Domestic Building Insurance - Victoria Policy Wording

Domestic Building Insurance - Victoria Policy Wording CBW DBI VIC 1213 Effective Date 01 December 2013

Welcome to the financial security provided by Calliden Domestic Building Insurance - Victoria Policy Wording. This product is issued by Calliden Insurance Limited (Calliden) (ABN 47 004 125 268, AFSL 234438). The information in this booklet is current at the date of preparation. This product is distributed by Calliden Agency Services Limited (CASL) (ABN 15 096 726 895, AFSL 234437) who act as our agent and do not act as your agent. The product is also distributed by other insurance intermediaries (brokers) who generally do act as your agent when you purchase this product. We are happy to explain the benefits of this Policy. If you require further information please contact us on 1800 805 899. Calliden Domestic Building Insurance Policy Wording - VIC 02

Table of Contents Calliden Domestic Building Insurance - Victoria Policy Wording Important Information 02 The Insurer 02 The Agent 02 Duty of Disclosure 02 Limitation or Exclusion of Rights Against Third Parties 02 Interested Parties 02 Privacy 02 Our Agreement With You 03 Dispute Resolution Process 03 General Insurance Code of Practice 04 Cost of Your Policy 04 Taxation Information 04 Definitions 05 Our Cover 06 Certificate of Insurance 06 Period of Cover 06 We Will Pay 06 We Will Not Pay 07 Exclusions 07 Claims Procedure 08 Conditions 09 Other Matters 10 Jurisdiction 10 How We Will Communicate 10 Calliden Domestic Building Insurance Policy Wording - VIC 01

Important Information The Insurer The insurer of this policy is Calliden Insurance Limited (Calliden) ABN 47 004 125 268. Calliden is a whollyowned subsidiary of Calliden Group Limited which is an Australian company listed on the ASX. Calliden is authorised under the Australian Insurance Act 1973 (Cth) to conduct insurance business in Australia. That Act establishes a system of financial supervision of general insurers in Australia. As an authorised insurer, Calliden is regulated by the Australian Prudential Regulation Authority (APRA). Calliden is also regulated under the Corporations Act 2001 and is the holder of an Australian Financial Services Licence (AFS Licence No. 234438) issued pursuant to that Act. As a holder of an AFS Licence, Calliden is regulated by the Australian Securities and Investments Commission (ASIC). Calliden specialises in manufacturing general insurance products for individuals, the SME sector and groups across metro and regional Australia. You may contact Calliden in any of the following ways: Tel: +61 2 9551 1111 Postal Address: PO Box 348, Milsons Point NSW 1565 Email: through our website www.calliden.com.au The Agent Calliden Agency Services Limited (CASL) ABN 15 096 726 895, AFSL 234437. CASL arranges policies for and on behalf of Calliden. CASL acts under a binding authority given to it by the insurer to administer and issue policies, alterations and renewals. In all aspects of arranging this Policy, CASL acts as an agent for the insurer and not for you. Duty of Disclosure This Policy is subject to the Insurance Contracts Act 1984, under that Act you have a Duty of Disclosure. Before you take out insurance with us, you have a duty, under the Insurance Contracts Act 1984, to tell us of everything that you know, or could reasonably be expected to know, is relevant to our decision to insure you and to the terms of that insurance. If you are not sure whether something is relevant you should inform us anyway. You have the same legal duty to inform us of those things before you renew, extend, vary, or reinstate your contract of general insurance. Your duty however does not require disclosure of things that: reduce the risk are common knowledge we know or, in the ordinary course of our business, ought to know, or we have indicated we do not want to know. If you do not comply with your Duty of Disclosure, we may be entitled to: reduce our liability for any claim cancel the contract refuse to pay the claim avoid the contract from its beginning, if your non-disclosure was fraudulent. Limitation or Exclusion of Rights Against Third Parties This Policy provides that you must not limit or exclude your rights against a party from whom you might otherwise be able to recover in respect to the loss or damage - see Condition e) of this Policy. Interested Parties This Policy provides that the cover provided by this Policy does not extend to an interest in the Dwelling that is not your interest - see Condition f) of this Policy. Privacy Both CASL and Calliden are committed to protecting the privacy of the personal information you provide to us. Any personal information you give us will be treated in accordance with the National Privacy principles, an industry code approved under the Privacy Act 1988 (Cth). We collect personal information from you for the purpose of issuing you with, and administering, this insurance product (including the handling and settlement of claims). CASL also collects information from you to help develop and identify other products and services that may interest clients. Calliden Domestic Building Insurance Policy Wording - VIC 02

Important Information (cont d) We will only disclose personal information about you to third parties where we believe it is necessary to assist us in providing our relevant services and products. The parties to whom we may disclose your personal information include (but are not limited to) other insurers, reinsurers, reinsurance brokers, loss adjusters, external claims data collectors, investigators, agents and others involved in the claims handling process, or as required by law. By submitting your personal information to us, you agree to us using and disclosing your personal information as outlined in this Privacy Statement. This consent to the use and disclosure of your personal information remains valid unless you alter or revoke it by giving us written notice. If you do not provide the information requested, your insurance application may not be accepted, or we may not be able to administer your Policy, or you may breach your Duty of Disclosure, the consequences of which are set out under the heading Duty of Disclosure in this document. You can request access to the personal information we hold about you and, where necessary, you can notify us in writing of changes so we can ensure that the information we hold about you is accurate, complete and up-to-date. From time to time, we may use your name and contact details to send you or your firm offers or information regarding our insurance services or promotions that may be of interest to you. Please let us know if you no longer wish to receive this information. If you require additional information or would like a copy of our privacy policies, please contact us thorough the following means: obtain the privacy policy online at www.calliden.com.au by phone +61 2 9551 1111 by email to privacy@calliden.com.au by letter to Privacy Officer, PO Box 348, Milsons Point, NSW 1565 Our Agreement With You This Policy is a legal contract between you and us. You, or any other person insured under this Policy, must comply with all provisions of this Policy, otherwise there may be no claim payable under this Policy. This Policy will only respond to claims in connection with work described in the Contract which supported the Application for this insurance, and carried out at the site described in the Certificate of Insurance. Dispute Resolution Process If you think we have let you down in any way, or our service is not what you expect (even if through one of our representatives), please tell us so we can help. We are committed to resolving your complaint fairly. If you have a complaint: Contact CASL by phone on +61 2 9551 1111. You will be put in contact with someone who can help resolve your complaint. If you wish you can also write to us about your complaint to Attention: The Customer Relations Manager, PO Box 348, Milsons Point, NSW 1565, or by email to servicefeedback@calliden.com.au. We will listen to you, consider the facts and respond to you within 15 business days. If we need more information or more time to respond properly to your complaint we will contact you to agree an appropriate timeframe to respond. If you are not satisfied with the resolution, then your complaint will be referred to the Dispute Resolution Officer. We will send you our final decision within 45 days from the date you first made your complaint. We expect our procedures will deal fairly and promptly with your complaint. However, if you are not satisfied with our final decision you can choose to have the matter resolved externally with the Financial Ombudsman Service Ltd (FOS). This is an independent body and its services are free to you. As a member we agree to accept the FOS s decision. You can contact the FOS by: Mail: Financial Ombudsman Service Ltd, GPO Box 3, Melbourne, Victoria 3001 Telephone: 1300 78 08 08 Fax: +61 3 9613 6399 Website: www.fos.org.au Email: info@fos.org.au Calliden Domestic Building Insurance Policy Wording - VIC 03

Important Information (cont d) General Insurance Code of Practice Calliden is a signatory to the General Insurance Code of Practice (the Code). The Code aims to raise standards of service between insurers and their customers. Calliden s service standards are in accordance with the Code. For any information about the Code, including a copy of the Code, contact us or the Financial Ombudsman Service on 1300 78 08 08 or visit www.codeofpractice.com.au Cost of your Policy The amount that we charge you for this insurance when you first acquire your Policy is called the premium. The total cost of your Policy is shown on your Policy schedule. Taxation Information All references in this Policy to dollar amounts and the Contract price are inclusive of Goods and Services Tax (GST). If you are not registered for GST in the event of a claim we will reimburse you the GST component in addition to the amount that we pay. The amount that we are liable to pay under this Policy will be reduced by the amount of any input tax credit that you are or may be entitled to claim for the supply of goods or services covered by that payment. If you are entitled to an input tax credit for the premium, you must inform us of the extent of that entitlement at or before the time you make a claim under this Policy. We will not indemnify you for any GST liability, fines or penalties that arise from or are attributable to your failure to notify us of your entitlement (or correct entitlement) to an input credit on the premium. If you are liable to pay an excess under this Policy, the amount payable will be calculated after deduction of any input tax credit that you are or may be entitled to claim on payment of the excess. Calliden Domestic Building Insurance Policy Wording - VIC 04

Definitions Some key words and terms used in this Policy have special meanings. Wherever the following words or terms are used in the Policy they mean what is set out below. Act means the Building Act 1993 as amended from time to time. Application means the application form completed by the Builder applying for this insurance. Builder is the builder described in the Application provided the builder is a builder under the Order. Building Practitioners Board means the same as it does in the Order. Certificate of Insurance means the most recent certificate issued by us. Commencement Day means the same as it does in the Order. Competition and Consumer Provision means the same as it does in the Order. Completion Date means the same as it does in the Order. Contract means the Insurable Domestic Building Contract between you and the Builder pursuant to which the Work is being, or is about to be, carried out. Defective means the same as it does in the Order. Developer means the same as it does in the Order. Disappearance (and its corresponding forms) means the same as it does in the Order. Domestic Building Work means the same as it does in the Order. Dwelling means the home (as defined in the Order) described in the Application. Insurable Domestic Building Contract means the same as it does in the Order. Non-Structural Defect means the same as it does in the Order. Order means the Order made under the Act by the Minister for Planning and as gazetted in May 2003 entitled Domestic Building Insurance Ministerial Order. Policy means this policy wording, any endorsements and the Certificate of Insurance. Statutory Warranty means a warranty implied into the Contract by section 8 of the Domestic Building Contracts Act 1995. Structural Defect means the same as it does in the Order. Structural Element means the same as it does in the Order. Tribunal means the same as it does in the Order. Work means the Domestic Building Work which is carried out or to be carried out by the Builder to the Dwelling under the Contract. We/us/our means Calliden Insurance Limited (Calliden) (ABN 47 004 125 268, AFSL 234438) You/your/yours means the person described in the Application as the owner of the building or land in respect of which the Work is or was being carried out, any successor in title to that person, and any other person who becomes entitled to the benefit of the Statutory Warranties. This Policy is intended to comply with the requirements set out under the Order and any term of this Policy which conflicts with, or is inconsistent with, the Order shall be read and be enforceable as if it complies with the Order. Insolvent (and its corresponding forms) means the same as it does in the Order. Calliden Domestic Building Insurance Policy Wording - VIC 05

Our Cover We will provide insurance cover to you, subject to the terms, conditions and exclusions set out in this Policy, if the Builder dies, becomes Insolvent, or Disappears and you suffer: a) loss or damage resulting from non- completion of the Work; b) loss or damage resulting from Defective Work; c) loss or damage arising from a breach of a Statutory Warranty; d) loss or damage resulting from a failure of the Builder to maintain a standard of quality of work specified in the Contract; e) loss or damage resulting from conduct by the Builder in connection with the Contract that contravenes a Competition and Consumer Provision; f) the loss of a deposit or progress payment under the Contract; and g) the costs of alternative accommodation, removal and storage that are reasonably and necessarily incurred as a result of an event referred to in paragraphs a), b), c), and d) above. We will only pay the costs of alternative accommodation or storage that are reasonably and necessarily incurred for up to 60 days, excluding any period of delay attributable to us. The cover we give in paragraphs a) to g) above extends to the acts or omissions of all persons contracted by the Builder to perform the Work. Certificate of Insurance a) We must provide a Certificate of Insurance evidencing that insurance for the Work has been issued which complies with the Order: i. to you immediately on the issue of this Policy; and ii. on request by you or the Builder at any time. b) The Certificate of Insurance shall be in the form prescribed by the Order. c) Even though you or another person who applies for this insurance may be required to pay the premium when lodging an Application, we may refuse to accept the Application. The Work is not covered until we have provided to you or that other person a Certificate of Insurance evidencing insurance for the Work. Period of Cover a) This Policy provides the cover in relation to Non-Structural Defects in respect of loss or damage occurring during the period commencing on the Commencement Day and ending 2 years after the earlier of: i. the Completion Date of the Contract; and ii. the date of termination of the Contract. b) Subject to paragraph a) above, this Policy provides the cover in respect of all other loss or damage occurring during the period commencing on the Commencement Day and ending 6 years after the earlier of: i. the Completion Date of the Contract; and ii. the date of termination of the Contract. We Will Pay 1. We will pay up to, but not more than $200,000 in the aggregate, for all claims made under this Policy in respect of any one Dwelling, including reasonable legal costs and expenses incurred by you associated with a successful claim against us. 2. If the claim is in respect of the cover for loss or damage resulting from conduct of the Builder that contravenes a Competition and Consumer Provision, we will only pay the costs of rectifying the Work. 3. If the Work is carried out on land in a plan of subdivision containing common property, any claim paid by us relating to the common property is applied pro rata to all such residences, and reduces your remaining available cover accordingly. 4. If the claim is in respect of the cover for loss or damage resulting from non-completion of the Work, we will not pay more than 20% of the Contract price (including any agreed variation to the Contract price) for the Work. Calliden Domestic Building Insurance Policy Wording - VIC 06

Our Cover (cont d) We Will Not Pay 1. Subject to paragraph 2 below, you must bear at your own risk: a) the first $1,000 of each claim first made more than 5 years after the Completion Date; b) the first $750 of each claim first made between 3 and 5 years after the Completion Date; c) the first $500 of each claim first made between 1 and 3 years after the Completion Date; or d) a claim under $500 made between 3 and 12 months after the Completion Date. 2. For the purposes of paragraph 1 above: a) a claim of $500 or more may relate to more than one defect if the amount claimed for any one or more defects is less than $500. b) The date when a claim is made is the earlier of: i. the date when you first notify us of a circumstance that may give rise to a claim; and ii. the date a claim is made. c) An excess may be applied only once in relation to: i. any claim comprising more than one defect; or ii. two or more claims that relate to the same defect. Exclusions a) We will not pay if you are the Builder. b) We will not pay if your claim relates to a person who is excepted under the Order. c) We will not pay any claims for penalties, fines, liquidated damages or other sums relating to delay on the part of the Builder, except to the extent that such amounts represent the increase in rectification costs caused by the effluxion of time. d) We will not pay any claims for money paid to the Builder that exceeds the amounts that should have been paid in accordance with section 11 of the Domestic Building Contracts Act 1995, and as the case requires, sections 40(2), 40(3), or 40(4) of that Act. e) Subject to your right to recover any money paid to the Builder in relation to the Contract and your reasonable costs and expenses incurred in relation to the Contract, we will not pay any claims for the cover for non-completion of the Work if the Builder dies, becomes Insolvent or Disappears before the Builder commences the Work (other than the removal of vegetation) that requires the use of any tools or building materials. f) If you are also a Developer, we will not pay any claims for non-completion of the Work. g) We will not pay for loss or damage in respect of Work relating to landscaping, paving, retaining structures, driveways or fencing, with the exception of such works which: i. are integral to the construction of a building, ii. require the issue of a building permit under the Act, iii. could result in water penetration of or within a building; iv. could adversely affect health or safety; v. adversely affect the structural adequacy of a building; or vi. are not completed and the Builder has died, become Insolvent or Disappeared. h) We will not pay for loss or damage due to fair wear and tear of the Work, or from your failure to maintain the Work. i) We will not pay for loss, damage, consequential loss, cost or expense, disablement or liability, directly or indirectly caused by, contributed to by, resulting from, or arising out of or in connection with: i. war, invasion, acts of foreign enemies, hostilities, or war-like operations (whether war be declared or not) or civil war; Calliden Domestic Building Insurance Policy Wording - VIC 07

Exclusions (cont d) ii. mutiny, civil commotion assuming the proportions of or amounting to a popular rising, military rising, insurrection, rebellion, military or usurped power, confiscation, nationalisation, requisition, or destruction of or damage to property by or under order of any government, public or local authority or looting, sacking or pillage following any of the above. iii. nuclear reaction, nuclear radiation, radioactive contamination or nuclear weapon material; iv. risks normally insured under a policy for public liability or contract works, v. asbestos, or any materials containing asbestos in whatever form or quantity. vi. an act of God or nature, vii. Your failure to maintain appropriate protection against pest infestation or exposure to natural timbers, viii. consequential loss, not otherwise covered by the Order, ix. malfunction in any mechanical or electrical equipment or appliance, if we prove that the malfunction is not attributable to the workmanship of, or installation by the Builder. Claims Procedure 1. You should notify us of any facts or circumstances which may give rise to a claim as soon as you become aware of them to ensure that you comply with the requirements set out in paragraphs 2 below. 2. We may refuse to accept a claim if it is made later than 180 days after the date on which you first became aware, or might reasonably be expected to have become aware, of the death, Disappearance or Insolvency of the Builder. 3. If you give us written notice within 180 days after the date on which you first became aware, or might reasonably be expected to become aware, of the death, Disappearance or Insolvency, of the Builder, we will not rely on section 54 of the Insurance Contracts Act 1984 to reduce our liability under this Policy, or to reduce any amount otherwise payable in respect of a claim made by reason only of a delay in a claim being notified to us. 4. If you submit a claim to us in writing, we will make a decision regarding our liability within 90 days of receipt of the claim. If we do not make a decision regarding our liability within 90 days then, unless we receive an extension of time from you or the Tribunal, we will be deemed to have accepted liability for the claim. 5. If you wish to dispute our decision regarding your claim, you may appeal to the Tribunal. If we are given notice of proceedings before the Tribunal, we will accept findings made by the Tribunal as to whether any of the following events has occurred: a) the non-completion of the Work; b) an event referred to in paragraphs a) to g) under the section of the Policy entitled Cover ; and c) if such an event has occurred, the amount of loss or damage suffered by you as a result of the event. 6. If you notify us of a defect (the initial defect), we will consider you to have given us notice of every other defect to which the initial defect is directly or indirectly related, whether or not the claim in respect of the initial defect is settled. 7. You must use our claim form to make a claim. 8. Upon making a claim under this Policy, you must: a) comply with any reasonable direction by us in relation to the completion or rectification of the Work; b) not undertake or cause to be undertaken, any rectification work without notifying us, unless those works are reasonably necessary to prevent or minimise any further loss or damage; c) provide us, or any builder nominated or approved by us, with reasonable access to the relevant building site for the purpose of inspection, rectification and completion of the Work. You may refuse to provide access to any builder nominated by us if you have reasonable grounds for doing so (such as loss of confidence in the builder); and Calliden Domestic Building Insurance Policy Wording - VIC 08

Claims Procedure (cont d) d) We may not reduce our liability to you by reason of your failure to comply with a requirement under paragraphs 5 a), b) and c) above, unless we can prove that your failure increased our liability under this Policy. 9. You must not make any admissions, offer, promise or payment in connection with any claim. Conditions a) We may not avoid this Policy or refuse to make or reduce any payment under this Policy on the grounds that: i. the Builder breached any duty of the utmost good faith; ii. the Builder failed to comply with any duty of disclosure; iii. the Builder made representations to us; iv. the Builder failed to comply with a provision or requirement of the Policy; v. the Builder prejudiced our interests by act or omission of any description; or vi. the premium or any instalment of the premium has not been paid. b) We are entitled to recover from the Builder any claim paid by us in the circumstances referred to in paragraph a) above. e) You must not limit or exclude your rights against a party from whom you might otherwise be able to recover in respect to the loss or damage. If you do, our liability to you is reduced to the extent we can no longer recover from that other party as a result of the limitation or exclusion by you. f) The cover provided by this Policy does not extend to an interest in the Dwelling that is not your interest. We will not be liable under this Policy to anyone except you. g) You must take reasonable precautions to avoid or minimise loss or damage covered by this Policy. h) You must comply with your obligations under the Policy. Otherwise we may not have to pay your claim(s). c) If we pay a claim, we are entitled to be subrogated to your rights against any party in relation to the claim to the extent of the amount paid by us. d) We will notify the Building Practitioners Board, at the times and in the manner agreed with the Board, in the event that: i. a Builder is refused insurance, ceases to be eligible to renew or procure insurance or, in respect of Domestic Building Work performed prior to the commencement of the Order, fails to purchase or maintain required insurance; ii. any claim under this Policy is settled or paid by agreement or otherwise. Calliden Domestic Building Insurance Policy Wording - VIC 09

Other Matters Jurisdiction This Policy is governed by the law of Victoria. The law of Victoria includes Commonwealth legislation such as the Insurance Contracts Act 1984. Any rights to refuse to pay a claim are subject to section 54 of that Act. How We Will Communicate a) All communications you are required to give or make under this Policy must be sent in writing to us. b) All communications we are required to give or make under this Policy will be sent in writing to you at the address specified in the Certificate of Insurance or as notified by you from time to time. c) All communications sent by post to you or your appointed agent will be deemed to have been received by you on the third day following the day of posting. d) All communications sent by facsimile to you or your appointed agent will be deemed to have been received by you on the date of transmission. Calliden Domestic Building Insurance Policy Wording - VIC 10

Calliden Agency Services Limited (CASL) ABN 15 096 726 895 AFSL 234437 Melbourne Calliden Agency Services Limited Level 9, 11 33 Exhibition Street Melbourne, VIC 3000 Ph 1800 805 899, Fax 1300 662 215 Sydney Calliden Agency Services Limited Level 7, 100 Arthur Street North Sydney, NSW 2060 PO Box 348, Milsons Point 1656 Ph +61 2 9551 1111, Fax +61 2 9551 1155 Calliden Agency Services Limited 2013 Insured and issued by Calliden Insurance Limited (ABN 47 004 125 268, AFSL 234438). CBW DBI VIC 1213