HomeStyle Renovation Submission Checklist

HomeStyle Renovation Submission Checklist Borrower Name: Loan #: Homestyle Calculation Worksheet (LoanBuilder) * HomeStyle Renovation Consumer Tips (Form 1204) signed by borrower Appraisal with all improvements listed on Repairs & Updates Addendum and reflecting "After-Improved Value" Renovation Loan Borrower's Disclosure (provided by FGMC) Pre-Purchase Home Inspection (if required per Purchase Agreement) Permit Certification Form (Provided by FGMC) Current Purchase Contract between Borrower(s) and Seller (Purchase Only) Payoff Statement (Refinance Loans Only) The Following Are Required from Each Contractor: HomeStyle Renovation Homeowner/Contractor Agreement (provided by FGMC) Contractor Bids/Proposals Signed by Contractor & Accepted by Borrower HomeStyle Renovation Draw Request Disclosure (provided by FGMC) Important tice Regarding Contingency Funds (provided by FGMC) Renovation Loan Contractor Profile Report (provided by FGMC) Permit Certification Form (provided by FGMC) General Contractor Attestation Letter (provided by FGMC) Contractor's Liability Insurance Contractor's License (as required by state or locality) Contractor's W9 * Required with Initial Submission HomeStyle Renovation Submission Checklist Rev 9.29.15

RENOVATION LOAN BORROWER'S DISCLOSURE Borrower(s): Property Address: City/State/Zip: Lender: Borrower hereby warrants and represents (which warranties, covenants, agreements and representations shall survive the making of any and all advances) to Lender, its agents, successors and/or assigns (hereinafter collectively called Lender ) as follows: Borrower acknowledges that Borrower will select and investigate or has selected and investigated the background, experience and reputation of any and all contractors (hereinafter referred to as Contractors ) who will furnish labor, material or other services for the construction of said improvements and that Lender has, and shall have, no responsibility or liability whatever for such persons or for the quality of their materials or workmanship. Borrower acknowledges that Lender has the right to verify the acceptability of Borrower s selection of any or all Contractors in accordance with the guidelines set forth by the Department of Housing and Urban Development (hereinafter referred to as HUD ), USDA, or Fannie Mae and, additionally, Lender has the right to disallow any or all Contractors that do not meet the guidelines for Contractors as set out by HUD, USDA, or FNMA. Borrower understands that these statements and acknowledgments are made for the purpose of inducing the Lender to advance the money pursuant to the terms of the Loan documents, and the Lender is relying upon the truth and accuracy of the statements made in advancing such loan proceeds. Further, Borrower agrees to indemnify and save Lender, its agents, successors and/or assigns, harmless against costs, damages, attorney's fees, expenses and liabilities which it may incur or sustain in connection with the incorrectness of any of these representations or any court action arising therefrom and will pay the same upon demand. Borrower further agrees to indemnify and save Lender, its agents, successors and/or assigns, harmless from any claims by or against the Contractor or any subcontractors or material suppliers. Borrower s Signature Date Co-Borrower s Signature Date Renovation Loan Borrower s Disclosure Rev. 9.29.15

HOMEOWNER/CONTRACTOR AGREEMENT Owner(s): Property Address: City/State/Zip: Phone #: Email Address: Contractor s Company Name: Contact Person: Address: City/State/Zip: Email Address: Phone Number: THIS AGREEMENT, made this date, / /, between the above mentioned Homeowner (Owner) and Contractor, is for the rehabilitation of the property located at that has been approved for a Fannie Mae HomeStyle Renovation Loan. The Owner(s) shall pay the Contractor the sum of $_ for completion of the work, including all sales tax due by law, together with such increases or decreases in the contract price as may be approved in writing by the Lender. The work will begin within 30 days of loan closing with the Lender and will be completed by / /, unless delayed beyond the Contractor's control. The General Provisions listed below are made a part of this Agreement. The contract documents consist of the architectural exhibits listed in the Rehabilitation Loan Agreement between the Owner(s) and the Lender, or as described below (or on an attached sheet): 1. Contract Documents: This Agreement includes all general provisions, special provisions, attached proposals and architectural exhibits that were accepted by the lender. Work not covered by this agreement will not be required unless it is required by reasonable inference as being necessary to produce the intended result. By executing this Agreement, the contractor represents that he/she has visited the site and understands local conditions, including state and local building regulations and conditions under which the work is to be performed. 2. Owner: Unless otherwise provided for in the Agreement, the owner will secure and pay for necessary easements, exceptions from zoning requirements, or other actions which must precede the approval of a permit for this project. If owner fails to do so then the contract is void. If the contractor fails to correct defective work or persistently fails to carry out the work in accordance with the agreement or general provisions, the owner may order the contractor in writing to stop such work, or a part of the work, until the cause for the order has been eliminated. 3. Contractor: The contractor will supervise and direct the work and the work of all subcontractors. He/she will use the best skill and attention and will be solely responsible for all construction methods and materials and for coordinating all portions of the work. Unless otherwise specified in the Agreement, the contractor will provide for and/or pay for all labor, materials, equipment, tools, machinery, transportation, and other goods, facilities, and services necessary for the proper execution and completion of the work. The contractor will maintain order and discipline among employees and will not assign anyone unfit for the task. The contractor warrants to the owner that all materials and equipment incorporated are new and that all work will be of good quality and free of defects or faults. The contractor will pay all sales, use and other taxes related to the work and will secure and pay for building permits and/or other permits, fees, inspections and licenses necessary for the completion of the work unless otherwise specified in the Agreement. The contractor will indemnify and hold harmless the owner from and against HomeStyle Homeowner Contractor Agreement Rev 9.29.15

all claim, damages, losses, expenses, legal fees or other costs arising or resulting from the contractors performance of the work or provisions of this section. The contractor will comply with all rules, regulations, laws, ordinances and orders of any public authority or HUD inspector bearing on the performance of the work. The contractor is responsible for, and indemnifies the Owner against, acts and omissions of employees, subcontractors and their employees, or others performing the work under this Agreement with the contractor. The contractor will provide shop drawings, samples, product data or other information provided for in this Agreement, where necessary. 4. Subcontractor: Selected by the contractor, except that the contractor will not employ any subcontractor to whom the owner may have a reasonable objection, nor will the contractor be required by the owner to employ any subcontractor to whom the contractor has a reasonable objection. 5. Work By Owner or Other Contractor: The owner reserves the right to perform work related to the project, but which is not a part of this Agreement, and to award separate contracts in connection with other portions of the project not detailed in this Agreement. All contractors and subcontractors will be afforded reasonable opportunity for the storage of materials and equipment by the owner and by each other. Any costs arising by defective or illtimed work will be borne by the responsible party. 6. Binding Arbitration: Claims or disputes relating to the Agreement or General Provisions will be resolved by the Construction Industry Arbitration Rules of the American Arbitration Association (AAA) unless both parties mutually agree to other methods. The notice of the demand for arbitration must be filed in writing with the other party to this Agreement and with the AAA and must be made in a reasonable time after the dispute has arisen. The award rendered by the arbitrator(s) will be considered final and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. 7. Cleanup and Trash Removal: The contractor will keep the owner s residence free from waste or rubbish resulting from the work. All waste, rubbish, tools, construction materials, and machinery will be removed promptly after completion of the work by the contractor. 8. Time: With respect to the scheduled completion of the work, time is of the essence. If the contractor is delayed at any time in the progress of the work by change orders, fire, labor disputes, acts of God or other causes beyond the contractor's control, the completion schedule for the work or affected parts of the work may be extended by the same amount of time caused by the delay. The contractor must begin work no later than 30 days after loan dosing and will not cease work for more than 30 consecutive days. 9. Payments and Completion: Payments may be withheld because of. (1) defective work not remedied; (2) failure of contractor to make proper payments to subcontractors, workers, or suppliers; (3) persistent failure to carry out work in accordance with this Agreement or these general conditions, or (4) legal claims. Final payment will be due after complete release of any and all liens arising out of the contract or submission of receipts or other evidence of payment covering all subcontractors or suppliers who could file such a lien. The contractor agrees to indemnify the Owner against such liens and will refund all monies including costs and reasonable attorney's fees paid by the owner in discharging the liens. A 10 percent holdback may be required by the lender to assure the work has been properly completed and there are no liens on the property. 10. Protection of Property and Persons: The contractor is responsible for initiating, maintaining, and supervising all necessary or required safety programs. The contractor must comply with all applicable laws, regulations, ordinances, orders or laws of federal, state, county or local governments. The contractor will indemnify the owner for all property loss or damage to the owner caused by his/ her employees or his/her direct or subtier subcontractors. 11. Insurance: The contractor will purchase and maintain such insurance necessary to protect from claims under workers compensation and from any damage to the owner(s) property resulting from the conduct of this contract. 12. Changes in the Contract: The owner may order changes, additions or modifications (using form HUD-92577) without invalidating the contract. Such changes must be in writing and signed by the owner and accepted by the HomeStyle Homeowner Contractor Agreement Rev 9.29.15

lender. t all change order requests may be accepted by the lender, therefore, the contractor proceeds at his/her own risk if work is completed without an accepted change order. 13. Correction of Deficiencies: The contractor must correct promptly any work of his/her own or his/her subcontractors found to be defective or not complying with the terms of the contract. 14. Warranty: The contractor will provide a one-year warranty on all labor and materials used in the rehabilitation of the property. This warranty must extend one year from the date of completion of the contract or longer if prescribed by law unless otherwise specified by other terms of this contract. Disputes will be resolved through the Construction Industry Arbitration Rules of the American Arbitration Association. I5. Termination: If the owner fails to make a payment under the terms of this Agreement, through no fault of the contractor, the contractor may, upon ten working days written notice to the owner, and if not satisfied, terminate this Agreement. The owner will be responsible for paying the contractor for all work completed. If the contractor fails or neglects to carry out the terms of the contract, the owner, after ten working days written notice to the contractor, may terminate this Agreement. The owner may finish the job by whatever reasonable method the owner deems expedient. If the cost of completion exceeds the contract balance, the difference, as well as reasonable attorney s fees if necessary, will be paid to the owner by the contractor. Homeowner s Signature Date Homeowner s Signature Date Contractor s Signature Date Name: Title: HomeStyle Homeowner Contractor Agreement Rev 9.29.15

HOMESTYLE RENOVATION DRAW REQUEST DISCLOSURE When the contractor desires to request a draw, the HomeStyle Renovation Loan Disbursement Request Form is to be completed and executed by all the necessary parties. All requested draw requests will require a percentage of completion inspection for determination of the amount to be disbursed. more than five payments may be made to each contractor. The final payment to the contractor will be made following completion of all work, as evidenced by an inspection ordered by First Guaranty Mortgage Corporation, and release of any and all liens arising out of the contract or submission of receipts or other evidence of payment covering all subcontractors or suppliers who could file a legal claim. All draw requests must be submitted directly to First Guaranty Mortgage Corporation. The appropriate Renovation Loan Disbursement Request Form is to be completed and executed by the Contractor and the Borrower for each draw. Please fax this request to 1-866-308-7198 or submit via e-mail to renodisbursements@fgmc.com so that an inspection can be ordered. Upon receipt of inspection (and title update if final draw) by Lender, funds will be disbursed to the Contractor by check. It is anticipated that the time from submittal of an acceptable request and receipt of an inspection report until the check is issued for delivery to the contractor shall be 4-5 business days unless there are delays by the inspector and/or closing agent. Please note: The cost for any failed inspections will be deducted from the Contractor s proceeds. Any questions related to draws are to be addressed with First Guaranty Mortgage Corporation. You may contact the renovation disbursements team by e-mail at renodisbursements@fgmc.com, by fax at 1-866-308-7198 or by mail at: First Guaranty Mortgage Corporation Attn: Renovation Disbursements 5280 Corporate Drive, Suite B200 Frederick, MD 21703 Please te: All change orders must be submitted to FGMC for lender approval prior to the start of the additional work. By signing below, you are acknowledging that you understand the draw procedure and accept the responsibility of this disclosure. BORROWER S SIGNATURE DATE CONTRACTOR S SIGNATURE DATE CO-BORROWER S SIGNATURE DATE PRINTED NAME CONTRACTOR S COMPANY NAME HomeStyle Draw Request Disclosure Rev 9.29.15

IMPORTANT NOTICE REGARDING CONTINGENCY FUNDS A contingency fund is for the sole purpose of unforeseen issues that develop as a result of the proposed scope of work detailed in the lender approved agreements. Therefore, the contingency fund is NOT authorized to be used for work that is unrelated to the scope of work in the lender approved agreements. FURTHERMORE, THE FUNDS CAN ONLY BE USED WITH APPROVAL FROM THE LENDER PRIOR TO THE WORK BEING PERFORMED. Borrower's Initials / Contractor's Initials / In order to request lender approval for any qualified changes, Borrower(s) and Contactor must submit to First Guaranty Mortgage Corporation a fully completed and executed change order request using the form, HUD-92577 "Request for Acceptance of Changes in Approved Drawings and Specifications". This form is available on the HUD website or can be obtained from your assigned escrow administrator. You may submit this completed form to FGMC by fax at 1-866-308-7198, by e-mail at renodisbursements@fgmc.com or by mail at: First Guaranty Mortgage Corporation Attn: Renovation Disbursements 5280 Corporate Drive, Suite B200 Frederick, MD 21703 If your request is approved by the lender, you will be notified by in writing or by phone. PLEASE NOTE: DO NOT BEGIN WORK WITHOUT NOTICE OF APPROVAL BY THE LENDER. IF THE BORROWER ALLOWS ADDITIONAL WORK TO BE PERFORMED WITHOUT PRIOR WRITTEN LENDER APPROVAL THEN THE PAYMENT TO THE CONTRACTOR FOR ANY CHANGES IS SOLELY THE RESPONSIBILITY OF THE BORROWER. By signing below, you are acknowledging that you understand the procedures and requirements for the use of the contingency funds and fully accept your responsibility as stated above. BORROWER'S SIGNATURE DATE CONTRACTOR'S SIGNATURE DATE CO-BORROWER'S SIGNATURE DATE PRINTED NAME CONTRACTOR'S COMPANY NAME FGMC 203k tice Regarding Contingency Rev 9.15.29

CONTRACTOR PROFILE REPORT CONTRACTOR INFORMATION Loan #: Date: Borrower Name: Co-Borrower: Contractor Name: Address: City/State/Zip: Point of Contact: Phone #: Email Address: Alternate #: ORGANIZATION Type of Organization: Corporation Individual Partnership LLC Joint Venture Number of years in which organization has been in business under present name: List jurisdictions legally licensed/qualified to conduct business: Tax ID Number: License Numbers: TYPES OF WORK/EXPERIENCE List the types of work performed directly by the organization: Provide information on two projects completed by the organization within the last year including the name and location of the projects, contact person & phone #, contract amounts, and dates of completion. 1. Name: Dates of Completion: Location Address: Contract Amount: Contact Person: Phone: ( ) 2. Name: Dates of Completion: Location Address: Contract Amount: Contact Person: Phone: ( ) Are there any judgments, claims, arbitration proceedings, or suits pending or outstanding against the organization or its officers? If so, describe in an attached document. Has the organization filed any lawsuits or requested arbitration with regard to construction contracts within the last five years? If so, please describe in an attached document. Contractor Profile Report Rev 9.29.15

FINANCIAL REFERENCES Banks/Creditors/BondingCompany Name: Contact: Phone: ( ) Name: Contact: Phone: ( ) Name: Contact: Phone: ( ) *Copy of most recent financial statement (audited if available) may be requested. INSURANCE Insurance Company with Type, Amount of Coverage, Contact, and Phone Number of Contact Contractor represents and warrants that all information in this Contractor's Profile is complete and accurate. Contractor authorizes the borrower, and/or the lender, to contact the references listed above to verify that the information represented in this Contractor Profile is complete and accurate. Signature: Date: Contractor Name: Title: Contractor Profile Report Rev 9.29.15

Rehabilitation Loan Permit Certification Property Type Applicant (s) Property Address Loan Number Rehab Type Municipality Type Name of Municipality Municipality Phone Number ( ) Contractor Name Anticipated Work (General Description or attach to document) Standard 203(k) Limited 203 (k) HomeStyle City County Other: ATTN: BUILDING DEPARTMENT/INSPECTOR The property listed is subject to renovations. Lending guidelines require that all necessary permits and inspections be obtained from local municipality authorities. Please review the attached plans & specifications to determine if permits are required for the outlined work. Please indicate below which permits/inspections will be required, or if already issued. MUNICIPALITY TO PROVIDE/CONFIRM PERMIT TYPE PERMIT REQUIRED? INSPECTION REQUIRED? COST OF EACH? (if any) General Building HVAC Roofing Electrical Plumbing Other Permits Required

Please check appropriate title of signor: 203(k) Consultant ID # Contractor License # (if applicable) City/Town/County Building Inspection/Code Enforcement Officer (By Signing, Member of Local Municipality certifies the above information to be accurate per the Scope of Work Provided and Reviewed) Borrower Acknowledgement/tice to Mortgage Applicant: You must have this form completed by either a member of your local municipality building department, your licensed General Contractor or your 203(k) HUD Consultant, if applicable. Lender will not permit the scheduling of your closing without verification of required permits, for refinance or purchase transactions. Borrower(s) SELECT ONE: I DO / I DO NOT request the sum of all permits to be financed into my Renovation Rehabilitation Escrow. I/We understand that I/We are responsible for obtaining the required permit and city/local building authority inspections for the above items. monies will be released from the rehab escrow account for the items requiring permits until I have provided the draw request documentation to the lender. Borrower Signature Date Borrower Signature Date First Guaranty Mortgage Corporation Renovation Lending Form 7/19/2016 Page 2 of 2