Section 8- Special Conditions of Contract
|
|
- Ami Black
- 6 years ago
- Views:
Transcription
1 Part 4: Section 8. of Contract Section 8- of Contract The following of Contract (SCC) shall supplement the General Conditions of Contract (GCC). Whenever there is a conflict, the provisions herein shall prevail over those in the GCC. GCC 1.1(y) Procurement No: The Project Manager is: Mr. Komakech Vincent GCC 1.1(bb) GCC 1.1(ee) GCC 1.1(ii) GCC 2.3 GCC 2.4 GCC2.5 GCC 3.1 GCC 4.2 GCC 6.1 The Site is located at Plot 176Pida, Koro sub-county in Gulu districtand is defined in Drawings included under Volume II of this document: The Start Date shall be: Not more than 7 (Seven) calendar days after the date of Site Possession The Works consist of: Construction of Phase 1 of the proposed JRP Headquarters including the following; Construction of JRP Office Block (1 Floor) Effluent& Waste water disposal facilities External works(selected) This Contract is an Ad-measurement Contract. Sectional completion shall not be permitted. The following documents shall also form part of the Contract: 1. Minutes of Negotiation Meetings if held 2. Contractor s Method statements &completion schedule 3. Contractor s comprehensive Health & Safety Plan The language of the Contract is English and the law governing the Contract is that of the Republic of Uganda. The Employer s specific approval is required for: The Project Manager shall obtain specific approval from the employer before carrying out any of his duties under the contract which in the Project Manager s opinion will cause the amount finally due under the contract to exceed the Contract Price or will give entitlement to extension of time. This requirement shall be waived in an emergency affecting safety of personnel or the works or adjacent property For notices, the Employer s address shall be: Attention: Street Address: Program coordinator JRP Plot 50 Lower Churchill Drive, Laroo Division Section 8: Page 1 of 9Document: Section 8, - SCC
2 Part 4: Section 8. of Contract Floor/Room number: Town/City: Gulu PO Box: 1216, Gulu, Country: UGANDA Telephone: +256 (0) Facsimile number: Electronic mail address: GCC 7.1 GCC 7.2 For notices, the Contractor s address shall be: Attention: Street Address: Floor/Room number: Town/City: Postal Code/PO Box: Telephone: Facsimile number: Electronic mail address: 7.1 on sub-contracting is not modified The following provisions shall apply with regard to the expenditure of provisional sums in respect of nominated sub-contractors; (a) Such sums shall be expended in favor of such persons as the Project Manager shall instruct and all specialists or other who are nominated by the Project Manager are hereby declared to be sub- contractors employed by the Contractor, and are referred to in these conditions as nominated sub contractors provided; (i) That the nominated sub-contractor shall carry out and complete the sub- contract works in every respect to the reasonable satisfaction of the Contactor and of the Project Manager, and in conformity with all the reasonable directions and equipments of the Contractor. (ii) That the nominated sub-contractor shall perform and comply with all the provisions of this contract on the part of the Contractor to be observed, performed and complied with so far as they apply to the sub contract works or to any portion of the same. (iii) That the nominated sub- contractor shall indemnify the Contractor against claims in respect of any negligence, omission or default of the sub contractor, his servants or agents or any misuse by him or them of any scaffolding or other plant, and shall insure himself against any such claims Section 8: Page 2 of 9Document: Section 8, - SCC
3 Part 4: Section 8. of Contract and produce the policy or policies and receipts in respect of premiums paid as and when required by either the Project Manager or the Contractor. (iv) That the nominated sub-contractor shall indemnify the Contractor against the same liabilities in respect of the sub contract works as those for which the contractor is liable to indemnify the Employer under this Contract. (v) That payment in respect of any work, materials or goods comprised in the sub contract shall be made within 14 days after receipt by the Contractor of the sum to which the Contractor shall be entitled by virtue of the Project Manager s certificate issued under the terms of this contract which states as due an amount including the total value of such work, materials or goods, and shall when due be subject to the retention by the Contractor of the sums mentioned in sub paragraph (vi) of paragraph (a) of this condition. (vi) That the Contractor shall retain from the sum directed by the Project Manager as having been included in the calculation of the amount stated as due in any certificate issued under the terms of this contract in respect of the total value of work, materials or goods executed or supplied by the nominated sub contractor the percentage of such value named in the of Contract (SCC) as percentage of certified value Retained up to a total amount not exceeding a sum which bears the same ratio to the sub contract price as the unreduced sum named as the limit of Retention Fund; and that the Contractor s interest in any sums so retained (by whomsoever held) shall be fiduciary as trustee for the nominated sub contractor (but without obligation to invest); and that the nominated sub contractor s beneficial interest in such sums shall be subject only to the right of the Contractor to have recourse thereto from time to time for payment of any amount which he is entitled under the sub contract to deduct from any sum due or to become due to the nominated sub contractor; and that if and when such sums, or any part thereof are released to the nominated sub contractor they shall be paid in full (vii) That the Project Manager and his representatives shall have a right of access to the workshops and other places of the nominated sub contractor as required by the terms of this contract. (b) The Project Manager shall direct the Contractor as to the total value of the work, materials or goods executed or supplied by a nominated sub contractor included in the calculation of the amount stated as due in any certificate issued under the terms of this contract and shall forthwith inform the nominated sub contractor in writing of the Section 8: Page 3 of 9Document: Section 8, - SCC
4 Part 4: Section 8. of Contract amount of the said total value. The sum representing such total value shall be paid by the Contractor to the nominated sub contractor within 14 days after receipt by the Contactor of the sum to which the Contractor shall be entitled by virtue of the certificate less only (i) any retention money which the Contractor may be entitled to deduct under the terms of the sub contract and (ii) any sum to which the Contractor may be entitled in respect of delay in the completion of the sub contract works or any section thereof and (iii) any amount paid under previous certificates. (c) Before issuing any certificate under the terms of the contract, the Project Manager may request the Contractor to furnish to him reasonable proof that all amounts included in the calculation of the amount stated as due in previous certificates in respect of the total value of the work, materials or goods executed or supplied by any nominated sub contractor have been duly discharged, and if the Contractor, fails to comply with any such request the Project Manager shall issue a certificate to that effect and thereupon the Employer may himself pay such amounts to the nominated subcontractor and deduct the same from any sums due or to become due to the Contractor. (d) That the sub contract works shall be completed within the period or (where they are to be completed in sections) periods therein specified and on completion of such sub-contract works, the Project Manager shall certify in writing accordingly; and send a duplicate of any such certificate to the nominated sub contractor (i) the Contractor shall not without the written consent of the Project Manager grant to any nominated sub contractor any extension of the period within which the sub contract works or (where the sub contract works are to be completed in sections) any section thereof is to be completed, provided always that the Contractor shall inform the Project Manager of any representations made by the nominated sub contractor as to the cause of any delay in the progress or completion of the sub contract works or of any section thereof, and that the consent of the Project Manager shall not be unreasonably withheld. (ii) If the nominated sub contractor fails to complete the subcontract works or (where the sub contract works are to be completed in sections) any section thereof within the period specified in the sub contract or within any extended time granted by the Contractor with the written consent of the Project Manager then if the same ought reasonably so to have been completed the Project Manager shall certify in writing accordingly; immediately upon issue the Project Manager shall send a duplicate of any such certificate to the nominated sub contractor. Section 8: Page 4 of 9Document: Section 8, - SCC
5 Part 4: Section 8. of Contract (iii) That if the nominated sub-contractor shall fail to complete the sub contract works or (where the sub contract works are to be completed in sections) any section thereof within the period therein specified or within any extended time granted by the contractor with written consent of the Project Manager, and the Project Manager certified in writing to the Contractor that the same ought reasonably so to have been completed, the nominated sub contractor shall pay or allow to the Contractor either a sum calculated at the rate therein agreed as liquidated and ascertained damages for the period during which the said works or any section thereof shall remain incomplete or a sum equivalent to any loss or damage suffered or incurred by the Contractor and caused by the failure of the nominated sub contractor as aforesaid. (e) If the Project Manager desires to secure final payment to any Nominated sub contractor before final payment is due to the Contractor, and if such sub contractor has satisfactorily indemnified the Contractor against any latent defects, then the Project Manager may issue an interim certificate including an amount to cover the said final payment, and thereupon the Contractor shall pay to such nominated sub contractor the amount so certified. Upon such final payment, the amount named in the appendix to these conditions as limit of Retention Fund shall be reduced by the sum which bears the same ratio to the said amount as does such sub contractor s sub contract price to the Contract Sum, and save for latent defects the Contractor shall be discharged from all liability for the work, materials or goods executed or supplied by such sub contractor under the sub contract to which the payment relates. (f) Neither the existence nor the exercise of the foregoing powers nor anything else contained in these conditions shall render the Employer in any way liable to any nominated sub contractor. (g) Where the Contractor in the ordinary course of his business directly carries out works for which prime cost sums are included in the Contract Specification and where he has so informed the Project Manager and the Project Manager is prepared to receive tenders from the Contractor for such items, then the Contractor shall be permitted to tender for the same or any of them but without prejudice to the Employer s right to reject the lowest or any tender. If the Contractor s tender is accepted, he shall not sub let the work without the consent of the Project Manager: Provided that where a prime cost sum arises under the Architect s instructions issued under the terms of this contract it shall be deemed for the purposes of this paragraph to have been included in the contract Specification. (h) Where the terms of a contract between the Contractor and a Section 8: Page 5 of 9Document: Section 8, - SCC
6 Part 4: Section 8. of Contract GCC 8.1 GCC 9.1 GCC 13.1 GCC 14.1 GCC 17.1 nominated sub contractor so required or the Project Manager shall so authorize in writing the Contractor shall make advance payments to the sub contractor before delivery of the goods, and the Contractor shall be allowed interest for the period from the date of such advance payment on the value of such goods calculated at commercial Bank Lending Rate in force at the time of the advance until the value of the said goods is included in a certificate in accordance with SCC The Schedule of Other Contractors is notpart of the Contract. N/A The Schedule of Key Personnel will bepart of the Contract. The minimum insurance covers shall be: (a) The minimum cover for insurance of the Works, Plant and Materials is:u.shs200million, (b) The maximum deductible for insurance of the Works, Plant and Materials is:u.shs10 million (c) The minimum cover for insurance of Equipment is: U.shs 50 million (d) The maximum deductible for insurance of equipment is: U.shs65 million (e) The minimum cover for insurance of property is: U.shs 650 million (f) The maximum deductible for insurance of property is: U.shs65 million (g) The minimum cover for personal injury or death insurance is: U.shs 130million (h) The maximum deductible for personal injury or death insurance is:u.shs65million Site Investigation Report(s)will not bepart of the contract. The Intended Completion Date for the whole of the Works shall be:. GCC 21.1 The Site Possession Date shall be: Not more than7 calendar days after signing of the contract GCC 25.1 The procedure for disputes shall be as specified in GCC 25.2 to GCC 25.3 GCC 25.4 Fees and types of reimbursable expenses to be paid to the Adjudicator:to be negotiated The arbitration shall be conducted in accordance with the Arbitration law of Uganda. Section 8: Page 6 of 9Document: Section 8, - SCC
7 Part 4: Section 8. of Contract GCC 26.1 GCC 27.1 GCC 27.3 GCC 35.1 G CC 42 GCC 44.1(l) GCC 47.1 Arbitration shall take place at: Gulu or other place within the vicinity of Gulu as specified by the arbitrator The Appointing Authority for the Adjudicator is: The President of the Uganda Society of Architects The Contractor shall submit a detailed program for the works within 14days of contract signing. The period between Program updates is 30 days. The amount to be withheld for late submission of an updated Program is: U.shs 1 million only The Defects Liability Period is 183calendar days. Payment certificates Add the following clause 42.7: The Project Manager shall not be bound to certify any payment under this clause if the net amount thereof, after all retentions and deductions, would be less than Ushs30million. i) At the Intervals stated, Certificates shall be issued provided the amounts of such Certificates are considered reasonable by the Project Manager, in accordance with Clause 42.3 of Conditions of Contract. When applying for a Certificate, the Contractor shall furnish the Project Manager with two copies of a detailed approximate statement of the value in order to expedite the issue of the Certificate. ii) All documents necessary for the purpose of the composition of the Final Account shall be passed to the Project Manager as and when available during the progress of the Works and not later than one month after the Date of Practical Completion. The following events shall also be Compensation Events: N/A The Contract is notsubject to price adjustment in accordance with Clause 47 of the General Conditions of Contract, and the following information regarding coefficients does not apply. The coefficients for adjustment of prices are: Not Applicable GCC 47.1 GCC 48.1 The Index I for local currency will be: N/A The Index I for the specified international currency will be: N/A The Index I for currencies other than the local currency and the specified international currency will be: N/A The proportion of payments retained for each payment certificate is 10% (ten percent). Section 8: Page 7 of 9Document: Section 8, - SCC
8 Part 4: Section 8. of Contract GCC 49.1 GCC 50.1 GCC 51.1 GCC 51.3 GCC 52.1 GCC 52.3 GCC 58.1 The liquidated damages for the whole of the Works are U.shs300,000 (Three Hundred, thousand Ugandan shillings)per day. The liquidated damages for sectional completion of the works shall be computed in proportion to the value of the said works that are completed beyond their due date of completion. The maximum amount of liquidated damages for the whole of the Works is 10%(ten percent) of the final Contract Price. In the event of the maximum amount of liquidated damages being reached before the works are completed, the client may consider alternative options for completion of the said works & subsequent recovery of losses & expenses incurred due to the delayed completion/termination The Bonus for the whole of the Works is N/A. The maximum amount of Bonus for the whole of the Works is N/A The Advance Payment will be equivalent to a maximum of 20%of the Contract Priceand will be paid in the same currencies and proportions as the Contract Price. It will be paid to the Contractor within30 days of the date of issue of the Advance payment certificate following submission of an acceptable Advance Payment Guarantee. The Advance Payment will be repaid by deduction from interim payments calculated as follows until full repayment has been achieved. R = [Va / (Vt x 0.80)] x D Where R = the amount to be repaid Va = the original amount of the advance Vt = the original Contract Price D = the amount of the interim payment pursuant to Clauses 43.1 to 43.4 Always provided that the advance payment shall be completely repaid prior to the time when 80 percent of the original Contract Price has been certified for payment A Performance Security shall be required. The Performance Security shall be for 10%(ten percent)of the Contract Price: The standard form of Performance Security acceptable to the Employer shall be an Unconditional Bank Guarantee in the format presented in Section 9 of the Bidding Documents. The date by which as built drawings are required is:60 days after issuance of the Certificate of Practical completion of the works or sectional completion of each section of work The date by which operating and maintenance manuals are required Section 8: Page 8 of 9Document: Section 8, - SCC
9 Part 4: Section 8. of Contract GCC 58.2 GCC 60.1 is:60 days after Practical completion of the works or sectional completion of each section of work The amount to be withheld for failing to produce as built drawings and/or operating and maintenance manuals by the date required is U.shs3,000,000/= (ThreemillionUganda Shillings). The percentage to apply to the value of the work not completed, representing the Employer s additional cost for completing the Works, is: 20% Section 8: Page 9 of 9Document: Section 8, - SCC
Section 7. General Conditions of Contract for the Procurement of Works
Section 7. General Conditions of Contract for the Procurement of Works Table of Clauses A. General...3 1. Definitions...3 2. Interpretation...5 3. Language and Law...5 4. Project Manager s Decisions...5
More information1 In these Domestic Sub-Contract Conditions the following expressions and terms shall have the meanings given below:
DOMESTIC SUB-CONTRACT CONDITIONS These are the Domestic Sub-Contract Conditions referred to by the Articles of Agreement to which they are attached. In the event that these Domestic Sub-Contract Conditions
More informationCosmos Projects - Standard Terms and Conditions of Sub-Contract
Cosmos Projects - Standard Terms and Conditions of Sub-Contract These standard terms and conditions shall apply to any Sub Contract between Cosmos Projects Limited ( CPL ) and any Sub-Contractor following
More informationAGREEMENT AND SCHEDULE OF CONDITIONS OF BUILDING SUB-CONTRACT (with Quantities)
FOR USE WHERE THE SUB-CONTRACTOR IS NOMINATED UNDER SUB-CLAUSE 31.2 OF THE NATIONAL CONSTRUCTION COUNCIL AGREEMENT AND SCHEDULE OF CONDITIONS OF BUILDING CONTRACT (WITH QUANTITIES), 2000 EDITION NATIONAL
More informationSUBCONTRACT FOR LABOUR ONLY ENGINEERING AND CONSTRUCTION WORKS (September 2005) (Second Edition of CIDB document 1016)
SUBCONTRACT FOR LABOUR ONLY ENGINEERING AND CONSTRUCTION WORKS (September 2005) (Second Edition of CIDB document 1016) Construction Industry Development Board Tel: 012 343 7136 or 012 481 9030 Fax: 012
More informationAGREEMENT AND CONDITIONS OF SUB-CONTRACT (DOMESTIC)
AGREEMENT AND CONDITIONS OF SUB-CONTRACT (DOMESTIC) FOR USE IN CONJUNCTION WITH THE FORMS OF MAIN CONTRACT FOR PUBLIC WORKS ISSUED BY THE OFFICE OF GOVERNMENT PROCUREMENT, DEPARTMENT OF PUBLIC EXPENDITURE
More informationSTANDARD CONSTRUCTION CONTRACT. THESE ARTICLES OF AGREEMENT made in duplicate and effective the day of 2017: NEW BRUNSWICK POWER CORPORATION
STANDARD CONSTRUCTION CONTRACT THESE ARTICLES OF AGREEMENT made in duplicate and effective the day of 2017: BETWEEN: NEW BRUNSWICK POWER CORPORATION (referred to herein as the Owner) AND (referred to herein
More informationTender Terms and Conditions: 1. This invitation of bid is open to contractors, Class-Small registered with the Construction Development Board.
Section II: Bidding Data Sheet 1 Tender Terms and Conditions: 1. This invitation of bid is open to contractors, Class-Small registered with the Construction Development Board. 2. The bidder shall be conducted
More informationNHS BORDERS SGTC3 CONDITIONS OF CONTRACT FOR CONSULTANCY SERVICES (other than Works Consultancies)
NHS BORDERS SGTC3 CONDITIONS OF CONTRACT FOR CONSULTANCY SERVICES (other than Works Consultancies) These Conditions may only be varied with the written agreement of the Client. No terms or conditions put
More information(1) In these sub-contract conditions of agreement, the following words and phrases shall have the following meanings:-
Anti-Bribery & Corruption Policy of Intent STONBURY LIMITED TERMS AND CONDITIONS FOR SUBCONTRACTORS 1. INTERPRETATION (1) In these sub-contract conditions of agreement, the following words and phrases
More informationAIRPORT AUTHORITY HONG KONG
AIRPORT AUTHORITY HONG KONG GENERAL CONDITIONS OF CONTRACT BUILDING AND CIVIL WORKS ISSUE NO. 10 August 2011 [this page not used] GENERAL CONDITIONS OF CONTRACT FOR BUILDING AND CIVIL WORKS TABLE OF CONTENTS
More informationAH: STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WOPKS SCC.1
COMPLIANCE TO CONDITIONS OF CONTRACT - SCC.1(Renovation) Please indicate clearly below your compliance to each clause of the Conditions of Contract. Where you are not in agreement, you should give your
More informationConditions of Contract for PLANT and Design-Build
Conditions of Contract for PLANT and Design-Build FOR ELECTRICAL AND MECHANICAL WORKS AND FOR BUILDING AND ENGINEERING WORKS DESIGNED BY THE CONTRACTOR General Conditions 1st Edition 1999 FEDERATION INTERNATIONALE
More informationMDB Harmonised Particular Conditions
FIDIC Plant and Design-Build Contract MDB Harmonised Particular Conditions 1. Introduction There is a need for FIDIC to provide sample Particular Conditions that render the General Conditions of the 1st
More informationMINISTRY OF FINANCE Procurement Policy Unit (Established under section 6 of the Public Procurement Act, 2015)
MINISTRY OF FINANCE Procurement Policy Unit (Established under section 6 of the Public Procurement Act, 2015) Ref: W/RFQ-GCC GENERAL CONDITIONS OF CONTRACT REQUEST FOR QUOTATION [Issued in terms of section
More informationInformation that complements provisions of Section IV must be incorporated.
Section V. Special Conditions of Contract Notes on the Special Conditions of Contract Similar to the clauses in the Bid Data Sheet in Section III, the clauses in this Section V are intended to help the
More informationConstruction Management Contract This agreement is made by (Contractor) and (Owner) on the date written beside our signatures.
Construction Management Contract This agreement is made by (Contractor) and (Owner) on the date written beside our signatures. Contractor City, Zip Work Phone Number: Cell Phone Number: Fax Number: Email
More informationCONSTRUCTION CONTRACT EXAMPLE
P a g e 1 CONSTRUCTION CONTRACT EXAMPLE THIS AGREEMENT, made and entered into this date, by and between, hereinafter called CONTRACTOR, and NPC QUALITY BURGER, INC., hereinafter called OWNER. IT IS HEREBY
More informationMINISTRY OF FINANCE Procurement Policy Unit (Established under section 6 of the Public Procurement Act, 2015)
MINISTRY OF FINANCE Procurement Policy Unit (Established under section 6 of the Public Procurement Act, 2015) Ref: NCS-LS/RFQ-GCC GENERAL CONDITIONS OF CONTRACT FOR REQUEST FOR QUOTATION [Issued in terms
More informationAnd. The Bank directly and/or through the Branch and/or the Bank Subsidiary/ies currently providers of Banking services to the Customer.
TERMS AND CONDITIONS BETWEEN (1) The Co-operative Bank of Kenya Limited a body corporate incorporated under the Companies Act (Cap 486 of the Laws of Kenya) and duly licensed to carry on banking business
More informationXXXXX TOWN WATER SUPPLY XXXXX TOWN WATER SUPPLY SYSTEM AND SEWERAGE AUTHORITY MANAGEMENT CONTRACT FOR. Date:
REPUBLIC OF UGANDA XXXXX TOWN WATER SUPPLY AND SEWERAGE AUTHORITY MANAGEMENT CONTRACT FOR XXXXX TOWN WATER SUPPLY SYSTEM Date:------------------------------ This MANAGEMENT CONTRACT is made this day of..,
More informationBETWEEN name. address. AND name (hereinafter called the Subcontractor ) address
AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR CONTRACTOR S COPY SUBCONTRACT NO. Alberta Standard Construction Subcontract THIS AGREEMENT made this day of, A.D. 20 BETWEEN name (hereinafter called the
More informationSUNCORP GROUP HOLDINGS (NZ) LIMITED SUNCORP GROUP LIMITED CRS NOMINEES LIMITED TRUST DEED CONSTITUTING THE EXEMPT EMPLOYEE SHARE PLAN
SUNCORP GROUP HOLDINGS (NZ) LIMITED SUNCORP GROUP LIMITED CRS NOMINEES LIMITED TRUST DEED CONSTITUTING THE EXEMPT EMPLOYEE SHARE PLAN CONTENTS PARTIES... 1 INTRODUCTION... 1 COVENANTS... 1 1. INTERPRETATION...
More informationSMALL SERVICE, REHABILITATION, OR CONSTRUCTION AGREEMENT
SMALL SERVICE, REHABILITATION, OR CONSTRUCTION AGREEMENT (This Agreement shall be utilized for any service, rehabilitation, or construction project when funding sources contain no additional restrictions
More informationSHORT FORM STANDARD SUBCONTRACT. This Agreement is made this day of, 20, between
SHORT FORM STANDARD SUBCONTRACT This Agreement is made this day of, 20, between (Contractor) and (Subcontractor). The work described in Section I below shall be performed in accordance with the prime contract
More informationANNEX A Standard Special Conditions For The Salvation Army
ANNEX A Standard Special Conditions For The Salvation Army TO BE ATTACHED TO AIA B101-2007 EDITION ABBREVIATED STANDARD FORM OF AGREEMENT BETWEEN OWNER AND ARCHITECT 1. Contract Documents. This Annex supplements,
More informationContract No BO0. A. Definitions. As used in this Contract the terms are defined as follows:
A. Definitions Contract No. 13139BO0 As used in this Contract the terms are defined as follows: 1. County and/or Owner shall mean the Board of County Supervisors of Prince William County, Virginia, or
More informationAGREEMENT FOR CONSTRUCTION MANAGEMENT SERVICES FOR
AGREEMENT FOR CONSTRUCTION MANAGEMENT SERVICES FOR By and Between WILLIAM S. HART UNION HIGH SCHOOL DISTRICT And Dated as of TABLE OF CONTENTS Page RECITALS... 1 PART 1 PROVISION OF CM SERVICES... 1 Section
More informationARTICLE 1 ARTICLE 3 CONTRACTOR THE SUBCONTRACT DOCUMENTS ARTICLE 2 MUTUAL RIGHTS AND RESPONSIBILITIES
ARTICLE 1 THE SUBCONTRACT DOCUMENTS 1.1 The Subcontract Documents consist of (1) this Agreement; (2) the prime Contract, consisting of the Agreement between the Owner and Contractor and the other Contract
More informationStandard Purchase Terms & Conditions for The Supply and Delivery of Goods
Sp Standard Purchase Terms & Conditions for The Supply and Delivery of Goods REV. NO. DRAFT ISSUED 12 FEBRUARY 2009 COPYRIGHT ALL RIGHTS RESERVED BY RAND REFINERY (PTY) LIMITED 12 February 2009 Rand Refinery
More informationStandard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project
Document A105 2007 Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project AGREEMENT made as of the in the year (In words, indicate day, month and year.) BETWEEN
More informationPOST BID ADDENDUM. Project: LDS Eastview, Mesa, Iona 10 HVAC Project No.: Addendum No.: 2
POST BID ADDENDUM Project: LDS Eastview, Mesa, Iona 10 HVAC Project No.: 504-6955 Addendum No.: 2 Project Address: 2349 Virlow St., Idaho Falls, Idaho 83401 Date: 8/29/2016 Owner: Corporation of the Presiding
More informationSAMPLE DOCUMENT SUBCONTRACT AGREEMENT
SUBCONTRACT AGREEMENT THIS SUBCONTRACT, made this day of by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter "Subcontractor") with an office and
More informationContractor for any and all liability, costs, expenses, fines, penalties, and attorney s fees resulting from its failure to perform such duties.
SUBCONTRACT AGREEMENT THIS SUBCONTRACT, made this day of, 20 by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter "Subcontractor") with an office
More informationTHE UNIVERSITY OF THE WEST INDIES, MONA CAMPUS Procurement Policies and Procedures Manual. Appendices APPENDICES
APPENDICES 53 Appendix 1-1 Agreement Form This Agreement made the...day of...20...between...of...hereinafter called the Employer and...of...hereinafter called the Contractor of the other part. Whereas
More informationPlease ensure that the following information is enclosed in your subcontract package:
SUBCONTRACT PROCESS PLEASE READ ENTIRELY: CONTAINS IMPORTANT INFORMATION Please ensure that the following information is enclosed in your subcontract package: Preliminary Information Subcontract Agreement
More informationTHE JAPAN COMMERCIAL ARBITRATION ASSOCIATION COMMERCIAL ARBITRATION RULES. CHAPTER General Provisions
THE JAPAN COMMERCIAL ARBITRATION ASSOCIATION COMMERCIAL ARBITRATION RULES As Amended and Effective on January 1, 2008 CHAPTER General Provisions Rule 1. Purpose The purpose of these Rules shall be to provide
More informationSTANDARD CONDITIONS FOR COMPANY VOLUNTARY ARRANGEMENTS
STANDARD CONDITIONS FOR COMPANY VOLUNTARY ARRANGEMENTS Version 3 January 2013 TABLE OF CONTENTS 1 COMPANY VOLUNTARY ARRANGEMENTS 1 PART I: INTERPRETATION 5 1 Miscellaneous definitions 5 2 The Conditions
More informationLLOYD'S ASIA (OFFSHORE POLICIES) INSTRUMENT 2002 CONTENTS
LLOYD'S ASIA (OFFSHORE POLICIES) INSTRUMENT 2002 CONTENTS Clause Page No. 1. Commencement and Interpretation 3 2. Direction by the Council 3 3. Constitution of the Member s Offshore Policies Trust Fund
More informationSECTION 2 : JURONG HEALTH SERVICES PTE LTD STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WORKS
SECTION 2 : JURONG HEALTH SERVICES PTE LTD STANDARD CONDITIONS OF CONTRACT FOR CONSTRUCTION AND IMPROVEMENT WORKS 1. DEFINITIONS AND INTERPRETATION 1.1 Definitions In this Contract (as hereinafter defined)
More informationREQUEST FOR PROPOSAL: 8/25/2012 NUMBER OF COPIES TO SUBMIT: TWO (2) Page 1
A REQUEST TO SUBMIT PROPOSALS FOR DEMOLITION CONTRACTORS FOR DEMOLITION OF PROPERTIES WITH COMMUNITY DEVELOPMENT BLOCK GRANT ( CDBG ) FUNDS FOR THE CITY OF PONTIAC This is a Federally Funded project. The
More informationIOP(SA) PLUMBING WORKS AGREEMENT
IOP(SA) PLUMBING WORKS AGREEMENT 1. INTERPRETATION 1.1 In this Agreement, unless inconsistent with the context, the words and phrases defined hereunder shall bear the meanings assigned to them in this
More informationScottish Conditions of Appointment of an Architect SCA/2014 (Apr 2015)
SCA/201 (Apr 2015) Definitions Where the defined terms are used in the SCA/201 (Apr 2015) they are distinguished by an initial capital letter. Appointment The agreement between the Client and the Architect
More informationCONDITIONS OF CONTRACT. The Builder must execute and complete the Works in a workmanlike manner and ensure the Works are adequately supervised.
CONDITIONS OF CONTRACT 1. RESPONSIBILITY OF BUILDER The Builder must execute and complete the Works in a workmanlike manner and ensure the Works are adequately supervised. 2. WORK PERFORMED OR MATERIALS
More information(i) Draw special attention to certain general conditions applicable to government bids, contracts and orders; and
INDEPENDENT REGULATORY BOARD OF AUDITORS PROCUREMENT GENERAL CONDITIONS OF CONTRACT NOTES The purpose of this document is to: (i) Draw special attention to certain general conditions applicable to government
More informationEXHIBIT A: SECTION INSTRUCTIONS TO BIDDERS
EXHIBIT A: SECTION 000200 INSTRUCTIONS TO BIDDERS 1.01 INVITATION TO BID A. The City of will be accepting bids for the Revised City Wayfinding Signage Project. This project is generally described as: fabrication
More informationAmount of Contract work per the plans and specifications for project. Specifications Attached. Plans Attached
Sample Company 2005 XXXX Main St Anywhere CA 99999 800 555-5555 SUBCONTRACT Contract#: 921 Contract Date: 08/20/2008 SUBCONTRACTOR: Baxter Heating & Cooling 4320 Eucalyptus Way Santa Rosa CA 95401 PROJECT:
More informationLEGAL NOTICE CITY OF ANSONIA, CONNECTICUT REQUEST FOR PROPOSALS
LEGAL NOTICE CITY OF ANSONIA, CONNECTICUT REQUEST FOR PROPOSALS FOR THE INSTALLATION OF BARRIER GATES, DUMPSTER ENCLOSURES, BOLLARDS, AND A CANTILEVER GATE FOR ANSONIA PUBLIC SCHOOLS ANSONIA, CONNECTICUT
More informationMASTER SUBCONTRACT AGREEMENT
MASTER SUBCONTRACT AGREEMENT This Master Subcontract Agreement ( Subcontract ), made this day of, 20 by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter
More informationStandard Form of Agreement Between Contractor and Subcontractor
Standard Form of Agreement Between Contractor and Subcontractor GENERAL TERMS AND CONDITIONS ARTICLE 1 THE SUBCONTRACT DOCUMENTS 1.1 The Subcontract Documents consist of (1) these General Terms and Conditions,
More information1997 Part 2. Document B141. Standard Form of Architect's Services: Design and Contract Administration TABLE OF ARTICLES
TM Document B141 Standard Form of Architect's Services: Design and Contract Administration 1997 Part 2 TABLE OF ARTICLES 2.1 PROJECT ADMINISTRATION SERVICES 2.2 SUPPORTING SERVICES 2.3 EVALUATION AND PLANNING
More information2 THE EMPLOYER Provision of Site 2.2 Permits and Licenses 2.3 Employer s Instructions 2.4 Approvals
GENERAL CONDITIONS 1 GENERAL PROVISIONS.................................... 1 1.1 Definitions The Contract Persons Dates, Times and Periods Money and Payments Other Definitions 1.2 Interpretation 1.3 Priority
More informationWashington University in St. Louis
Washington University in St. Louis Construction Terms and Conditions A. AGREEMENT. The Purchase Order, these Terms and Conditions, any special conditions, Owner s Policies, Design Standards and Insurance
More informationDated 13 August 2009 THE INSOLVENCY FUND AGREEMENT. between MOTOR INSURERS BUREAU OF HONG KONG. and THE GOVERNMENT OF HONG KONG
Dated 13 August 2009 THE INSOLVENCY FUND AGREEMENT between MOTOR INSURERS BUREAU OF HONG KONG and THE GOVERNMENT OF HONG KONG Deacons Solicitors & Notaries 5th Floor Alexandra House 18 Chater Road Central
More informationDOUKPSC04 Rev Feb 2013
DOUKPSC04 Purchasing Standard conditions for the Purchase of Consultancy Services 1 DEFINITIONS In the Contract (as hereinafter defined) the following words and expressions shall have the meanings hereby
More informationForm of Agreement Between the Client And the Quantity Surveyor
Form of Agreement Between the Client And the Quantity Surveyor Second ACQS Edition (May 2009) Contents Agreement 1 Terms of Appointment 1. Quantity Surveyor's obligations 2 2. Client's obligations 2 3.
More informationREQUEST TO SUBMIT PROPOSALS FOR ASBESTOS SURVEYOR FOR THE CITY OF PONTIAC
REQUEST TO SUBMIT PROPOSALS FOR ASBESTOS SURVEYOR FOR THE CITY OF PONTIAC This is a Federally Funded project. The Surveyor and Subcontractors on this project must comply with HUD contract provisions 24CFR
More informationJAPAN INTERNATIONAL COOPERATION AGENCY. General Terms and Conditions for Japanese ODA Loans
JAPAN INTERNATIONAL COOPERATION AGENCY General Terms and Conditions for Japanese ODA Loans April 2012 General Terms and Conditions for Japanese ODA Loans Table of Contents Article Number Heading Page Article
More informationGeneral Conditions of Contract for the Hire of Plant With or Without an Operator
General Conditions of Contract for the Hire of Plant With or Without an Operator CC7 April 1991 (Revised September 2010) Table of Clauses 1. Definition of Terms 2. Contractor s Proper Performance of the
More informationConstruction Management Approach based on FIDIC Conditions of Contract for Construction, st Edition. Dr. Munther M.
Construction Management Approach based on FIDIC Conditions of Contract for Construction, 1999 1st Edition Dr. Munther M. Saket March 2015 1 Traditional Construction Contracts Owner of a construction project
More informationAGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER PRE-CONSTRUCTION AND CONSTRUCTION SERVICES
AGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER PRE-CONSTRUCTION AND CONSTRUCTION SERVICES AGREEMENT made by and between, hereinafter called the Owner, and SITESCOMMERCIAL, LLC 185 WIND CHIME COURT, SUITE
More information1 2 Tender Terms and Conditions: 1. This NOTICE INVITING LIMITED TENDER is open to all contractors, Class-Small registered with the Construction Development Board. 2. The bidder shall be conducted through
More informationWorks Appointment: We, on behalf of the Employer, would like to inform you that your quotation, Reference Number
6/F Dorset House, Taikoo Place, 979 King's Road, Quarry Bay, Hong Kong Project Works Order Works Order No.: Name of Contractor: Description of the works: Date: "Contractor") "Works") Address of premises:
More informationREQUEST FOR PROPOSALS PENSION and OPEB CONSULTING SERVICES
P. O. B o x 1 5 4 0 T h o m a s v i l l e, G A 3 1 7 9 9 2 2 9-2 2 7-7 0 0 0 F A X 2 2 9-2 2 7-3 2 4 3 w w w. t h o m a s v i l l e. o r g REQUEST FOR PROPOSALS PENSION and OPEB CONSULTING SERVICES Proposals
More informationFidelity Guarantee Insurance
Fidelity Guarantee Insurance Policy Wordings Please read this insurance Policy carefully to ensure that you understand the terms and conditions and that this Policy meets your requirements. If there are
More informationKENYA SAFARI LODGES AND HOTELS LIMITED (KSLH) TENDER DOCUMENT FOR REFURBISHMENT WORK AT MOMBASA BEACH HOTEL TENDER NO. MBH/RW/001(A)/
MOMBASA Beach Hotel NGULIA Safari Lodge VOI Safari Lodge KENYA SAFARI LODGES AND HOTELS LIMITED (KSLH) TENDER DOCUMENT FOR REFURBISHMENT WORK AT MOMBASA BEACH HOTEL TENDER NO. MBH/RW/001(A)/2017-2018 KENYA
More informationGOVERNMENT OF GUYANA STANDARD REQUEST FOR PROPOSAL. SELECTION OF CONSULTANTS- Individual
GOVERNMENT OF GUYANA STANDARD REQUEST FOR PROPOSAL SELECTION OF CONSULTANTS- Individual Introduction This Standard Procurement Documentation has been prepared by the NPTA for use by the Procuring Entities
More informationSTANDARD CONDITIONS FOR INDIVIDUAL VOLUNTARY ARRANGEMENTS. Produced by the. Association of Business Recovery Professionals
STANDARD CONDITIONS FOR INDIVIDUAL VOLUNTARY ARRANGEMENTS Produced by the Association of Business Recovery Professionals Version 2 November 2004 TABLE OF CONTENTS FOR STANDARD CONDITIONS 1 INDIVIDUAL VOLUNTARY
More informationDEVELOPER EXTENSION AGREEMENT
DEVELOPER EXTENSION AGREEMENT SILVER LAKE WATER DISTRICT APPLICATION AND AGREEMENT TO CONSTRUCT EXTENSION TO DISTRICT SYSTEM Project: Developer: The undersigned, Developer (also referred to as Owner )
More informationWESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT
WESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT This Equipment Purchase Agreement ( Agreement ) is entered into this day of, 20, by and between the Western Riverside Council of Governments,
More informationREPUBLIC OF KENYA MINISTRY OF LAND AND PHYSICAL PLANNING PROPOSED ERECTION AND COMPLETION OF LAND REGISTRY AT BOMET, BOMET COUNTY
REPUBLIC OF KENYA MINISTRY OF LAND AND PHYSICAL PLANNING PROPOSED ERECTION AND COMPLETION OF LAND REGISTRY AT BOMET, BOMET COUNTY TENDER DOCUMENTS (Main Works) W.P ITEM NO. D111/RV/BOT/1501 JOB NO.10053A
More informationSTANDARD TERMS AND CONDITIONS
STANDARD TERMS AND CONDITIONS 1. Parties to this Agreement 1. In these conditions ( these Conditions ) WPDT means Wilson Power And Distribution Technologies Pvt. Ltd. and Customer means the person entering
More informationWorkforce Management Consulting Services
Request for Proposal #40604 Workforce Management Consulting Services For Grand River Dam Authority PROPOSALS TO BE SUBMITTED TO: Grand River Dam Authority Central Purchasing Unit 226 West Dwain Willis
More informationWhereas the Contractor has entered into an agreement (the "Prime Contract") dated the, 20 with:
SUBCONTRACT Job AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR This subcontract agreement (the "Agreement") made on this day of, 20. between: Aim Waste Management Inc. 400 Jones Road Stoney Creek, ON L8E
More informationSTANDARD TENDER DOCUMENTS FOR PROCUREMENT OF WORKS (MINOR CONTRACTS)
STANDARD TENDER DOCUMENTS FOR PROCUREMENT OF WORKS (MINOR CONTRACTS) National Competitive Tendering (NCT) VOLUME I Tender Reference:. Issue Date: Day/Month/Year Public Procurement Authority Accra, Ghana
More informationSMALL ORDERS TERMS AND CONDITIONS - BLANKET
1. COMPLIANCE WITH LAWS Contractor must observe and comply with all applicable federal, state, county and municipal laws, statutes, regulations, codes, ordinances and executive orders, in effect now or
More informationTHE NATIONAL TREASURY. Republic of South Africa
THE NATIONAL TREASURY Republic of South Africa GOVERNMENT PROCUREMENT: GENERAL CONDITIONS OF CONTRACT July 2010 THE NATIONAL TREASURY: Republic of South Africa 2 TABLE OF CLAUSES 1. Definitions 2. Application
More informationDeluxe Corporation Purchase Terms and Conditions
Deluxe Corporation Purchase Terms and Conditions The following standard purchase terms and conditions only apply to purchasing transactions (including but not limited to purchase orders) that do not have
More informationPROFESSIONAL SERVICES AGREEMENT. For On-Call Services WITNESSETH:
PROFESSIONAL SERVICES AGREEMENT For On-Call Services THIS AGREEMENT is made and entered into this ENTER DAY of ENTER MONTH, ENTER YEAR, in the City of Pleasanton, County of Alameda, State of California,
More informationDRAFT. Herein you will find the following documents; those marked Required need to be returned in order for your subcontract to be processed:
November 10, 2016 «Company» SC #: «Address» JOB # / NAME: «City», «State_» «Zip» PHONE #: «Phone» PROJECT MGR: FAX #: «Fax» PROJECT MGR PHONE #: Enclosed is your Subcontract Agreement with Ghilotti Construction
More informationFATIGUE TECHNOLOGY INC. PURCHASE ORDER TERMS AND CONDITIONS DATED JANUARY 4, 2006
FATIGUE TECHNOLOGY INC. PURCHASE ORDER TERMS AND CONDITIONS DATED JANUARY 4, 2006 1. CONTRACT. Fatigue Technology Inc. s, hereinafter called FTI, purchase order, or change order to a purchase order, collectively
More informationStandard Subcontract
Subcontractor: New York State Fence, Inc. Job Number: 92 Taxpayer ID No.: 16-1098453 THIS AGREEMENT, made this 1 st day of May, 2007 by and between Subcontract Number: 06 New York State Fence, Inc. 858
More informationAGREEMENT BETWEEN THE VENTURA COUNTY TRANSPORTATION COMMISSION AND Conrad LLP FOR PROFESSIONAL SERVICES
AGREEMENT BETWEEN THE VENTURA COUNTY TRANSPORTATION COMMISSION AND Conrad LLP FOR PROFESSIONAL SERVICES This is an agreement ( Agreement ) by and between the Ventura County Transportation Commission, hereinafter
More informationDirectors and Officers Liability and Reimbursement Coverage Part for Condominiums Associations
Declarations POLICY NO. Item 1. Named Insured and Mailing Address: Item 2. Policy Period: From to at 12:01 A.M. Standard Time at the mailing address shown above Item 3. Limits of Liability: Each Loss $
More informationDocument A133 TM. AGREEMENT made as of the day of in the year Two Thousand and Sixteen. BETWEEN the Owner:
Document A133 TM 2009 Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of the Work Plus a Fee with a Guaranteed Maximum Price AGREEMENT
More informationREPUBLIC OF KENYA MINISTRY OF TRANSPORT, INFRASTRUCTURE, HOUSING AND URBAN DEVELOPMENT
REPUBLIC OF KENYA MINISTRY OF TRANSPORT, INFRASTRUCTURE, HOUSING AND URBAN DEVELOPMENT STATE DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT PROPOSED CIVIL SERVANTS HOUSING SCHEME AT EMBU TOWN, EMBU COUNTY
More informationDocument A Standard Form of Agreement Between Contractor and Subcontractor
Document A401 2017 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Contractor: (Name, legal
More informationFOREIGN EXCHANGE TRADING AGREEMENT TERMS AND CONDITIONS
FOREIGN EXCHANGE TRADING AGREEMENT TERMS AND CONDITIONS Foreign Exchange Trading Agreement Between Mercantile Bank Limited, Registration 1965/006706/06 ( the Bank ) and Registration Number ( the Client
More informationUNITED OVERSEAS BANK LIMITED VISA/CO-BRANDED CARDS CARDMEMBER AGREEMENT (INDIVIDUAL)
UNITED OVERSEAS BANK LIMITED VISA/CO-BRANDED CARDS CARDMEMBER AGREEMENT (INDIVIDUAL) IMPORTANT: Please read carefully and understand this Cardmember Agreement before you accept or use any of the credit
More informationSTANDARD CONDITIONS FOR COMPANY VOLUNTARY ARRANGEMENTS
STANDARD CONDITIONS FOR COMPANY VOLUNTARY ARRANGEMENTS One Courtenay Park Newton Abbot Devon. TQ12 2HD www.lameys.co.uk TABLE OF CONTENTS PART I: INTERPRETATION 1 Miscellaneous definitions 2 The conditions
More informationcontract STANDARD PROVISIONS - COMMERCIAL PRODUCTION CONTRACT
contract STANDARD PROVISIONS - COMMERCIAL PRODUCTION CONTRACT 1. Ownership All right, title and interest in and to the commercials and/or advertisements, all negatives, prints, soundtracks and other elements
More informationTERMS AND CONDITIONS OF SALE
TERMS AND CONDITIONS OF SALE 1. DEFINITIONS AND INTERPRETATION 1.1 In these Standard Terms, unless the context or subject matter otherwise requires: (a) Attaches has the meaning given to it in the PPSA;
More informationMORTGAGE TRUST SERVICES PLC. - and - CITICORP TRUSTEE COMPANY LIMITED GHL MORTGAGE SERVICES LIMITED. FIRST FLEXIBLE No. 6 PLC
DATED 29 JANUARY 2004 CONFORMED COPY MORTGAGE TRUST SERVICES PLC - and - CITICORP TRUSTEE COMPANY LIMITED - and - GHL MORTGAGE SERVICES LIMITED - and - FIRST FLEXIBLE No. 6 PLC STANDBY SERVICING AGREEMENT
More informationTRUST AGREEMENT ARTICLE I TRUST FUND
TRUST AGREEMENT Unless the context of this Trust Agreement clearly indicates otherwise, the terms defined in Article 2 of the Plan entered into by the Employer, of which this Trust Agreement forms a part,
More informationEXHIBIT B Terms & Conditions Revised: 10/15/15
EXHIBIT B Terms & Conditions Revised: 10/15/15 Paragraph 1. Payment of Contract Price 1.1 Contract Price shall be paid in accordance with the provisions of this Paragraph 1. Subcontractor shall hold as
More informationREPUBLIC OF KENYA TURKANA COUNTY GOVERNMENT PROPOSED CONSTRUCTION OF BOREHOLE DRILLING SERVICES & EQUIPPING AT TURKANA COUNTY HEADQUARTERS.
REPUBLIC OF KENYA TURKANA COUNTY GOVERNMENT PROPOSED CONSTRUCTION OF BOREHOLE DRILLING SERVICES & EQUIPPING AT TURKANA COUNTY HEADQUARTERS. TENDER NO. TCG/F&P/5/2017-2018 SEPTEMBER 2017 TABLE OF CONTENTS
More informationDear Sirs Date : Country
LETTERS OF GUARANTEE / INDEMNITY APPLICATION: *Indicates mandatory information to be provided_ To : DBS BANK (CHINA) LIMITED ("Bank" or "You", which expression shall include its successors and/or assigns)
More informationMASTER SUBCONTRACT AGREEMENT SUBCONTRACTOR:
CONTRACTOR: Rapid Restoration and Construction Inc. SUBCONTRACTOR: RRC (Contractor)and Subcontractor hereby enter into this Master Subcontract Agreement effective, 2019. This agreement is entered into
More informationRevised GENERAL CONDITIONS (Procurement Contract)
Revised 2005-03-14 GENERAL CONDITIONS (Procurement Contract) INDEX GC1 INTERPRETATION... 1 GC2 ASSIGNMENT AND SUB-LETTING... 2 GC3 CONDUCT OF THE WORK... 2 GC4 PERSONAL INFORMATION AND PRIVACY... 3 GC5
More informationConditions for the Carriage of Goods by Road
Conditions for the Carriage of Goods by Road The Conditions set down the basis on which the Carrier will carry goods for the Customer (definitions of Carrier and Customer are given in Condition 1). The
More information