PUNJAB & SIND BANK APPLICATION FOR EMPANELMENT OF INTERIOR FURNISHERS Application Reference No: - PSB/ZO. Dehradun/GA/EF/02/2018-19 LAST DATE OF SUBMISSION. 26-11 2018 by 5.00 PM ZONAL OFFICE Dehradun
1. EMPANELMENT OF INTERIOR FURNISHERS Punjab & Sind Bank is in the process of Empanelling 02-03 each Interior Furnishurers for renovation of / Offices /Branches ( Located in Dehradun, Saharanpur & Muzaffarnagar ) furnishing & interior decoration, etc and similar projects under ZO Dehradun. 2. INSTRUCTIONS TO APPLICANTS 1) Generally, the routine works of the Bank are awarded/procurements are made by calling competitive tenders/quotations from the empanelled contractors/vendors and in case of emergent works/ works of small magnitude, the Bank may opt to award the work/procure supply from any of the empanelled agencies, depending on the exigencies of the work on nomination basis and also has the right for open tendering process for any particular work depending on the nature & magnitude of the work, as per Bank s policies / guidelines stipulated by various statutory Authorities. 2) The empanelment of a contractor/furnisher in Bank shall not confer any right on him either to be necessarily issued the tender papers or for award of work. 3) Application form for empanelment shall be submitted in sealed envelope super scribing Application for Empanelment as Interior Furnishers. 4) The details of the applicants shall be submitted in the Bank s prescribed Application Format only. Wherever required and if the space provided is not sufficient, particulars can be furnished as Annexures but such details shall be clearly mentioned in the respective columns of the Application Format. 5) The applicant should ensure that the application is delivered at the given address within prescribed date and time as mentioned in the advertisement. The application shall be accepted by post / courier or by hand directly put in to tender box placed at ZO Dehradun. 6) No costs incurred by the applicant in applying, in providing necessary clarifications or attending discussions, conferences or site visits will be reimbursed by the Bank. 7) Documentary proof with respect to the prequalification criteria shall be furnished along with the completed application form. Incomplete applications or applications without proper proofs for establishing their credentials will be liable for rejection and no correspondence will be entertained in this regard. 8) The empanelment will be made depending on the credentials submitted and acceptable to Bank, For consideration of experience, works should have been executed in same name & style of the firm in which empanelment is sought. 9) The evaluation will be based on the following; a) Experience and reputation of the firm b) Empanelment with other Banks, PSUs, Govt. Institutions etc. c) Manpower & logistical support of the firm d) Previous experience with the Bank e) Registration with statutory tax authorities like IT, GST, Service Tax, VAT etc., as applicable. 10) If found necessary, Bank may also consider inspecting the works undertaken by the applicants, for which necessary co-ordination shall be made by them. Based on the details furnished in acceptable format, inspection of works and eligibility criteria, the applicants will be empanelled. 11) If found necessary, the Bank may adopt marking scheme for short listing the final list of Interior Furnisher. The marking scheme so adopted will be disclosed before the last date of submission of the applications. 1
12) Decision of the Bank regarding selection / rejection for empanelment will be final and binding and no further correspondence will be entertained. The empanelled contractors will only be informed by post. 13) If, information and details furnished by applicants are found to be false at any time in future or any information withheld, which comes to the notice of the Bank at a later date, the empanelment of such applicant will be cancelled immediately. 14) Applications received after the due date and time is liable to be rejected. 15) The empanelment shall be valid for a period of three years from the date of intimation letter to the short listed consultants / contractors/suppliers/vendors. 16) The present empanelment is mainly for works for value upto Rs.30 Lacs. In case of any high value works, Bank may undertake the works by project specific pre-qualification exercise. 17) The applicant should enclose demand draft (non refundable) for Rs. 1,000/-(Rupees One thousand only) in favour of Punjab & Sind Bank and payable at respective cities where applications are submitted Dehradun. 18) Completed empanelment document shall be submitted up to the last date given in advertisement, during office hours i. e 5 PM at : - THE ZONAL MANAGER PUNJAB & SIND BANK ZONAL OFFICE DEHRADUN, 30 I & S BUILDING MOHEBEWALA, SAHARANPUR ROAD DEHRADUN -248002 3. SCOPE OF EMPANELMENT The scope of work of Contractors for Interior Furnishing Works broadly is to undertake original interior furnishing works, alterations and renovations involving erection of partitions, cabins, workstations, false ceiling, flooring, counters, paneling, storage units, furniture, blinds etc. The contractors will be required to undertake comprehensive works covering civil, interior and electrical works shall submit necessary documentary evidence for carrying out Civil, Interior and electrical works, at the tender stage. 4. ELIGIBILITY CRITERIA The applicant should have the following minimum eligibility criteria: a) The applicant should have undertaken works in Government Departments / Public Sector Undertakings / Central Autonomous Bodies / State Autonomous Bodies / Banks/ Financial Institutions and other reputed Private Firms during last 5 years. One work/project costing Rs.16 lakh (80% of value of work Rs. 20 lakh OR Two works/projects costing Rs.10lakh ( 50% of value of work Rs. 20 lakh OR Three works/projects costing Rs.08 lakh (40% of value of work Rs 20 lakh) Each b) The applicant shall submit the following documents/documentary proof along with the application a. Bidder Profile as per Annexure I. b. Declaration by the Firm / Company has not been declared by Central Governments / State Governments/ Public Sectors to be ineligible to participate for corrupt,
fraudulent or any other unethical business practice and Blacklisted by Government body/established institutions. c. Copies of Work order and details of past installation and works in Hand. d. Copy of Partnership Deed / Registration certificate with Registrar of Companies (If applicable) e. Details of Staff. f. Satisfactory Completion certificate. g. Audited Profit and Loss Account and Balance sheet for the year ending on 2015-16, 2016-17 and 2017-18. h. D.D/P.O for Rs 1000/- (Rupees One thousand only) being the cost of application. i. All pages of bid document must be signed and stamped. j. Tender Offer as per the prescribed format. k. Sample photographs of works undertaken by the firm ( Min.3-4 Nos ). l. Latest I.T.R for the year ending on 2015-16, 2016-17 and 2017-18. m. Other information -Any other relevant information, which is necessary to be furnished, must be provided. n. Applicant should submit copy of the income tax PAN,GSTN Registration certificate with valid registration number. o. The applicant / firm / company shall be registered with ESI, EPF etc., as per extant labour laws. The Requisite documents pertaining to registration for the same shall be obtained. c) The applicant shall have the average annual financial turnover of at least Rs. 80 Lacs in the respective category during last 3 years up to 31-03-2018. d) Contractors for all classes should have well-established office with adequate engineering staff and the applicant / firm / company shall be registered with ESI, EPF etc, as per extant labour laws. 5. APPLICANT OBLIGATIONS 1) The applicant should intimate change of address to the Bank. Failure to do so may result in removal of his name from the empanelled list. 2) The applicant should not indulge in unethical practices. 3) The applicant should execute the works awarded to him strictly as per the terms and conditions of the contract and specifications. 4) The applicant should co-ordinate with Bank Officials/Architects / Consultants/ Contractors, if any, for smooth completion of the works. 5) Any Change in Constitution of firm without prior approval will render the applicant to be removed from the panel. In case of conversion of a firm into two or more firms, fresh empanelment is essential. 6. DISCIPLINARY ACTIONS The Interior Furnisher shall have to abide by all the rules of empanelment and also by the terms and conditions of the agreement/mou. He shall have to execute the works as per contract on time and with good quality. PSB shall have the right to suspend business with him for any period, debar or remove the name from the approved list of Interior Furnishers indefinitely or for a period as decided by PSB after issue of a show cause notice. Decision of PSB shall be final and binding on the Interior Furnishers. The name of the contractor may be removed from the approved list of contractors /Interior Furnishers by the Bank if he:
1. Fails to execute a contract or has executed it unsatisfactorily or 2. Persistently violates any important conditions of contract: or 3. Furnishes false particulars at the time of empanelment: or 4. Indulges in any type of forgery or falsification of records: or 5. Defaults in tax dues like Income Tax, Work Contract Tax, Sales Tax etc. 7. REVISION OF ABOVE RULES OF EMPANELMENT: Bank may modify, add, delete and / or change any of the above rules and the same shall be binding on all the empanelled Contractors / Consultants. Bank reserves its right to reject any / or all the applications without assigning any reasons whatsoever. 8. DATE OF OPENING OF TECHNICAL BID: Technical bid will be opened on.. 9. TECHNICAL EVALUATION CRITERIA The Evaluation Committee (EC) shall carry out the entire evaluation process. The Technical proposal evaluation process would focus on the ability of Interior Furnisher to satisfy the technical requirements of the assignment, quality assurance procedures and experience of Interior Furnishing works. Based upon the above prequalification criteria, the technical proposals will be further evaluated on the following criteria and rating will be provided as below. SNo. DESCRIPTION RATING 1 Experience in Interior Furnishing works Less than 5 years 0 upto 5 years 3 2 above -do- 5 Years and Experience in Interior Furnishing works for Other Bank branches (applicable for both Government and Private Banks) LL Less than 3 Bank Branches 5 0 Bank branches -do- for 3 Bank branches 3 -do- More than 3 Average annual financial turnover during last 3 years up to 31-3 03-2018. 5
Less than 80 Lacs 0 4 Above 80 Lacs upto 100 Lacs 3 Above 100 Lacs 5 category Empanelment with other Public Sector Banks for Interior Furnishing works Less than 3 Banks 0 -do- Up to 3 Banks 3 -do- More than 3 Banks 5 Marking based on Evaluation of the satisfactory certificates provided 5 by other Clients of the Interior Furnisher. For this the latest/last completed project will be taken into consideration. a) If Technical proficiency i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 b) If Financial soundness i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 c) If Mobilization of adequate T&P i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 d) If Mobilization of manpower i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 e) If General behaviour i) Is Outstanding 5 ii) Is Very good 4
iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 f) If the deviation in stipulated date of completion and actual date of completion is i) Delayed 1 ii) Actual Time 3 iii) Before Time 5 TOTAL SCORE 50 10. EVALUATION CRITERIA Only the Interior Furnisher who score at least 60% marks in Technical Evaluation process will qualify to be Empanelled with the Bank. Once the evaluation of technical proposals is completed, the Service Providers who score the prescribed cut-off score & above will only be short listed. In case, none of the required no. of furnishing contractors or less than the no. of furnishing contractors required to be Empanelled fail to reach the cut-off score of at least 60%, then the Bank, at its sole discretion, may qualify required no. of Interior Furnishers on the basis of the top scores.
ANNEXURE I INFORMATION TO BE FURNISHED BY THE APPLICANTS 1 Name of the Applicant/Firm/ Organization Postal address 2 Registered Address Telephone nos 3 4 Address for Communication Mobile nos. E-mail address Postal address Telephone nos. Mobile nos. E-mail address Year of establishment (enclose documentary proof)/experience in no. of years 5 Status of the firm (Enclose copy) o o o o Company Partnership Proprietor Firm Individual 6 Name of Proprietor/ Partners/ Directors of the Organization/Firm with Qualification. Registration Details Companies/Firm Registration Number & date (attach proof) i) ii) 7 GST Registration No: ( Copy shall be enclosed) Income Tax Number: ( Copy shall be enclosed PAN Number: ( Copy shall be enclosed 8 Name and address of Bankers. Enclose Solvency Certificate
Important major projects on which the firm was engaged in the last 5 years and their estimated 9 cost, stage of work viz. planning and construction, the full address of clients shall be indicated against each project. 10 Year Specify the maximum value of work done in a 2015-16 year 2016-17 2017-18 Value of Work 11 A Average Annual financial turnover during last three years Year Annual turnover Important major projects on which the firm is engaged at present and their estimated cost, 11 B stage of work viz. planning and construction, the full address of clients shall be indicated against each project. 2015-16 2016-17 2017-18 Whether an assessor of income tax, if so, 12 mention Permanent Account Number furnish copies of Income Tax Clearance Certificate. Furnish copies of audited Balance Sheet and 13 Profit & loss account (audited) for the last three years.( FY 2015-16, 2016-17,2017-18) 14 If you are registered in panel of other Organization / Statutory bodies such as CPWD, PWD, MES, Banks, etc, furnish their name, Category and date of registration. ( furnish proof) i) ii) iii) iv) Details of three responsible clients/ persons 1. to whom the major works carried out by the applicant with address and telephone number who will be in a position to certify about the 15 quality as well as past performance of your organization
Details of Application Fee DD No. : 2. 16 Date: Issuing Bank / Branch: 17 Furnish copies of Satisfactory Completion Certificate only from PSU Clients (Minimum 3 Nos). (The completion of the projects considered for this satisfactory completion should not be later than 1 year from the date of the application). 9
To, The Zonal Manager Punjab & Sind Bank Ref: Application for empanelment as Furnishing Contractor. Dear Sir, I / we have read and understood the instructions and the Terms & Conditions mentioned in the application form. I / we do hereby declare that the information furnished in the application and the supplementary sheets are correct to the best of my knowledge and belief. I / we authorize Bank to approach our Employers, Clients, Corporation, Organization etc. to verify the facts submitted by me/us. Signature of applicant with seal Name: Designation: Address: Place Date:
CLIENTS CERTIFICATE REGARDING PERFORMANCE OF THE CONTRACTOR Name and address of the clients Name of the interior furnisher. 1 Name of work with brief Particulars 2 Agreement no. date 3 Agreement amount 4 Date of commencement of work 5 Stipulated date of completion 6 Actual Date of completion 7 Details penalty levied for delay ( indicate amount ) if any 8 Gross amount of work competed and paid 9 Name and address of the authority under whom work executed 10 Whether the contract employed qualified Engineer / Overseer during execution of work? 11 I) Quality of work Outstanding/ Very good /good/ Satisfactory / poor II) Amount of work paid on reduced rate, if any 12 i)did the contractor go for arbitration? ii)if, yes total amount of claim iii) Total amount awarded 13 Comments on the capabilities of the contractor a. Technical Proficiency Outstanding/ Very good /good/ Satisfactory / poor b. Financial soundness Outstanding/ Very good /good/ Satisfactory / poor c. Mobilization of adequate T Outstanding/ Very good /good/ Satisfactory / poor & P d. Mobilization of man power Outstanding/ Very good /good/ Satisfactory / poor e. General behavior Outstanding/ Very good /good/ Satisfactory / poor
Note: All columns should be filled in properly Place- Date Signature of the clients Name & Designation Seal of the Organization
PERFORMA 1 PARTICULARS IN RESPECT OF WORK EXECUTED Name of the Bidder: Sr. No 1 List of Important Works Executed by the Agency during the Last Five Years (Separate sheet can also be enclosed if required) Name of the Short Name and Value of Stipulated Date of Date of If the work was Whether work work/ description address of work time of commence completion delayed beyond was left project of work owner executed completion ment stipulated date incomplete or executed executed of completion, contract was with give reasons terminated from address for the delay either side, Give Details Any other relevant information 2 3 4 Note:-Copies of the Agreement/ Moue /Completion Certificate to be enclosed Place: Date: Signature of the Applicant
PERFORMA- 2 LIST OF KEY PERSONAL PERMANANTLY EMPLOYED Sr. No. Name Designation Qualification Experience Years with the Firm Any other information Place: Date: Signature of the Applicant
PERFORMA 3 PARTICULARS IN RESPECT OF WORK IN HAND List of Important Works in Hand/ in Progress Sr. No Name of the work/ project executed with address Short description of work executed Name and address of owner Value of work executed Stipulated time of completion Status Of Work If the work was delayed beyond stipulated date of completion, give reasons for the delay Any other relevant information 1 2 3 4 Note:-Copies of the Agreement/MoU to be enclosed Place: Date: Signature of the Applicant
SNo. DESCRIPTION RATING 1 Experience in Interior Furnishing works Less than 5 years 0 Up to 5 years 3 2 above -do- 5 Years and Experience in Interior Furnishing works for Other Bank branches (applicable for both Government and Private Banks) LL Less than 3 Bank Branches 5 0 Bank branches -do- for 3 Bank branches 3 -do- More than 3 Average annual financial turnover during last 3 years up to 31-3 03-2018. 5 Less than 80 Lacs 0
4 Above 80 Lacs upto 100 Lacs 3 Above 100 Lacs 5 category Empanelment with other Public Sector Banks for Interior Furnishing works Less than 3 Banks 0 -do- Up to 3 Banks 3 -do- More than 3 Banks 5 Marking based on Evaluation of the satisfactory certificates provided 5 by other Clients of the Interior Furnisher. For this the latest/last completed project will be taken into consideration. a) If Technical proficiency i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 b) If Financial soundness i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2
v) Is Poor 1 c) If Mobilization of adequate T&P i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 d) If Mobilization of manpower i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 e) If General behaviour i) Is Outstanding 5 ii) Is Very good 4 iii) Is Good 3 iv) Is Satisfactory 2 v) Is Poor 1 f) If the deviation in stipulated date of completion and actual date of completion is i) Delayed 1 ii) Actual Time 3 iii) Before Time 5 TOTAL SCORE 50 Technical bid will be opened on 27-11 -2018 at ZO Dehradun at 3.00 PM.