its own tools, equipment, and, until they have been incorporated into the Project, building materials against any eventuality, including theft and vandalism. The Contractor shall not be responsible for any loss to them, whether caused by the negligence of the Contractor or otherwise. The Subcontractor shall obtain appropriate insurance to insure this risk and the provisions of section 10.2 shall apply to it. pick one 10.6 The Subcontractor need not provide the bond(s) that the Contractor is to provide under the Prime Contract The Subcontractor shall provide a performance bond using the most current version of CCDC 221 Performance Bond. The performance bond shall be in an amount of 50% of the Subcontract Price. ARTICLE 11 - INDEMNIFICATION 11.1 In addition to the Subcontractor's duty to indemnify under the provisions of the Prime Contract incorporated by reference, the Subcontractor shall indemnify and hold harmless the Contractor and its agents and employees from and against all claims, demands, losses, costs, damages, actions, suits or proceedings (collectively, the "Claims") by third parties and the Owner that arise out of, or are attributable to, the Subcontractor's performance of the Agreement. The Claims by third parties, but not the Owner, must be: a) attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property, and b) caused by negligent acts or omissions of the Subcontractor or anyone for whose acts the Subcontractor may be liable. ARTICLE 12 - CLEAN UP 12.1 The Subcontractor shall, on a day-by-day basis, at its own expense and to the satisfaction of the Contractor, keep its work areas in a tidy condition and free from the accumulation of waste products and debris. It shall remove from the Project all waste products and debris caused by the performance of the Subcontract Work. If it fails to perform these housekeeping requirements, the Contractor has the right to have the work performed by whatever means may be expedient and the Subcontractor agrees that the Subcontract Price shall be reduced by the costs of the clean-up and removal of the waste products and debris When the Subcontractor has completed its Subcontract Work, the Subcontractor shall remove all surplus products, tools, machinery and equipment, and any waste products and debris and leave the Project in a clean and tidy condition to the Contractor's satisfaction. Until the Subcontractor has complied with this section, it shall be deemed not to have totally performed the Subcontract Work. Page 8

9 ARTICLE 13 SAFETY 13.1 In performing the Subcontract Work, the Subcontractor agrees to respect and comply with all necessary procedures and requirements (the "H&S Requirements") in accordance with the following: all applicable legislation passed by federal, provincial, and local authorities governing health and safety; the safety requirements set out in the Prime Contract; and the Contractor's safety policy, as attached to the Agreement and amended from time to time Before commencing its Subcontract Work, the Subcontractor shall: a) submit an approved "Registration of Constructors and Employers Engaged in Construction" form to the Contractor; and b) provide the Contractor with the Subcontractor s health and safety policy, not for the Contractor's approval, but rather to demonstrate that the Subcontractor has a health and safety policy The Subcontractor acknowledges that the Contractor has a zero tolerance policy for workers who do not comply with the H&S Requirements. If any of the on-site personnel of the Subcontractor, and any Subsub of that Subcontractor, breach the H&S Requirements, the Contractor will warn with a written violation notice and assess damages of $100, or more if incurred, for the infraction. The amount of $100 represents compensation for the time that the Contractor expects to spend in noting the violation and sending the violation notice. The Subcontractor agrees that the Subcontract Price shall be reduced by the damages set out above. If a person commits three infractions for which a violation notice was given, then, upon receipt of the third violation notice, the Subcontractor shall permanently eject that person from the Project site In addition to its obligations under the Prime Contract that are incorporated by reference pursuant to the Agreement, the Subcontractor shall ensure that, while any of its labourers, material suppliers, or Subsubs are working at the Project site, a foreman/superintendent employed by the Subcontractor shall also be present at the Project site to direct and oversee the Subcontract Work. The foreman/superintendent must be sufficiently fluent in the English language to be understood by the Contractor's superintendent and employees, other subcontractors on the Project, and the labourers, material suppliers, and Subsubs. ARTICLE 14 GENERAL PROVISIONS 14.1 The Agreement shall be interpreted in accordance with the law of the place of the Project. It is the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements, written or oral, including any bid or tender from the Subcontractor The Subcontractor shall be responsible for all permits, licences, and certificates necessary for the performance of the Subcontract Work The Subcontractor shall give all required notices and comply with all laws, ordinances, rules, regulations, codes, and orders of all authorities having jurisdiction that are or become in force during the performance of the Agreement and that govern the Subcontract Work The Subcontractor shall make no delivery of material or equipment at the Project site without proper packaging and without first arranging for the delivery with the Contractor s site superintendent. The Contractor may refuse to accept any delivery made or attempted to be made in contravention of this section and, upon the Contractor's direction, the Subcontractor Page 9

10 shall forthwith remove the material or equipment from the site at its own expense If the Agreement refers to costs that the Contractor has incurred for which the Subcontractor is liable, these costs shall be increased by a 10% surcharge to take into account the Contractor's profit and overhead. This surcharge is in substitution for any surcharge set out in the Contract Documents and not in addition to it Subject to the following, the terms and conditions of the Prime Contract are binding upon the Contractor and the Subcontractor for the Subcontract Work as if the Contractor were the Owner and the Subcontractor were the contractor in the Prime Contract. a) The Prime Contract terms that are incorporated by reference are subject to the provisions of the Agreement and apply only if the Agreement is silent as to any term or condition dealt with in the Prime Contract. A term or condition shall not be incorporated by reference if the term or condition: i) deals with a matter on which the Agreement is silent, but deals with the matter in such a way that it would not be in accordance with the spirit of similar matters in the Agreement; or ii) deals with a matter that relates to a duty of the Contractor in its relationship with the Owner that would be nonsensical to be attributed to the Subcontractor. b) All provisions of the Prime Contract dealing with arbitration, mediation, and dispute resolution apply to the Agreement. If the dispute between the parties is integrally tied to a similar dispute between the Contractor and the Owner, then the dispute must be resolved at the same time, and with the same mediator or arbitrator, as the dispute between the Owner and the Contractor. Any mediator chosen to be the project mediator for the Prime Contract shall be deemed the project mediator for the Agreement. c) If the Prime Contract provides for the Contractor to present to the Consultant/Owner, as the case may be, any matters for decision, the Subcontractor shall present these matters to the Contractor and, if they also apply to the Prime Contract, the Contractor shall present them on the Subcontractor's behalf to the Consultant/Owner, as the case may be. d) The Prime Contract may set out time limitations by which the Contractor must give notice to the Owner or Consultant for the notice, and rights asserted, to be effective. In each such case, for the Subcontractor's notice, and rights asserted, to be effective, the Subcontractor must give its notice to the Contractor at least two days before the date that the Contactor is required to deliver its notice to the Owner or Consultant Time is of the essence. No payment or forbearance to complain should be construed as a forbearance of a party's rights under the Agreement, without an express written agreement to that effect The Subcontractor shall conduct its affairs to ensure harmonious and stable labour relations at the Project and so as not to cause labour interference or disruption at the Project, whether or not related to the Subcontractor's Work. The Subcontractor represents that no labour agreement or lack of a labour agreement with its employees will adversely affect its ability to perform the Subcontract Work. Page 10

11 ARTICLE 15 - RECEIPT OF AND ADDRESSES FOR NOTICE 15.1 The parties shall give any notices or communications, which the Agreement requires, in writing. These notices or communications, and the Agreement itself, shall be sufficiently given by courier, fax, personal delivery, , or postage prepaid ordinary mail. The document shall be addressed to the Contractor or the Subcontractor, as the case may be, at the addresses below or to any other address as may be notified from time to time in writing by either of them to the other. The document shall be deemed to have been received on the third business day following the day of the mailing or, if sent by courier, fax, , or given personally, on the date on which it was received. The Contractor at: Aim Waste Management Inc. 400 Jones Road Stoney Creek, ON, L8E 5P4 The Subcontractor at: Phone: Phone: Fax: Fax: Contact: Contact: In Witness whereof the parties have executed the Agreement under their respective corporate seals and by the hands of their proper authorised officers. SIGNED AND SEALED Aim Waste Management Inc. Subcontractor name signature c/s signature c/s Name Manager, Division Name Title I have authority to bind the corporation I have authority to bind the corporation Page 11

12 SCHEDULE A DOCUMENTS A full list of the Prime Contract Documents will go here. Page 12

13 SCHEDULE B SCOPE OF WORK A detailed Scope of Work will go here. Site Contact Details:. Aim Waste Management Inc. Job Site Address: Office Contact: Phone: Fax: Site Superintendent: Site Phone: Fax: Cell Phone:. Subcontractor name. Address: Contact: Phone: Fax:. Page 13

14 SCHEDULE C SCHEDULE OF VALUES The following Schedule of Values will represent the payment breakdown for this subcontract. Monthly progress claims shall follow this breakdown. Item Description Unit Price Unit Total Contract Total: Page 14

BETWEEN name. address. AND name (hereinafter called the Subcontractor ) address

BETWEEN name. address. AND name (hereinafter called the Subcontractor ) address AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR CONTRACTOR S COPY SUBCONTRACT NO. Alberta Standard Construction Subcontract THIS AGREEMENT made this day of, A.D. 20 BETWEEN name (hereinafter called the

More information

Contractor for any and all liability, costs, expenses, fines, penalties, and attorney s fees resulting from its failure to perform such duties.

Contractor for any and all liability, costs, expenses, fines, penalties, and attorney s fees resulting from its failure to perform such duties. SUBCONTRACT AGREEMENT THIS SUBCONTRACT, made this day of, 20 by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter "Subcontractor") with an office

More information

SAMPLE DOCUMENT SUBCONTRACT AGREEMENT

SAMPLE DOCUMENT SUBCONTRACT AGREEMENT SUBCONTRACT AGREEMENT THIS SUBCONTRACT, made this day of by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter "Subcontractor") with an office and

More information

Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project

Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project Document A105 2007 Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project AGREEMENT made as of the in the year (In words, indicate day, month and year.) BETWEEN

More information

MASTER SUBCONTRACT AGREEMENT

MASTER SUBCONTRACT AGREEMENT MASTER SUBCONTRACT AGREEMENT This Master Subcontract Agreement ( Subcontract ), made this day of, 20 by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter

More information

Professional Services Agreement

Professional Services Agreement Professional Services Agreement Agreement No.: Project Name: File: This Agreement, made this day of in the year Two Thousand and. Between: And The Government of Saskatchewan as represented by (insert government

More information

Standard Form of Agreement Between Contractor and Subcontractor

Standard Form of Agreement Between Contractor and Subcontractor Standard Form of Agreement Between Contractor and Subcontractor GENERAL TERMS AND CONDITIONS ARTICLE 1 THE SUBCONTRACT DOCUMENTS 1.1 The Subcontract Documents consist of (1) these General Terms and Conditions,

More information

ARTICLE 1 ARTICLE 3 CONTRACTOR THE SUBCONTRACT DOCUMENTS ARTICLE 2 MUTUAL RIGHTS AND RESPONSIBILITIES

ARTICLE 1 ARTICLE 3 CONTRACTOR THE SUBCONTRACT DOCUMENTS ARTICLE 2 MUTUAL RIGHTS AND RESPONSIBILITIES ARTICLE 1 THE SUBCONTRACT DOCUMENTS 1.1 The Subcontract Documents consist of (1) this Agreement; (2) the prime Contract, consisting of the Agreement between the Owner and Contractor and the other Contract

More information

Standard Form of Agreement Between Contractor and Subcontractor

Standard Form of Agreement Between Contractor and Subcontractor Document A401 2007 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the in the year (In words, indicate day, month and year.) day of BETWEEN the Contractor: (Name, legal

More information

GENERAL CONDITIONS UNIT PRICE CONTRACT

GENERAL CONDITIONS UNIT PRICE CONTRACT GENERAL CONDITIONS OF UNIT PRICE CONTRACT INDEX GENERAL CONDITIONS OF CONTRACT SECTION PAGE 1 1 Definitions 2 2 Documents 3 3 Additional Instructions and Schedule of Work 4 3 Documents Provided 5 3 Documents

More information

stipulated price contract

stipulated price contract 2 2 stipulated price contract 2 0 0 8 Apply a CCDC 2 copyright seal here. The application of the seal demonstrates the intention of the party proposing the use of this document that it be an accurate and

More information

Document A401 TM. Standard Form of Agreement Between Contractor and Subcontractor

Document A401 TM. Standard Form of Agreement Between Contractor and Subcontractor Document A401 TM 2017 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Contractor: (Name,

More information

Document A401 TM. Standard Form of Agreement Between Contractor and Subcontractor

Document A401 TM. Standard Form of Agreement Between Contractor and Subcontractor Document A401 TM 2007 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Contractor: (Name,

More information

Document A Standard Form of Agreement Between Contractor and Subcontractor

Document A Standard Form of Agreement Between Contractor and Subcontractor Document A401 2017 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Contractor: (Name, legal

More information

AGC TEXT COPY THE ASSOCIATED GENERAL CONTRACTORS OF AMERICA AGC DOCUMENT NO. 603 STANDARD SHORT FORM AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR

AGC TEXT COPY THE ASSOCIATED GENERAL CONTRACTORS OF AMERICA AGC DOCUMENT NO. 603 STANDARD SHORT FORM AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR THE ASSOCIATED GENERAL CONTRACTORS OF AMERICA AGC DOCUMENT NO. 603 STANDARD SHORT FORM AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR (Where Contractor Assumes Risk of Owner Payment) The original text

More information

DOUKPSC04 Rev Feb 2013

DOUKPSC04 Rev Feb 2013 DOUKPSC04 Purchasing Standard conditions for the Purchase of Consultancy Services 1 DEFINITIONS In the Contract (as hereinafter defined) the following words and expressions shall have the meanings hereby

More information

Subcontract Agreement

Subcontract Agreement S THIS AGREEMENT made as of the day of, 2012 BETWEEN the Contractor: TCL Partners 5212 123 rd Place SE Everett, WA 98208 and the For the Following Project: The Architect for the Project: The Contractor

More information

STANDARD CONSTRUCTION CONTRACT. THESE ARTICLES OF AGREEMENT made in duplicate and effective the day of 2017: NEW BRUNSWICK POWER CORPORATION

STANDARD CONSTRUCTION CONTRACT. THESE ARTICLES OF AGREEMENT made in duplicate and effective the day of 2017: NEW BRUNSWICK POWER CORPORATION STANDARD CONSTRUCTION CONTRACT THESE ARTICLES OF AGREEMENT made in duplicate and effective the day of 2017: BETWEEN: NEW BRUNSWICK POWER CORPORATION (referred to herein as the Owner) AND (referred to herein

More information

4. The Division shall receive tenders at a location specified by the Secretary-Treasurer up to the time and date specified on the tender documents.

4. The Division shall receive tenders at a location specified by the Secretary-Treasurer up to the time and date specified on the tender documents. Administrative Procedure 515 FACILITIES AND MAINTENANCE TENDERING Background Golden Hills School Division believes in purchasing goods and services at competitive prices, treating suppliers fairly and

More information

HALIFAX REGIONAL MUNICIPALITY SECTION GENERAL CONDITIONS PAGE 1 OF THE CIVIL WORKS CONTRACT JANUARY 2018

HALIFAX REGIONAL MUNICIPALITY SECTION GENERAL CONDITIONS PAGE 1 OF THE CIVIL WORKS CONTRACT JANUARY 2018 GENERAL CONDITIONS PAGE 1 Delete Section 00 72 45 of the Standard Specifications for Municipal Services, as developed and published by the Nova Scotia Road Builders Association and the Consulting Engineers

More information

MANITOBA HOUSING SUPPLEMENTAL CONDITIONS CONTRACT #: XXXX GENERAL

MANITOBA HOUSING SUPPLEMENTAL CONDITIONS CONTRACT #: XXXX GENERAL GENERAL 1. Stipulated Price Contract CCDC2-2008 2. CCDC2-2008 Supplemental Conditions The Construction Contract for this project is the standard Construction Document- CCDC2 2008, Stipulated Price Contract.

More information

SUBCONTRACT (SHORT FORM)

SUBCONTRACT (SHORT FORM) SUBCONTRACTOR: PHONE SUBCONTRACT (SHORT FORM) PROJECT: LOCATION: This agreement is made and effective, by and between SUN CONSTRUCTION & FACILITY SERVICES, INC. (Contractor) and (Subcontractor) which are

More information

STANDARD SUBCONTRACT AGREEMENT FOR BUILDING CONSTRUCTION

STANDARD SUBCONTRACT AGREEMENT FOR BUILDING CONSTRUCTION STANDARD SUBCONTRACT AGREEMENT FOR BUILDING CONSTRUCTION THIS AGREEMENT made at Columbus, Ohio on by and between Lincoln Construction, Inc., hereinafter referred to as the Contractor, and, hereinafter

More information

Document A401. Standard Form of Agreement Between Contractor and Subcontractor

Document A401. Standard Form of Agreement Between Contractor and Subcontractor TM Document A401 1997 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year) BETWEEN the Contractor: (Name,

More information

Amount of Contract work per the plans and specifications for project. Specifications Attached. Plans Attached

Amount of Contract work per the plans and specifications for project. Specifications Attached. Plans Attached Sample Company 2005 XXXX Main St Anywhere CA 99999 800 555-5555 SUBCONTRACT Contract#: 921 Contract Date: 08/20/2008 SUBCONTRACTOR: Baxter Heating & Cooling 4320 Eucalyptus Way Santa Rosa CA 95401 PROJECT:

More information

SUBCONTRACTOR AGREEMENT

SUBCONTRACTOR AGREEMENT SUBCONTRACTOR AGREEMENT THIS AGREEMENT MADE THIS DAY OF IN THE YEAR OF 2016 (In words, indicate day, month and year) BETWEEN DeWitt & Associates, Inc. 1256 South Barnes Springfield, Missouri 65804 AND:

More information

Town of Whitby Terms and Conditions

Town of Whitby Terms and Conditions Town of Whitby Terms and Conditions Part B - Standard Terms and Conditions 1. Definitions Town - The Corporation of the Town of Whitby, its successors and assigns. Bidder - The person, firm or corporation

More information

PROFESSIONAL SERVICES AGREEMENT. For On-Call Services WITNESSETH:

PROFESSIONAL SERVICES AGREEMENT. For On-Call Services WITNESSETH: PROFESSIONAL SERVICES AGREEMENT For On-Call Services THIS AGREEMENT is made and entered into this ENTER DAY of ENTER MONTH, ENTER YEAR, in the City of Pleasanton, County of Alameda, State of California,

More information

WESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT

WESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT WESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT This Equipment Purchase Agreement ( Agreement ) is entered into this day of, 20, by and between the Western Riverside Council of Governments,

More information

SHORT FORM STANDARD SUBCONTRACT. This Agreement is made this day of, 20, between

SHORT FORM STANDARD SUBCONTRACT. This Agreement is made this day of, 20, between SHORT FORM STANDARD SUBCONTRACT This Agreement is made this day of, 20, between (Contractor) and (Subcontractor). The work described in Section I below shall be performed in accordance with the prime contract

More information

FIRM FIXED PRICE TERMS AND CONDITIONS AES-1 Applicable to Architect-Engineering Services Contracts INDEX CLAUSE NUMBER TITLE PAGE

FIRM FIXED PRICE TERMS AND CONDITIONS AES-1 Applicable to Architect-Engineering Services Contracts INDEX CLAUSE NUMBER TITLE PAGE Applicable to Architect-Engineering Services Contracts INDEX CLAUSE NUMBER TITLE PAGE 1. DEFINITIONS 1 2. COMPOSITION OF THE ARCHITECT-ENGINEER 1 3. INDEPENDENT CONTRACTOR 1 4. RESPONSIBILITY OF THE ARCHETECT-ENGINEER

More information

ANNEX A Standard Special Conditions For The Salvation Army

ANNEX A Standard Special Conditions For The Salvation Army ANNEX A Standard Special Conditions For The Salvation Army TO BE ATTACHED TO AIA B101-2007 EDITION ABBREVIATED STANDARD FORM OF AGREEMENT BETWEEN OWNER AND ARCHITECT 1. Contract Documents. This Annex supplements,

More information

MASTER SUBCONTRACT AGREEMENT

MASTER SUBCONTRACT AGREEMENT Back s Construction, Inc. 1602 Front Street, Suite 100 San Diego, CA 92101 Phone: 619-713-2566 Fax: 619-713-0992 MASTER SUBCONTRACT AGREEMENT This subcontract made and entered into this Monday, January

More information

Document A Standard Abbreviated Form of Agreement Between Owner and Contractor

Document A Standard Abbreviated Form of Agreement Between Owner and Contractor Document A104 2017 Standard Abbreviated Form of Agreement Between Owner and Contractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Owner: (Name, legal

More information

ConsensusDocs 751 STANDARD SHORT FORM AGREEMENT BETWEEN CONSTRUCTOR AND SUBCONTRACTOR

ConsensusDocs 751 STANDARD SHORT FORM AGREEMENT BETWEEN CONSTRUCTOR AND SUBCONTRACTOR ConsensusDocs 751 STANDARD SHORT FORM AGREEMENT BETWEEN CONSTRUCTOR AND SUBCONTRACTOR Job No. [ ] Subcontract No. [ ] This Agreement is made this [ ] day of [ ], [ ], by and between CONSTRUCTOR, L&L Builders

More information

GENERAL: WITNESSETH: That the said Contractor and the said District, for consideration hereinafter named agree as follows: DESCRIPTION OF WORK:

GENERAL: WITNESSETH: That the said Contractor and the said District, for consideration hereinafter named agree as follows: DESCRIPTION OF WORK: GENERAL: This Contract made and entered into this day of, 2013, by and between the Sundown Sanitary Sewer District, hereinafter called "District", and, hereinafter called "Contractor", duly authorized

More information

City means the municipal corporation, generally known as the City of Richmond.

City means the municipal corporation, generally known as the City of Richmond. General Conditions of Contract for General Construction Services on City of Richmond Property 1.0 Definitions The following words and terms, unless the context otherwise requires, shall have the meanings

More information

Stipulated Price. Subcontract. Subcontract No:

Stipulated Price. Subcontract. Subcontract No: Stipulated Price Subcontract Project: xxxxxxx Subcontract Work: xxxxxx Subcontractor: xxxxxxx Subcontract No: xxxxxxx TABLE OF CONTENTS AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR Article 1 Work to

More information

CONSTRUCTION CONTRACT EXAMPLE

CONSTRUCTION CONTRACT EXAMPLE P a g e 1 CONSTRUCTION CONTRACT EXAMPLE THIS AGREEMENT, made and entered into this date, by and between, hereinafter called CONTRACTOR, and NPC QUALITY BURGER, INC., hereinafter called OWNER. IT IS HEREBY

More information

C R D A Capital Region Development Authority

C R D A Capital Region Development Authority C R D A Capital Region Development Authority 100 Columbus Boulevard Suite 500 Hartford, CT 06103-2819 Tel (860) 527-0100 Fax (860) 527-0133 www.crdact.net September 26, 2018 Addendum #3 Regional Market

More information

PART INSTRUCTIONS TO BIDDERS

PART INSTRUCTIONS TO BIDDERS [ ] [ ] [ ] Date [Date] [ ] [] PART 1 - INSTRUCTIONS TO BIDDERS CLAUSE 1 - DOCUMENTS 1 DOCUMENTS Carefully examine the following information. Failure to follow these instructions may result in bid disqualification.

More information

1.1 The Canadian standard Construction Document CCDC 2, 2008 for Stipulated Price Contract, English version hereby forms the basis of this Contract.

1.1 The Canadian standard Construction Document CCDC 2, 2008 for Stipulated Price Contract, English version hereby forms the basis of this Contract. 1 General 1.1 The Canadian standard Construction Document CCDC 2, 2008 for Stipulated Price Contract, English version hereby forms the basis of this Contract. 1.2 The following amendments, additions and

More information

PURCHASING TERMS AND CONDITIONS DOMESTIC FLEET

PURCHASING TERMS AND CONDITIONS DOMESTIC FLEET PURCHASING TERMS AND CONDITIONS DOMESTIC FLEET GENERAL Agreement means, collectively, these terms and conditions and the Order to which they apply. CSL means The CSL Group Inc., acting through its Canada

More information

SUBCONTRACT FOR BUILDING CONSTRUCTION

SUBCONTRACT FOR BUILDING CONSTRUCTION SUBCONTRACT FOR BUILDING CONSTRUCTION TABLE OF ARTICLES 1. AGREEMENT 2. SCOPE OF WORK 3. SCHEDULE OF WORK 4. CONTRACT PRICE 5. PAYMENT 6. CHANGES, CLAIMS AND DELAYS 7. CONTRACTOR'S OBLIGATIONS 8. SUBCONTRACTOR'S

More information

AGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER PRE-CONSTRUCTION AND CONSTRUCTION SERVICES

AGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER PRE-CONSTRUCTION AND CONSTRUCTION SERVICES AGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER PRE-CONSTRUCTION AND CONSTRUCTION SERVICES AGREEMENT made by and between, hereinafter called the Owner, and SITESCOMMERCIAL, LLC 185 WIND CHIME COURT, SUITE

More information

CS ENERGY LIMITED SERVICE CONDITIONS

CS ENERGY LIMITED SERVICE CONDITIONS CS ENERGY LIMITED SERVICE CONDITIONS 1. DEFINITIONS In these Conditions: Agreement means the agreement between CS Energy and the Contractor for the provision of Services and comprises the relevant Service

More information

203(K) STANDARD OWNER/CONTRACTOR AGREEMENT

203(K) STANDARD OWNER/CONTRACTOR AGREEMENT 203(K) STANDARD OWNER/CONTRACTOR AGREEMENT Loan Number: : Provided By: Primary Borrower: CARRINGTON MORTGAGE SERVICES, LLC Property Address: Homeowner (s) ( Homeowner and/or Borrower ) FHA Case #: Address:

More information

POST BID ADDENDUM. Project: LDS Eastview, Mesa, Iona 10 HVAC Project No.: Addendum No.: 2

POST BID ADDENDUM. Project: LDS Eastview, Mesa, Iona 10 HVAC Project No.: Addendum No.: 2 POST BID ADDENDUM Project: LDS Eastview, Mesa, Iona 10 HVAC Project No.: 504-6955 Addendum No.: 2 Project Address: 2349 Virlow St., Idaho Falls, Idaho 83401 Date: 8/29/2016 Owner: Corporation of the Presiding

More information

Cooper Heat Treating LLC Terms and Conditions of Order Effective April 2, 2013

Cooper Heat Treating LLC Terms and Conditions of Order Effective April 2, 2013 1. DEFINITIONS - The terms defined in this paragraph shall have the meanings set forth below: 1.1. Customer means Cooper Heat Treating LLC. 1.2. Order means this written Purchase Order between Customer

More information

AGREEMENT BETWEEN OWNER AND SELLER

AGREEMENT BETWEEN OWNER AND SELLER AGREEMENT BETWEEN OWNER AND SELLER 11-15-2018 THIS AGREEEMENT is effective as of the day of in the year of 2018 by and between the Velasco Drainage District, a political subdivision of the State of Texas,

More information

VIRIDOR WASTE MANAGEMENT LIMITED TERMS AND CONDITIONS OF TRADE

VIRIDOR WASTE MANAGEMENT LIMITED TERMS AND CONDITIONS OF TRADE VIRIDOR WASTE MANAGEMENT LIMITED TERMS AND CONDITIONS OF TRADE The Supplier will collect/accept Waste for disposal and will supply/deliver quarried or other material subject to the conditions set out below:

More information

MASTER SUBCONTRACTOR AGREEMENT

MASTER SUBCONTRACTOR AGREEMENT MASTER SUBCONTRACTOR AGREEMENT THIS MASTER SUBCONTRACTOR AGREEMENT ("Agreement") is made this day of, 20, between, a ("Contractor"), and, a ("Subcontractor"). 1. Recitals: Contractor has entered into a

More information

WATER QUALITY MAINTENANCE-SPARKS MARINA CANAL CITY OF SPARKS, NEVADA

WATER QUALITY MAINTENANCE-SPARKS MARINA CANAL CITY OF SPARKS, NEVADA General Services Contract (Rev 3/30/09) Page 1 WATER QUALITY MAINTENANCE-SPARKS MARINA CANAL CITY OF SPARKS, NEVADA THIS CONTRACT made and entered into on this 9th day of April, 2012, by and between the

More information

SUBCONTRACT AGREEMENT PROFESSIONAL SERVICES

SUBCONTRACT AGREEMENT PROFESSIONAL SERVICES SUBCONTRACT AGREEMENT PROFESSIONAL SERVICES This Subcontract Agreement (this Agreement ) is made this day of, 20, by and between LARON INCORPORATED, an Arizona corporation ( Contractor ), and ( Subcontractor

More information

Drexel University Independent Contractor Service Provider Agreement. Name: [ ] Limited Liability Company [ ] Professional Corporation

Drexel University Independent Contractor Service Provider Agreement. Name: [ ] Limited Liability Company [ ] Professional Corporation This is a form agreement for discussion purposes only. It does not constitute a binding offer or contract of Drexel University until all of the terms have been approved and this agreement is executed by

More information

CITY OF PORT ORCHARD PROFESSIONAL SERVICES AGREEMENT

CITY OF PORT ORCHARD PROFESSIONAL SERVICES AGREEMENT CITY OF PORT ORCHARD PROFESSIONAL SERVICES AGREEMENT THIS Agreement is made effective as of the day of 201_, by and between the City of Port Orchard, a municipal corporation, organized under the laws of

More information

SUBCONTRACT. by and between. to perform the Work identified in Article 2 in accordance with the Projects Contract documents.

SUBCONTRACT. by and between. to perform the Work identified in Article 2 in accordance with the Projects Contract documents. Phone 800 555-5555 Fax 999 555-5551 TO: 4320 Eucalyptus Way Santa Rosa CA 95401 SUBCONTRACT PROJECT: 186 Williams Post Office 19420 Williams Rd. Monte Rio CA 95462 This agreement entered into this day

More information

APPENDIX 3 - CONTRACT AGREEMENT BETWEEN OWNER AND CONTRACTOR

APPENDIX 3 - CONTRACT AGREEMENT BETWEEN OWNER AND CONTRACTOR APPENDIX 3 - CONTRACT AGREEMENT BETWEEN OWNER AND CONTRACTOR THIS AGREEMENT made this day of, 201* BETWEEN: (the "Owner") AND (the "Contractor") In consideration of the mutual covenants and agreements

More information

CONDITIONS OF CONTRACT. The Builder must execute and complete the Works in a workmanlike manner and ensure the Works are adequately supervised.

CONDITIONS OF CONTRACT. The Builder must execute and complete the Works in a workmanlike manner and ensure the Works are adequately supervised. CONDITIONS OF CONTRACT 1. RESPONSIBILITY OF BUILDER The Builder must execute and complete the Works in a workmanlike manner and ensure the Works are adequately supervised. 2. WORK PERFORMED OR MATERIALS

More information

AGREEMENT FOR TRANSPORTATION SERVICES

AGREEMENT FOR TRANSPORTATION SERVICES AGREEMENT FOR TRANSPORTATION SERVICES This Agreement is made this day of 20, by and between Long Island University ( University ), an educational institution incorporated and doing business under the laws

More information

MANITOBA LIQUOR AND LOTTERIES COPORATION CORPORATE PURCHASE ORDER - TERMS & CONDITIONS

MANITOBA LIQUOR AND LOTTERIES COPORATION CORPORATE PURCHASE ORDER - TERMS & CONDITIONS MANITOBA LIQUOR AND LOTTERIES COPORATION CORPORATE PURCHASE ORDER - TERMS & CONDITIONS 1. Incorporation of Terms and Conditions in Purchase Order The terms and conditions in this document are incorporated

More information

SUBCONTRACT AGREEMENT

SUBCONTRACT AGREEMENT 200 Parr Boulevard, Richmond, CA 94801 p 510-234-0926 f 510-237-2435 www.overaa.com Subcontractor Contact Person Address Project Project Location Owner SUBCONTRACT AGREEMENT Phone No. Fax No. Subcontract

More information

Document A107. Standard Form of Agreement Between Owner and Contractor for a Project of Limited Scope

Document A107. Standard Form of Agreement Between Owner and Contractor for a Project of Limited Scope TM Document A107 2007 Standard Form of Agreement Between Owner and Contractor for a Project of Limited Scope AGREEMENT made as of the in the year (In words, indicate day, month and year.) day of BETWEEN

More information

AIA Document A107 TM 1997

AIA Document A107 TM 1997 AIA Document A107 TM 1997 Abbreviated Standard Form of Agreement Between Owner and Contractor for Construction Projects of Limited Scope where the basis of payment is a STIPULATED SUM AGREEMENT made as

More information

STATE OF SOUTH CAROLINA ) ) CONTRACTOR AGREEMENT COUNTY OF HORRY )

STATE OF SOUTH CAROLINA ) ) CONTRACTOR AGREEMENT COUNTY OF HORRY ) STATE OF SOUTH CAROLINA ) ) CONTRACTOR AGREEMENT COUNTY OF HORRY ) THIS AGREEMENT is made this day of, 20, by and between Horry County, a political subdivision of the State of South Carolina, whose Administrative

More information

OGC-S Owner-Contractor Construction Agreement

OGC-S Owner-Contractor Construction Agreement Owner-Contractor Construction Agreement This agreement is entered into as of ( Effective Date ) between Lone Star College (the "College"), a public junior college pursuant to Section 130.004 of the Texas

More information

W I T N E S S E T H:

W I T N E S S E T H: GENERAL CONTRACTORS SUBCONTRACT AGREEMENT THIS CONTRACT, made and entered into the day of, 20, by and between, a Tennessee, having its principal place of business at, hereinafter referred to as "Contractor"

More information

APPENDIX 3 - CONTRACT AGREEMENT BETWEEN OWNER AND CONTRACTOR ARTICLE 1 SCOPE OF CONTRACT WORK

APPENDIX 3 - CONTRACT AGREEMENT BETWEEN OWNER AND CONTRACTOR ARTICLE 1 SCOPE OF CONTRACT WORK APPENDIX 3 - CONTRACT AGREEMENT BETWEEN OWNER AND CONTRACTOR THIS AGREEMENT made this day of, 201* BETWEEN: AND (the "Owner") (the "Contractor") In consideration of the mutual covenants and agreements

More information

These Standard Terms and Conditions form a contract between the Company and the Supplier. SUPPLY OF GOODS / SERVICES QUALITY PRICE AND PAYMENT

These Standard Terms and Conditions form a contract between the Company and the Supplier. SUPPLY OF GOODS / SERVICES QUALITY PRICE AND PAYMENT These Standard Terms and Conditions form a contract between the Company and the Supplier. SUPPLY OF GOODS / SERVICES 1. The Supplier shall supply and deliver to the Company all the goods/services set out

More information

1 In these Domestic Sub-Contract Conditions the following expressions and terms shall have the meanings given below:

1 In these Domestic Sub-Contract Conditions the following expressions and terms shall have the meanings given below: DOMESTIC SUB-CONTRACT CONDITIONS These are the Domestic Sub-Contract Conditions referred to by the Articles of Agreement to which they are attached. In the event that these Domestic Sub-Contract Conditions

More information

TOWN OF BURLINGTON PURCHASING DEPARTMENT New Four Stage Breathing Air Compressor Contract #17S

TOWN OF BURLINGTON PURCHASING DEPARTMENT New Four Stage Breathing Air Compressor Contract #17S TOWN OF BURLINGTON PURCHASING DEPARTMENT New Four Stage Breathing Air Compressor Contract #17S-220-0006 If this document is used to submit a bid then you must submit your contact information to Kate Moskos

More information

AIBC Standard Form of Contract 6C between Client and Consultant

AIBC Standard Form of Contract 6C between Client and Consultant AIBC Standard Form of Contract 6C between Client and Consultant FOR USE ON: PROJECTS WITH SEPARATELY ENGAGED CONSULTANTS. This Form of Contract contemplates: 1. Engagement of the Consultant to provide

More information

Document A Exhibit A Insurance and Bonds

Document A Exhibit A Insurance and Bonds Document A101 2017 Exhibit A Insurance and Bonds This Insurance and Bonds Exhibit is part of the Agreement, between the Owner and the Contractor, dated the day of in the year (In words, indicate day, month

More information

ATTACHMENT 1 - SUBCONTRACTOR TERMS AND CONDITIONS

ATTACHMENT 1 - SUBCONTRACTOR TERMS AND CONDITIONS ATTACHMENT 1 - SUBCONTRACTOR TERMS AND CONDITIONS Any Subcontract Agreement between CTI and Subcontractor ( Agreement ) shall include these. CTI and Subcontractor agree as follows: 1. Subcontract Documents.

More information

Region of Waterloo Terms and Conditions

Region of Waterloo Terms and Conditions Region of Waterloo Terms and Conditions Note: These Terms and Conditions, as applicable, together with the attached Purchase Order form a legally binding agreement (the Agreement ) between the Vendor and

More information

(1) In these sub-contract conditions of agreement, the following words and phrases shall have the following meanings:-

(1) In these sub-contract conditions of agreement, the following words and phrases shall have the following meanings:- Anti-Bribery & Corruption Policy of Intent STONBURY LIMITED TERMS AND CONDITIONS FOR SUBCONTRACTORS 1. INTERPRETATION (1) In these sub-contract conditions of agreement, the following words and phrases

More information

PROJECT SUBCONTRACT AGREEMENT BETWEEN GERSHENSON CONSTRUCTION CO., INC. AND

PROJECT SUBCONTRACT AGREEMENT BETWEEN GERSHENSON CONSTRUCTION CO., INC. AND PROJECT SUBCONTRACT AGREEMENT BETWEEN GERSHENSON CONSTRUCTION CO., INC. AND CONTRACTOR: ADDRESS: Gershenson Construction Co., Inc. #2 Truitt Drive Eureka, Missouri 63025 TELEPHONE: (636) 938-9595 SUBCONTRACTOR:

More information

SUBCONTRACTOR TERMS AND CONDITIONS

SUBCONTRACTOR TERMS AND CONDITIONS SUBCONTRACTOR TERMS AND CONDITIONS ARTICLE 1.0 GENERAL OBLIGATIONS The Prime Contract, including all general conditions; appendices; special and supplemental conditions or provisions; drawings or plans;

More information

CONTRACT AGREEMENT FOR PARKING AREA CONSTRUCTION. THIS AGREEMENT, made this day of, 2018,

CONTRACT AGREEMENT FOR PARKING AREA CONSTRUCTION. THIS AGREEMENT, made this day of, 2018, CONTRACT AGREEMENT FOR PARKING AREA CONSTRUCTION THIS AGREEMENT, made this day of, 2018, signed between Nampa & Meridian Irrigation District, hereafter referred to as "NMID" and, of (address), hereinafter

More information

HOUSING CONSTRUCTION CONTRACT (Projects up to $10,000)

HOUSING CONSTRUCTION CONTRACT (Projects up to $10,000) HOUSING CONSTRUCTION CONTRACT (Projects up to $10,000) THIS CONTRACT is by and between the Stockbridge-Munsee Community ( TRIBE ), for its Division of Community Housing, whose address is N8618 Oak St.,

More information

I N V I T A T I O N T O B I D BID #33-16 RECONSTRUCTION OF RETAINING WALL

I N V I T A T I O N T O B I D BID #33-16 RECONSTRUCTION OF RETAINING WALL FINANCE DEPARTMENT I N V I T A T I O N T O B I D GREGORY N. L HEUREUX Finance Director KRISTIE BRADBURY Deputy Finance Director COLLEEN C. SELBERG Purchasing Agent BID #33-16 RECONSTRUCTION OF RETAINING

More information

Cost plus contract. (with guaranteed maximum price option) Standard construction document CCDC. Canadian construction documents committee

Cost plus contract. (with guaranteed maximum price option) Standard construction document CCDC. Canadian construction documents committee Standard construction document CCDC Cost plus contract (with guaranteed maximum price option) Apply a CCDC 3 copyright seal here. The application of the seal demonstrates the intention of the party proposing

More information

REQUEST FOR TENDER No GENERAL INSURANCE BROKERAGE SERVICES FOR PROPERTY, BOILER & MACHINERY and CRIME

REQUEST FOR TENDER No GENERAL INSURANCE BROKERAGE SERVICES FOR PROPERTY, BOILER & MACHINERY and CRIME REQUEST FOR TENDER No. 1717 GENERAL INSURANCE BROKERAGE SERVICES FOR PROPERTY, BOILER & MACHINERY and CRIME Issue date: February 10, 2016 Closing location: Purchasing Department 2020 Labieux Road Nanaimo,

More information

ANNEX III INDIVIDUAL CONSULTANT GENERAL TERMS AND CONDITIONS

ANNEX III INDIVIDUAL CONSULTANT GENERAL TERMS AND CONDITIONS ANNEX III INDIVIDUAL CONSULTANT GENERAL TERMS AND CONDITIONS 1. LEGAL STATUS: The Individual contractor shall have the legal status of an independent contractor vis-à-vis the United Nations Development

More information

Cummins South Africa (Pty) Limited

Cummins South Africa (Pty) Limited Cummins South Africa (Pty) Limited STANDARD TERMS AND CONDITIONS 1 General 1.1 This Agreement contains all the terms and conditions between the Customer and Cummins South Africa (Pty) Ltd (Cummins). 1.2

More information

Please ensure that the following information is enclosed in your subcontract package:

Please ensure that the following information is enclosed in your subcontract package: SUBCONTRACT PROCESS PLEASE READ ENTIRELY: CONTAINS IMPORTANT INFORMATION Please ensure that the following information is enclosed in your subcontract package: Preliminary Information Subcontract Agreement

More information

STANDARD TERMS AND CONDITIONS FOR THE SALE OF GOODS ALL MARKETS EXCEPT OIL AND GAS

STANDARD TERMS AND CONDITIONS FOR THE SALE OF GOODS ALL MARKETS EXCEPT OIL AND GAS STANDARD TERMS AND CONDITIONS FOR THE SALE OF GOODS ALL MARKETS EXCEPT OIL AND GAS 1. Scope of Application These terms and conditions of sale ( T&C ) apply to all sales by our company ( Supplier ) of goods

More information

GENERAL CONDITIONS OF CONTRACT

GENERAL CONDITIONS OF CONTRACT Petroleum Company of Trinidad and Tobago Limited GENERAL CONDITIONS OF CONTRACT 2009 MAY 26 GENERAL CONDITIONS OF CONTRACT TABLE OF CONTENTS NO. CLAUSE PAGE 1. DEFINITIONS 1 2. COMMENCEMENT AND COMPLETION

More information

SECTION 2 : JURONG HEALTH SERVICES PTE LTD STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WORKS

SECTION 2 : JURONG HEALTH SERVICES PTE LTD STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WORKS SECTION 2 : JURONG HEALTH SERVICES PTE LTD STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WORKS 1. DEFINITIONS AND INTERPRETATION 1.1 Definitions In this Contract (as hereinafter defined)

More information

General Terms of Business

General Terms of Business Applied Satellite Technology Limited General Terms of Business INTRODUCTION These terms and conditions govern the relationship between Applied Satellite Technology Ltd and the Client and are the basis

More information

Pleece&Co LTD. Terms and Conditions +44 (0)

Pleece&Co LTD. Terms and Conditions +44 (0) Pleece&Co LTD Terms and Conditions +44 (0)1273 921 772 gary@pleeceandco.com 1. APPLICABILITY OF THESE GENERAL CONDITIONS 1.1 Except as set out below, or as otherwise agreed in writing, these General Conditions,

More information

SUBCONTRACTOR AGREEMENT

SUBCONTRACTOR AGREEMENT SUBCONTRACTOR AGREEMENT This Subcontractor Agreement (herein referred to as "Agreement"), made this day of _, 20 between Bianchi Construction LLC, ("Contractor"), and ("Subcontractor"). Terms: The basic

More information

PENNSYLVANIA CONVENTION CENTER REGISTRATION AND RIGHT OF ENTRY LICENSE AGREEMENT EVENT CONTRACTOR

PENNSYLVANIA CONVENTION CENTER REGISTRATION AND RIGHT OF ENTRY LICENSE AGREEMENT EVENT CONTRACTOR PENNSYLVANIA CONVENTION CENTER REGISTRATION AND RIGHT OF ENTRY LICENSE AGREEMENT EVENT CONTRACTOR This Registration and Right of Entry License Agreement ( Agreement ) dated is entered between SMG, a Pennsylvania

More information

PRODIGY. CONTRACTING GROUP INC. CommerCial residential industrial

PRODIGY. CONTRACTING GROUP INC. CommerCial residential industrial Dear Subcontractor; Please find enclosed our Subcontractor Insurance/Hold Harmless agreement and Master Agreement for your signature and return. It is the company s policy and our insurance program s requirement

More information

RENOVATION CONTRACT. Borrower Name(s): Phone #: Phone #:

RENOVATION CONTRACT. Borrower Name(s): Phone #: Phone #: RENOVATION CONTRACT Case Number: Date: Borrower Name(s): Phone #: Phone #: THIS RENOVATION CONTRACT ( Contract ) dated as of, by and between ( Owner ) and ( Contractor ). Owner and Contractor, in consideration

More information

AH: STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WOPKS SCC.1

AH: STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WOPKS SCC.1 COMPLIANCE TO CONDITIONS OF CONTRACT - SCC.1(Renovation) Please indicate clearly below your compliance to each clause of the Conditions of Contract. Where you are not in agreement, you should give your

More information

Emtelle UK Limited Conditions Of Sale Of Goods

Emtelle UK Limited Conditions Of Sale Of Goods Emtelle UK Limited Conditions Of Sale Of Goods 1. INTERPRETATION 1.1 In these terms and conditions the following words have the following meanings: Buyer the person(s) or company whose order for the Goods

More information

Purchase Order Terms and Conditions

Purchase Order Terms and Conditions Purchase Order Terms and Conditions 1. These terms and conditions together with the terms and conditions on the face of the Purchase Order, and any specifications, drawings, instructions or other written

More information

SUBCONTRACTOR CONTRACT THIS AGREEMENT, Made as of (Current Date), In the Year of (Current Year),

SUBCONTRACTOR CONTRACT THIS AGREEMENT, Made as of (Current Date), In the Year of (Current Year), SUBCONTRACTOR CONTRACT THIS AGREEMENT, Made as of (Current ), In the Year of (Current Year), Between the Contractor: And the Sub-Contractor: For the Project: Owner s Name Sub-Contractor s Name License

More information

SC BUILDERS, Inc. SAMPLE MASTER SUBCONTRACT AGREEMENT TABLE OF CONTENTS

SC BUILDERS, Inc. SAMPLE MASTER SUBCONTRACT AGREEMENT TABLE OF CONTENTS SC BUILDERS, Inc. MASTER SUBCONTRACT AGREEMENT TABLE OF CONTENTS Contract #XXXXX Page Section 1. Entire Contract... 2 Section 2. Scope... 3 Section 3. Subcontract Price... 3 Section 4. Payment Schedule/Retention...

More information