Contract Administration Final Exam
|
|
- Dwain Johns
- 6 years ago
- Views:
Transcription
1 Contract Administration Final Exam 1. You want to solicit bids for a one year contract for concrete to support your roadway construction work. At this time, prices are fluctuating due to high demand and short supply so no supplier is willing to give you a firm fixed price for the entire year. Which type of contract pricing should you use? a. Fixed price incentive b. Cost plus a fixed fee c. Firm fixed price d. Fixed price with escalation Chap. 3, p The Project Manager has been trying to resolve an issue with the Contractor. The next step in the project is the creation of a test instance. The Project Manager believes it is the Contractor s responsibility to create the test instance in the agency s environment so it will be available for testing by end users. The Contractor claims that he does not have the Application Database Administrator on board to do this and believes this to be the responsibility of the agency. If the Contractor brings an Apps DBA on board, there will be additional charges to the agency covering these costs. The Project Manager insists that test instance creation is the responsibility of the Contractor, and as such, the costs are included in the contract. They are 6 months into the contract. What should the Contract Administrator do? a. Review the SOW and see if you can find the issues they are talking about. b. Listen to their issues and concerns, clarify the SOW in writing and amend the contract as needed. Chap. 3 c. Modify the contract just to get along and to keep the project moving forward. d. Terminate the contract for convenience because they are correct, the contract does not address any of their issues. 3. The supply contract has been awarded to the same contractor who has won this contract in the past. The Project Manager vigorously opposed this award, stating that the contractor did not perform satisfactorily on past contracts. When the Contract Administrator asked for the Project Manager s records to support his statements, the Project Manager could not produce them. What should the Project Manager use to avoid a repeat of this problem? a. Contract Administration Plan b. Performance Assessment Plan Chap. 4, P. 40 c. Contract Closeout Checklist d. Surveillance Techniques Contract Administration 1
2 4. The contract administration phase of a complex turn-key information systems project is in process. The Contractor states that the testing requirements have been met; however, the Project Manager states that the testing requirements have not yet been validated pursuant to the contract. The Contract Administrator is contacted to resolve the issue. What is the first thing that the Contract Administrator should do? a. Request a meeting with the Contractor and the Project Manager to discuss the Contract Administration phase of the project. b. Notify the Contractor that the testing is not complete and that this affects the Performance Assessment Plan (PAP). c. Review the Contract Administration Plan (CAP) to determine any validation requirements and relevant details about testing. Chap. 4 p. 29 d. Suggest that the end-user consider an amendment to the testing section of the scope of work of the contract. 5. The agency has just awarded a contract for cleaning services in the headquarters building. It is very important that the cleaning be done in a professional manner since this is a high visibility area and receives a lot of the senior staff traffic throughout the day. The contract was very detailed as to the standards to be met. What can the Contract Administrator include in the performance assessment plan to ensure compliance with the performance standards? a. Value analysis b. Surveillance techniques Chap. 4, 42 c. Progress meetings d. Final inspections 6. A software description clearly states that it will work on your existing technology platform and accept data from an existing software package your agency uses to collect the necessary data. Unfortunately, you ve installed the software and found that it does not accept the data in the format your existing software package uses. What is the first step to take in seeking a remedy for this situation? a. Notify the contractor that the express warranty has been breached. Chap. 7, pp b. Notify the contractor that the implied warranty has been breached. c. Request administrative relief from the contractor. d. Request injunctive relief from the contractor s attorney. 7. You have a contract to purchase 1,000 3-ring binders for a specific project. The shipment was received and accepted; however, when an employee attempted to use the binders, he found that the rings did not close securely. Which of the following actions is the best to take in this case? a. Reject the binders for patent defects. b. Seek remedy from the contractor for latent defects. Chap. 7, p c. Notify your agency s attorney about a possible case of fraud. d. Negotiate with the vendor to get a discount. Contract Administration 2
3 8. You ve just completed the closeout process for an annual contract for the rental of copiers. Throughout the year you ve kept notes on what issues and problems your agency has experienced. None of the issues and problems has required making any contract changes and has been easily resolved with the contractor. However, you want to ensure that the next time you bid this requirement that you address these issues in the contract. Also, you want to make sure that you are aware of any issues or problems the contractor has had. You ve arranged for a meeting with the contractor and key end-users to discuss the contract and lessons learned. When you finish the current phase of the contract management cycle, what is likely to be the next phase? a. Monitoring performance on the current contract. b. Analysis of the current contract. c. Identifying contract risks and establishing contract goals to manage risks d. Specifying needs for a subsequent solicitation. Chap. 2, p Regarding a service contract you've been administering, the contractor recently presented you with a Request for Equitable Adjustment (REA) for work that was added. Since then, the contractor has not proven to you that he's entitled to an equitable adjustment. What step will you take next? a. Immediately pay the contractor the requested amount because you ve determined that he s entitled to an equitable adjustment. b. Allow the contractor to try to prove the adjustment amount and be prepared to negotiate it. Chap. 8, p. 88 c. Contact the agency's legal staff to arrange for alternative dispute resolution. d. Determine a way to adjust the price downward. 10. In the course of renovating a building, asbestos is discovered. Asbestos was not addressed in the contract. The contractor notified you of this problem and provided a cost estimate for asbestos abatement which the contractor is qualified to perform. You want to make a bilateral modification to the contract to include the abatement work and appropriate insurance coverage. What do you need to do in order to enact this type of modification? a. Put the asbestos abatement project out for competitive bids. b. Verbally notify the contractor to begin the asbestos abatement project. c. Negotiate a price with the contractor and send a summary of the modification to the contractor for review and approval. p d. Prepare a Request for Equitable Adjustment and present it to the contractor. 11. The City just finished negotiations on a $35,000,000 contract for software implementation services. It is expected that it will take three years for the software to be completely installed and accepted. What type of payment mechanism would be the most appropriate? a. Progress payments b. Partial payments c. Milestone payments Chap. 12 d. Completion payment Contract Administration 3
4 12. The city has had a term contract in place for two years. The original term of the contract was for up to three years. Usage of the contract has declined to almost nothing. The city purchasing manager has decided to cancel the contract. Which of the following methods best addresses this action? a. Termination for default b. Issue a show cause notice c. Termination for convenience Chap. 13, p. 147 d. Issue notice of suspension 13. A janitorial firm has repeatedly failed to satisfactorily clean according to the detailed schedule in the contract for the City Hall Annex. The city may terminate the contract for default but it is more interested in motivating contract compliance and performance. What is the city s next step? a. Issue Notice of Termination for Default b. Issue Cure Notice Chap. 13, pp c. Issue Request for liquidated damages d. Notify the contractor of rights to appeal 14. Currently the contractor for janitorial services has not been performing up to the quality standard required under the contract s specification. The Contract Administrator has been working with the project manager to improve the contractor s performance to meet the stated contractual quality standard. The contractor has consistently failed to meet specifications. The Contract Administrator is now ready to terminate for default or breach of contract. He believes that the first step towards termination for default has been met: reasonable grounds. What is the Contract Administrator s next step towards terminating for default? a. Compliance with procedural notification requirements Chap. 13 p. 141 b. Punitive action and stop deliveries c. Stop receiving goods or services and notify the authorities d. A cure notice or a notice of termination 15. A contract has just been completed for maintenance work on the main runway of the County s general aviation airport. The contract required closure of the runway which affected the County s revenue stream. The project was delayed because of inclement weather and a change order was issued extending the term. In addition to the inclement weather, the contractor fell behind for other reasons, and was assessed liquidated damages because the runway was not opened pursuant to the contract. The Contract Administrator is performing contract closeout activities. What is the final step in the contract management cycle for the runway project? a. Prepare a contract compliance statement b. Include the change order documentation in the central file c. Conduct an analysis of the contract administration process Chap. 14, p. 154 d. Verify and document that the assessment of liquidated damages was appropriately handled Contract Administration 4
5 16 At the first meeting of the Contract Administration Committee, a conflict of interest form was signed off by all members of the team. During an evaluation session, the Contracting Officer noticed that the Project Manager continued to score and discuss one submission excessively and was always trying to convince the other members to change their scores. The Contracting Officer met with the Project Manager and discussed the situation. It was discovered that the Project Manager was an employee of the company for two years before coming to the government agency. What steps would you take as the Contract Officer? a. Declare no conflict of interest and continue with the evaluation b. Declare an 'actual conflict of interest' and take immediate action by removing the Project Manager from the evaluation team c. Declare an 'appearance of conflict of interest' and take immediate action by removing the Project Manager from the evaluation team Chap. 5, p. 51 d. Declare a 'potential conflict' and continue with the same evaluation team 17. One day after being advised that the lowest priced bid/tender was being recommended for award because it was both compliant and acceptable, the Project Manager tells you that the agency's consultant for the design and contract administration recommends that the award go to the second bidder. The reason stated did not justify rejecting the lowest priced bid. After you contacted them directly, the consultant still failed to provide sufficient information to justify its recommendation. After contacting the references you discover that the lowest priced bidder has an unresolved claim against the consultant firm and another agency. What should you do? a. Reject the consultant recommendation and award to the lowest acceptable bidder. b. Approve the consultant recommendation and award the contract to the second lowest bidder. c. Declare a conflict of interest with the consultant and rebid the requirement. d. Declare an apparent conflict of interest with the consultant and award the contract to the lowest acceptable bidder. Chap. 5, p On the first day of work the contractor reported that the drawings provided in the solicitation are not 'as built' drawings and the method of construction stated in the scope of work is not appropriate. Not long after the contractor mobilized his labor and equipment the project manager issued a stop work order for two weeks to allow time to evaluate the specifications and drawings. After taking down the scaffolding and de-mobilizing the site the contractor issued an invoice for the cost of the mobilization. The project consultant will not approve the associated costs as the work was stopped and is not complete. The contractor has contacted the purchasing officer to resolve the situation. What would you do? a. Advise the consultant to pay the invoice. b. Request a change order for the additional specification work and determine what costs should be paid. Chap. 8 c. Request a change order notice for the work that was completed and accepted. d. Don't make any payments, as the change order was not properly authorized. Contract Administration 5
6 19 Your entity has just gone through a very complex procurement. You conducted a pre-bid conference, dealt with requirements protests, and successfully closed the solicitation with a total of seven proposers submitting responsive proposals. Your evaluation team has completed the evaluations of all seven proposals and has selected the highest scoring proposal. Your customer concurs that the highest scoring proposal meets the requirements and would like to move forward with the award. What should your next action be? a. Announce the award and schedule debriefs with the unsuccessful proposers. chap. 6, p. 55 b. Announce the award and advise the unsuccessful proposers of their legal rights. c. Develop a performance assessment plan. d. Obtain a conflict of interest statement from each of the evaluators. 20. The final walk through on the project finds many major deficiencies. The Assistant Project Manager calls the Contract Administrator and wants to know what to do first. What should the Contract Administrator advise? a. In the public interest, the government consents to accept the work with an appropriate adjustment in price. b. Terminate the contract and withhold the liquidated damages as a penalty against the contractor. c. Call in the contractor and get the facts on the acceptance and inspection reports. d. Require contractor to without charge, replace or correct defective work found by the government not to conform to the contract requirements. Chap Several large tents were ordered for an outdoor event starting at 6 PM. It is now 4:30, and the Public Affairs Office notifies you that the vendor has not arrived. You immediately contact the vendor who informs you that the tents you requested will not be available in time. The vendor s staff had inadvertently double booked the tents. As the Buyer responsible for this contract, what steps should you take? a. Consider the double booking of the tents as Force Majeure and allow the vendor to deliver the tents as soon as possible. b. Consider the delay as excusable and cancel the contract since the tents won t be delivered on time. c. Try to locate tents from another supplier, if available, and notify the original vendor that the delay is non-excusable. Chap. 10 d. Contact the vendor supplying the tents and inform them that this is considered a compensable delay even though the contract doesn t specifically contain a compensable delay clause. Contract Administration 6
7 22. A contractor is claiming that he had to spend $1,000 for additional materials not specified in the contract that were necessary for him to complete the contract successfully. The claim letter is dated two months prior and has been sitting inadvertently on the purchasing manager s desk under a pile of papers. Your disputes and appeals administrative process states that all claims and disputes will be decided within 30 days after receipt. This is clearly more than 30 days. How does this affect the claim? a. The contractor can construe the failure to respond as a denial of the claim and proceed with an appeal. Chap. 11 b. The contractor must resubmit the claim within 7 days after the 30-day period expires. c. The purchasing manager is obligated to resolve the claim in the contractor s favor as a result of the delay. d. The contractor is required to prove that his claim is now two months old prior to taking any further action with regard to the claim. 23. Your agency recently prepared what was believed to be a thorough Request for Proposals (RFP) for a new software program. The RFP was advertised, a pre-proposal conference was held and there appeared to be significant interest from software providers. On the day proposals were due, only one proposal was received. The Purchasing Department was left wondering what went wrong. After contacting several of the companies who attended the pre-proposal conference, it was determined that the main concern dealt with technical data rights. What was the most likely reason that only one proposal was received? a. The IT Department had already decided with whom they wanted to contract. b. The specifications stated that your agency has unlimited data rights. Chap. 9 c. The software companies wanted unlimited access to your agency s technical data. d. The software companies want to provide a complete software system, not just one program module. 24. A construction project to resurface a runway and taxiway at the municipal airport experienced significant delays for a various number of reasons. The contractor is blaming the city and is seeking additional construction days added to the contract, as well as additional compensation. The contractor is threatening to file a lawsuit if the demands are not met. Documentation supports the city s position that it bears no blame for the delays. As the contracts administrator, what should you do? a. Let the contractor know that there is no basis for the claim and to go ahead and file a lawsuit. b. Consent to allowing for additional contract days and increase the contract amount to allow for additional compensation. c. Agree to arbitration and stipulate that both parties will be bound by the decision of a third party. Chap. 11 d. Negotiate with the contractor and give them additional work at the airport if they will withdraw their demands. Contract Administration 7
8 25. Your agency has awarded a software contract to I.T. Go Home Software, Inc. Given the complexity of the new software system, it will require 18 months to complete the installation. You have been assigned as the Contracts Administrator for this project. You received and have reviewed the schedule and milestones. This is a large dollar, high visibility project with a critical completion date deadline. What should you do? a. Rely on the software vendor s installation schedule because it shows milestones and a completion date which is within the contract completion deadline. b. Schedule a site visit to the software vendor s facility, with follow-up visits to other existing users of the software. c. Assign a staff member to assist with the installation process. d. Ensure that the monthly progress reports are submitted and the watch list and action items are addressed. Chap. 9 Contract Administration 8
Slide 1. Slide 2. Slide 3 LEARNING OBJECTIVES WHAT S THE DIFFERENCE? PERSONAL AND PROFESSIONAL EXCELLENCE
Slide 1 PERSONAL AND PROFESSIONAL EXCELLENCE Contract Administration Beginning With the End in Mind David E. Nash, CPPO, CPPB 50 TH ANNUAL CONFERENCE MAY 24-27, 2017 ORLANDO, FLORIDA Slide 2 LEARNING OBJECTIVES
More informationWebinar: Making the Right Choices in Government Contracting Part 3
Public Contracting Institute LLC Webinar: Making the Right Choices in Government Contracting Part 3 Presented by Richard D. Lieberman, FAR Consultant, Website: www.richarddlieberman.com. Email rliebermanconsultant@gmail.com.
More informationCOUNTY OF COLE JEFFERSON CITY, MISSOURI
COUNTY OF COLE JEFFERSON CITY, MISSOURI REQUEST FOR BID 2018-33: PROPANE PROVISION & SERVICES SUBMISSIONS SHALL BE ACCEPTED UNTIL THURSDAY, AUGUST 23 at 3:30 p.m. Central AND RECEIVED AT: COLE COUNTY COMMISSION
More informationStandard Form of Agreement Between Contractor and Subcontractor
Standard Form of Agreement Between Contractor and Subcontractor GENERAL TERMS AND CONDITIONS ARTICLE 1 THE SUBCONTRACT DOCUMENTS 1.1 The Subcontract Documents consist of (1) these General Terms and Conditions,
More informationRFP GENERAL TERMS AND CONDITIONS
RFP GENERAL TERMS AND CONDITIONS PUBLIC RECORD After an award is made, copies of the proposals will be available for public inspection, under the supervision of the City's Finance Department from 8:00
More informationREQUEST FOR QUOTE # 16471
REQUEST FOR QUOTE # 16471 RFQ # 16471 Quotation Due By: Bid Due Time: 12/13/2013 10:00:00 AM VENDOR INFO: VENDOR #: 99999.00 NAME: CONTACT: ADDRESS 1: ADDRESS 2: CITY: STATE: ZIP: EMAIL: PHONE: FAX: REPLY
More informationREQUEST FOR PROPOSAL FOR. Full Cost Allocation Plan and Citywide User Fee and Rate Study. Finance Department CITY OF HUNTINGTON BEACH
REQUEST FOR PROPOSAL FOR Full Cost Allocation Plan and Citywide User Fee and Rate Study Finance Department CITY OF HUNTINGTON BEACH Released on October 17, 2007 Full Cost Allocation Plan and Citywide User
More informationWHITFIELD COUNTY, GEORGIA PURCHASING POLICY AND MANUAL January 14, 2014
1 WHITFIELD COUNTY, GEORGIA PURCHASING POLICY AND MANUAL January 14, 2014 WHITFIELD COUNTY, GEORGIA PURCHASING POLICY AND MANUAL TABLE OF CONTENTS Purchasing Policy Introduction... 3 Policy Specifics...
More informationSession 10 and 11 EXECUTING THE WORK & CLAIMS AND DISPUTES
Audio Sessions Session 10 and 11 EXECUTING THE WORK & CLAIMS AND DISPUTES Education Program Certified Construction Contract Administrator (CCCA) Preparatory Course 2011 www.csinet.org This presentation
More informationDocument A General Conditions of the Contract for Construction, Construction Manager as Adviser Edition
Document A232 2009 General Conditions of the Contract for Construction, Construction Manager as Adviser Edition for the following PROJECT: (Name, and location or address) THE CONSTRUCTION MANAGER: (Name,
More informationWINDSOR NORTH WEST PARK NATURE CENTER ADDITION AND STRUCTURE PROJECT 145 LANG ROAD. WINDSOR, CT
INVITATION TO BID Contractor Services Associated with: WINDSOR NORTH WEST PARK NATURE CENTER ADDITION AND STRUCTURE PROJECT 145 LANG ROAD. WINDSOR, CT 06095 THIS IS AN INVITATION FOR BIDS AND THE TOWN
More informationCHARTERED INSTITUTE OF ARBITRATORS NEC compensation events A process for all eventualities? April 21 st 2016
CHARTERED INSTITUTE OF ARBITRATORS NEC compensation events A process for all eventualities? April 21 st 2016 SARAH KELLERMAN PARTNER m +44 (0) 7810 850 387 e sarah.kellerman@arcadis.com Arcadis Arcadis,
More informationARTICLE 8: BASIC SERVICES
THE SCOPE OF SERVICES ADDED BY THIS AMENDMENT IS FOR A CM AT RISK PROJECT ONLY. THE SCOPE OF SERVICES SPECIFIED BELOW INCLUDES ARTICLES 8.1, 8.3, 8.4, 8.5, 8.6, 8.7 AND 8.8. THE SERVICES SPECIFIED IN ARTICLE
More informationREQUEST FOR PROPOSAL MOBILE AND ONLINE CITIZEN ENGAGEMENT SOLUTION
REQUEST FOR PROPOSAL MOBILE AND ONLINE CITIZEN ENGAGEMENT SOLUTION The Town of Windsor is requesting proposals from qualified firms to provide and host an array of mobile and online public engagement and
More informationTO THE MEMBERS OF THE COMMITTEES ON GROUNDS AND BUILDINGS AND FINANCE: DISCUSSION ITEM EXECUTIVE SUMMARY
Office of the President J1 TO THE MEMBERS OF THE COMMITTEES ON AND FINANCE: DISCUSSION ITEM For the Meeting of UPDATE ON THE 2020 PROJECT, MERCED CAMPUS EXECUTIVE SUMMARY This item provides an overview
More informationIn order to implement these measures the parties enter into this framework agreement (hereinafter referred to as FRAMEWORK AGREEMENT).
Framework Agreement between GAUDLITZ GmbH Callenberger Strasse. 42 D- 96450 Coburg (hereinafter referred to as GA) and (hereinafter referred to as Supplier) 1. Preamble GAUDLITZ is interested in obtaining
More informationGeneral Conditions for Construction GCC201. Contract Type: Document No. for the following PROJECT: (Name and location or address) EXAMPLE
Page 1 of 37 for the following PROJECT: (Name and location or address) EXAMPLE THE OWNER: (Name and address) Example, THE ARCHITECT: (Name and address) TABLE OF ARTICLES 1 GENERAL PROVISIONS 2 OWNER 3
More informationTERM CONTRACT AWARD CONTRACT NO:
2 4 COMMODITY CODE: 285-93-00-047498 0.000 4.0000 % 5 COMMODITY CODE: 285-93-00-047498 0.000 5.0000 % 6 COMMODITY CODE: 285-93-00-047498 0.000 6.0000 % 7 COMMODITY CODE: 285-93-00-047498 1.000 7.0000 %
More informationIFB F B-WING RENOVATIONS IFB F C OFFICES BUILD OUT. Addendum 3
JUNE 23, 2016 ATTENTION ALL PROPONENTS: IFB F2015017 B-WING RENOVATIONS IFB F2015007 9C OFFICES BUILD OUT Addendum 3 The purpose of this Amendment is to advise all offertories of the following: 1. In Project
More informationSECTION 2 - STANDARD TERMS & CONDITIONS
SECTION 2 - STANDARD TERMS & CONDITIONS 1. Genesee County Purchasing Regulations: All procurements are conducted in accordance with the Genesee County Purchasing Regulations, a copy of which is on file
More informationRequest for Proposal Kelowna Office Renovation. Request for Proposals (RFP)
Request for Proposals (RFP) Scope of Service RFP # RFP issued by Kelowna Office Renovation 2018RFP-25 First Nations Health Authority (FNHA) Issue date October 20, 2017 Closing date/time FNHA Contact Information
More informationStandard Form of Agreement Between OWNER AND CONSTRUCTION MANAGER Construction Manager At-Risk
CMAA Document CMAR-1 Standard Form of Agreement Between OWNER AND CONSTRUCTION MANAGER Construction Manager At-Risk 2004 EDITION This document is to be used in connection with CMAA Standard Form of Contract
More informationCONTRACT TERMS AND CONDITIONS: PURCHASE OF MATERIALS (NOT TO EXCEED $300,000 VALUE)
CONTRACT TERMS AND CONDITIONS: PURCHASE OF MATERIALS (NOT TO EXCEED $300,000 VALUE) 1. DELIVERABLES Contractor agrees to provide the goods, equipment, or items ( Materials ) detailed in the work scope
More informationARCHIVED - MAY 20, 2014
TEXAS POLICY In Texas, organizations contracting directly with the Texas Department of Agriculture (TDA) to operate nutrition programs federally funded through the United States Department of Agriculture
More informationProcurement of Licences of Business Objects BI Platform
RESERVE BANK OF INDIA Request For Proposal (RFP) For Procurement of Licences of Business Objects BI Platform Date of Issue: January 25, 2016 Department of Statistics and Information Management Reserve
More informationSection 7000 Procurement
Section 7000 Procurement Table of Contents 7100 Conflicts of Interest 7110 Conduct of Employees 7200 Procurement Methods 7210 Small Purchase 7220 Competitive Sealed Bids 7230 Competitive Negotiation 7240
More informationHome Improvement Contract Contractor Any Notice of Cancellation can be sent to this address. Owner
Home Improvement Contract This agreement is made by (Contractor) and (Owner) on the date written beside our signatures. Contractor Any Notice of Cancellation can be sent to this address. City, Zip Work
More informationTrends and Developments in Public Works Law and Practice
Trends and Developments in Public Works Law and Practice APWA Public Works Conference 2015 Presented by: Arne B. Sandberg, Lozano Smith Ron Bernal, City of Antioch INTRODUCTION New ADR Requirements for
More informationHULL & COMPANY, INC. DBA: Hull & Company MacDuff E&S Insurance Brokers PRODUCER AGREEMENT
HULL & COMPANY, INC. DBA: Hull & Company MacDuff E&S Insurance Brokers PRODUCER AGREEMENT THIS PRODUCER AGREEMENT (this Agreement ), dated as of, 20, is made and entered into by and between Hull & Company,
More informationUNITED STATES AND CANADA TERMS AND CONDITIONS OF SALE NOVEMBER 2006
UNITED STATES AND CANADA TERMS AND CONDITIONS OF SALE NOVEMBER 2006 1 Definitions Invoice means the invoice issued by the Supplier which described the Products purchased by the Purchaser and which includes,
More informationCAR 7-1 PURCHASING REGULATION CAR 7-1 OPR: Finance 4/90 (Revised 2/10)
CAR 7-1 PURCHASING REGULATION CAR 7-1 OPR: Finance 4/90 (Revised 2/10) Purpose Section I Scope II Definitions III Responsibility IV Using Department IV A Purchasing Function IV B Property Disposal V I.
More informationDocument A201 TM 2007 SP
AIA Document A201 TM 2007 SP General Conditions of the Contract for Construction, for use on a Sustainable Project for the following PROJECT: (Name and location or address) THE OWNER: (Name, legal status
More informationDESERT COMMUNITY COLLEGE DISTRICT General Terms and Conditions
DESERT COMMUNITY COLLEGE DISTRICT www.collegeofthedesert.edu General Terms and Conditions 1. PURCHASE ORDER DEFINED: The term purchase order as used in these terms conditions means the document entitled
More informationGerman General Purchasing Conditions
Translation of the EGELHOF German General Purchasing Conditions 1 Scope We will place orders based exclusively on our General Purchasing Conditions in the version that is in effect at the time. Agreements
More informationCITY OF COVINGTON REQUEST FOR PROPOSAL HURRICANE ISAAC VEGETATIVE DEBRIS REDUCTION & TRANSPORTATION
CITY OF COVINGTON REQUEST FOR PROPOSAL HURRICANE ISAAC VEGETATIVE DEBRIS REDUCTION & TRANSPORTATION OVERVIEW The City of Covington is soliciting proposals for the reduction of Hurricane Isaac vegetative
More informationConstruction Management Contract This agreement is made by (Contractor) and (Owner) on the date written beside our signatures.
Construction Management Contract This agreement is made by (Contractor) and (Owner) on the date written beside our signatures. Contractor Address Address City, Zip Work Phone Number: Cell Phone Number:
More informationLEGAL NOTICE CITY OF ANSONIA, CONNECTICUT REQUEST FOR PROPOSALS
LEGAL NOTICE CITY OF ANSONIA, CONNECTICUT REQUEST FOR PROPOSALS FOR THE INSTALLATION OF BARRIER GATES, DUMPSTER ENCLOSURES, BOLLARDS, AND A CANTILEVER GATE FOR ANSONIA PUBLIC SCHOOLS ANSONIA, CONNECTICUT
More informationHALIFAX REGIONAL WATER COMMISSION PROCUREMENT POLICY. Edited May 22, 2012
HALIFAX REGIONAL WATER COMMISSION PROCUREMENT POLICY Edited May 22, 2012 May 1, 1997 Table of Contents 1. POLICY STATEMENT... 3 2. GUIDING PRINCIPLES... 3 3. DEFINITIONS... 4 4. GENERAL... 4 5. AUTHORITY
More informationGENERAL CONDITIONS AND INSTRUCTIONS TO BIDDERS FOR STATEWIDE CONTRACTS FOR SERVICES
Department of General Services GSPUR-11D Rev. 1/17/03 GENERAL CONDITIONS AND INSTRUCTIONS TO BIDDERS FOR STATEWIDE CONTRACTS FOR SERVICES 1. SUBMISSIONS OF BIDS: a. Bids are requested for the item(s) described
More information7/14/16. Hendry County Purchase Order Terms and Conditions
Hendry County Purchase Order Terms and Conditions 1. Offer The order set forth in the Purchase Order is subject to cancellation by HENDRY COUNTY without notice if not accepted by VENDOR within fourteen
More informationTERMS AND CONDITIONS. 5. Retroactive amendments and additions to the contract require written confirmation to become valid.
TERMS AND CONDITIONS I. A R E A O F A P P L I C A B I L I T Y: 1. There are no gummy bears living in the wild. You buy them in packs at the movie theater. This purchase is the beginning of an almost erotic
More informationRolling Plains Management Corporation 118 North First Street P.O. Box 490 Crowell, Texas REQUEST FOR PROPOSALS FOR
Rolling Plains Management Corporation 118 North First Street P.O. Box 490 Crowell, Texas 79227 REQUEST FOR PROPOSALS FOR CONTRACTORS FOR THE AMY YOUNG BARRIER REMOVAL PROGRAM July 30, 2018 1 TABLE OF CONTENTS
More informationAPPLICATION FOR PRE-QUALIFICATION OF GENERAL CONTRACTORS FOR NORTH ORANGE COUNTY COMMUNITY COLLEGE DISTRICT
APPLICATION FOR PRE-QUALIFICATION OF GENERAL CONTRACTORS FOR NORTH ORANGE COUNTY COMMUNITY COLLEGE DISTRICT NORTH ORANGE COUNTY COMMUNICTION COLLEGE DISTRICT PURCHASING DEPARTMENT 1830 WEST ROMNEYA DR.
More informationLATITUDE ENGINEERING - GENERAL TERMS OF SALE
1. General Scope LATITUDE ENGINEERING - GENERAL TERMS OF SALE These General Terms of Sale ( Terms ), together with the terms and conditions set forth on the purchase order form ( Order Form ) (collectively
More informationThe Bidding Game: Contractors and Contracts. A seminar for Association Managers and HOA Directors, Presented by Carl Brown, RCI, RRO
The Bidding Game: Contractors and Contracts A seminar for Association Managers and HOA Directors, Presented by Carl Brown, RCI, RRO Bidding is a Game of Strategy Many Contractors are experts at bidding
More informationVendor Contract TERMS AND CONDITIONS OF PURCHASE. 2. Payment Terms. Payment to Seller is subject to compliance with the following requirements:
Vendor Contract TERMS AND CONDITIONS OF PURCHASE 1. Acceptance. This Contract is conditional upon, and can be accepted only upon, the terms and conditions specified in this Contract. If Seller has previously
More informationCooper Heat Treating LLC Terms and Conditions of Order Effective April 2, 2013
1. DEFINITIONS - The terms defined in this paragraph shall have the meanings set forth below: 1.1. Customer means Cooper Heat Treating LLC. 1.2. Order means this written Purchase Order between Customer
More informationSUPPLIER - TERMS AND CONDITIONS Materials and Goods
SUPPLIER - TERMS AND CONDITIONS Materials and Goods 1. BINDING EFFECT; ACCEPTANCE. This purchase order and all subsequent purchase orders delivered by Buyer to Seller (each, an "order"), shall be governed
More informationPurchasing Card Program
University Of North Alabama Purchasing Card Program User Guidelines University of North Alabama Procurement Department Created: March 2008 University of North Alabama Purchasing Card Program 1 Table of
More informationHome Renovations and Repair
Home Renovations and Repair June 2005 This tipsheet is intended to provide general information and is not a substitute for legal advice. This tipsheet has two parts: general information about hiring any
More informationEXHIBIT A ONE-TIME-ACQUISITION STATEMENT OF WORK. IT General Provisions
EXHIBIT A ONE-TIME-ACQUISITION STATEMENT OF WORK IT General Provisions This Statement of Work ( Agreement ) reflects the change to General Provisions, GSPD-401- IT Commodities, as required for the California
More informationForce Vector, Inc. Master Contract for Sales of Goods and Services
Force Vector, Inc. Master Contract for Sales of Goods and Services 1. Force Vector s Business. Force Vector, Inc., an Illinois corporation ( Force Vector ) sells various industrial goods as a reseller
More informationINSTRUCTIONS TO BIDDERS
11/21/2011 HENNEPIN COUNTY PURCHASING INSTRUCTIONS TO BIDDERS TABLE OF CONTENTS 1. DEFINITIONS...1 2. BIDDER'S PREBID DOCUMENT REVIEW...2 2.1. Availability of Documents 2 2.2. Interpretation or Correction
More informationCity of Columbia Community Development Department 1225 Lady St., Suite 102 Columbia, SC NOTE: May be printed on agency letterhead
City of Columbia Community Development Department 1225 Lady St., Suite 102 Columbia, SC 29201 NOTE: May be printed on agency letterhead Request for Proposal (Consultant Services) RFP Number: RFP-CD01-10115
More informationCHARTER TOWNSHIP OF WEST BLOOMFIELD INVITATION TO BID WEST BLOOMFIELD, FACILITY OPERATIONS
CHARTER TOWNSHIP OF WEST BLOOMFIELD INVITATION TO BID WEST BLOOMFIELD, FACILITY OPERATIONS REPAIR PARKING LOT SEAL COATING TOWN HALL & POLICE DEPARTMENT BID: 03182019: DEADLINE: Thursday, April 11, 2019,
More informationNEW YORK LIQUIDATION BUREAU REQUEST FOR PROPOSAL
NEW YORK LIQUIDATION BUREAU REQUEST FOR PROPOSAL DOCUMENT SHREDDING February 26, 2015 The New York Liquidation Bureau ( NYLB ) carries out the responsibilities of the Superintendent of Financial Services
More informationRequest for Quotation Page One
Request for Quotation Page One THIS IS NOT AN ORDER Purchasing Department 1600 Hampton Street, Suite 606 Columbia, SC 29208 (803) 777-4115 Quotation must be received no later than: 02:00 PM Send Quotation
More informationRequest for Proposal RFP # SUBJECT: Ergotron LX
Request for Proposal RFP #13-1422 SUBJECT: Ergotron LX DATE OF ISSUE: July 3, 2013 TO RESPOND BY: RESPOND TO: July 19, 2013 @ 1500 Hours (3:00 PM Pacific Time) Leslie Burke, Purchasing Agent Purchasing
More informationREQUEST FOR PROPOSALS MICHIGAN ECONOMIC DEVELOPMENT CORPORATION TRANSFORMATIONAL BROWNFIELD REDEVELOPMENT PROJECTS RFP-CASE
REQUEST FOR PROPOSALS MICHIGAN ECONOMIC DEVELOPMENT CORPORATION TRANSFORMATIONAL BROWNFIELD REDEVELOPMENT PROJECTS RFP-CASE-211899 i REMINDER Please check your proposal to make sure you have included all
More informationDocument A201 TM. General Conditions of the Contract for Construction
Document A201 TM 2007 General Conditions of the Contract for Construction for the following PROJECT: Proposed Renovations to a Portion of the Township Municipal Building 175 West Valley Forge Road King
More informationHOUSING AUTHORITY OF THE CITY OF TULSA
HOUSING AUTHORITY OF THE CITY OF TULSA 415 EAST INDEPENDENCE TULSA, OKLAHOMA 74106 REQUEST FOR PROPOSALS FOR PROFESSIONAL INSURANCE BROKERAGE AND ALL RELATED CONSULTING SERVICES RFP #18-081 Proposal Deadline:
More informationMultiple Structure Asbestos Abatement and Demolition Project
REQUEST FOR BID and PROJECT PROPOSAL Multiple Structure Asbestos Abatement and Demolition Project Proposal Due Date: May 9, 2016 2:00 p.m. TABLE OF CONTENTS I. Introduction II. III. IV. RFP Timeline Scope
More informationONE-TIME CLOSE CONSTRUCTION LOAN INFORMATION PACKET
ONE-TIME CLOSE CONSTRUCTION LOAN INFORMATION PACKET At AmeriFirst we are committed to providing you with all the information you need regarding your construction loan. This guide will walk you through
More informationACA UNIFORM TERMS AND CONDITIONS
ACA UNIFORM TERMS AND CONDITIONS ARIZONA COMMERCE AUTHORITY (ACA) UNIFORM TERMS AND CONDITIONS 1. Definition of Terms As used in this Solicitation and any resulting Contract, the terms listed below are
More informationAUCTION TERMS FOR F&O DEFAULT AUCTIONS INDEX
AUCTION TERMS FOR F&O DEFAULT AUCTIONS INDEX 1. INTRODUCTION... 2 2. THE AUCTION PROCESS... 4 3. THE BIDDING PROCESS... 6 4. PARTICIPATION BY CUSTOMERS AND SPONSORED PRINCIPALS IN THE AUCTION... 7 5. SELECTION
More informationFATIGUE TECHNOLOGY INC. PURCHASE ORDER TERMS AND CONDITIONS DATED JANUARY 4, 2006
FATIGUE TECHNOLOGY INC. PURCHASE ORDER TERMS AND CONDITIONS DATED JANUARY 4, 2006 1. CONTRACT. Fatigue Technology Inc. s, hereinafter called FTI, purchase order, or change order to a purchase order, collectively
More informationAIA Document A201 TM 1997
AIA Document A201 TM 1997 General Conditions of the Contract for Construction for the following PROJECT: (Name and location or address): A201 conversion Michigan State University East Lansing, MI THE OWNER:
More informationMAINTENANCE CONTRACT ADMINISTRATION, INSPECTION, AND REPORTING
Approved: Effective: December 22, 2017 Review: October 10, 2017 Office: Maintenance Topic No.: 375-020-002-l Department of Transportation PURPOSE: MAINTENANCE CONTRACT ADMINISTRATION, INSPECTION, AND REPORTING
More informationAIA Document A201 TM 1997
AIA Document A201 TM 1997 General Conditions of the Contract for Construction for the following PROJECT: (Name and location or address): Project University of Maine at Farmington THE OWNER: (Name and address):
More informationPROCUREMENT CODE. Part A Authority to Bind County to a Contract
PROCUREMENT CODE ARTICLE 4 CONTRACT FORMATION Part A Authority to Bind County to a Contract 4-101 Authorization By Dollar Amount. Regardless of the acquisition or disposal method to be used, the level
More informationAGREEMENT FOR CONSTRUCTION PROJECT MANAGEMENT SERVICES
AGREEMENT FOR CONSTRUCTION PROJECT MANAGEMENT SERVICES THIS AGREEMENT is made by and between the School District, a political subdivision of the State of California ("DISTRICT"), and, a California corporation,
More informationGozo Channel Company Limited The Brokerage, Level 2, St. Martha Street, Victoria, Gozo
DEPT. REF: CONCESSION FOR THE PROVISION OF ADVERTISING SERVICES ON COMPANY PRE-PRINTED FERRY TICKETS Date Published: 7 November 2014 Closing Date: 5 December 2014 at 10:00am CET IMPORTANT: Free of Charge
More informationMunicipal Small Cities Housing Rehabilitation Program CONTRACTOR ORIENTATION
Municipal Small Cities Housing Rehabilitation Program CONTRACTOR ORIENTATION $300,000 housing rehabilitation grant minority, women s, disabled, and Section 3 contracting businesses encouraged to apply
More informationREQUEST FOR PROPOSAL. PIKES PEAK LIBRARY DISTRICT Colorado Springs, CO
REQUEST FOR PROPOSAL For 21c Roof Replacement PIKES PEAK LIBRARY DISTRICT Colorado Springs, CO PPLD RFP # 490-18-05 The Pikes Peak Library District (PPLD) invites qualified Roofing Contractors (The Company
More informationtransmitted to or from Company. Customer may not provide Services to End Users without consent of both Company and the End User.
Terms and Conditions Shipment Auditing Agreement. We may amend this Agreement at any time by posting a revised version on our website. The revised version is effective and active at the time of posting.
More informationREQUEST FOR TENDER No GENERAL INSURANCE BROKERAGE SERVICES FOR PROPERTY, BOILER & MACHINERY and CRIME
REQUEST FOR TENDER No. 1717 GENERAL INSURANCE BROKERAGE SERVICES FOR PROPERTY, BOILER & MACHINERY and CRIME Issue date: February 10, 2016 Closing location: Purchasing Department 2020 Labieux Road Nanaimo,
More informationDocument A401 TM. Standard Form of Agreement Between Contractor and Subcontractor
Document A401 TM 2017 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Contractor: (Name,
More informationTexas Automobile Insurance Plan Association (TAIPA) Request for Proposal for Actuarial Services
Texas Automobile Insurance Plan Association (TAIPA) Request for Proposal for Actuarial Services TAIPA is soliciting proposals from qualified actuarial firms, to develop insurance rate filings for automobile
More informationCommon Glossary of Procurement Terms
Common Glossary of Procurement Terms Term arbitration award best and final offer bid bid security (bid bond) bidder, proposer, offeror bill of lading bill of quantities blanket purchase order A method
More informationFEDERAL CONSTRUCTION PROJECT MANAGER S BULLETIN Devoted exclusively to problems encountered while performing Government construction contracts
FEDERAL CONSTRUCTION PROJECT MANAGER S BULLETIN Devoted exclusively to problems encountered while performing Government construction contracts Volume II Number 21 ENFORCEABILITY OF CONTRACTS Readers of
More informationAIA Document A201 TM 2007
AIA Document A201 TM 2007 General Conditions of the Contract for Construction for the following PROJECT: (Name and location or address) Pre-Construction and Construction Management at Risk Services Lafayette
More informationRenville County Purchasing Procedures (Procurement Policy)
Renville County Purchasing Procedures (Procurement Policy) Board approved 11-15-2016 1 RENVILLE COUNTY PURCHASING PROCEDURES I. Purchasing/Procurement Approval Requirements All employees authorized to
More information6 Critical Documents You Need
Preview Of What You Will Learn Sections: Introduction...5 #1 - Independent Contractor Agreement...7 #2 - Final Scope of Work...9 #3 - Payment Schedule...10 #4 - Insurance Indemnification Agreement...12
More informationConstruction Law Survival Manual. Credit Management Contract Terms.
1 Credit Management Contract Terms Presented by James D. Fullerton www.fullertonlaw.com JFullerton@FullertonLaw.com James D. Fullerton Fullerton & Knowles, P.C. 12642 Chapel Rd. Clifton, VA 20124 (703)
More informationByte Paradigm General Conditions ( Design version)
Byte Paradigm General Conditions ( Design version) Article I General 1. When these General Conditions for Delivery are part of tenders and agreements concerning the performance of deliveries and/or services
More informationGRAND RIVER DAM AUTHORITY REQUEST FOR QUOTE # 11135
REQUEST FOR QUOTE # 11135 RFQ # 11135 Quotation Due By: 08/08/2012 10:00 AM CT REPLY TO: MK Monica Fowler PURCHASING DEPARTMENT 226 W DWAIN WILLIS AVE TO: PROVIDE COMPANY NAME, ADDRESS, E-MAIL PO BOX 409
More informationSand Purchase for Golf Course Bunker Renovation. Hoffman Estates Park District
Hoffman Estates Park District BID DATE: 12/5/16 BID TIME: 10am CST PREPARED BY: Brian Bechtold Director of Golf Operations 847-781-3679 HOFFMAN ESTATES PARK DISTRICT 1685 W. Higgins Road Hoffman Estates
More informationATTACHMENT I - TELEDYNE BROWN
Sheet 1 of 5 ATTACHMENT I - TELEDYNE BROWN ENGINEERING, INC. TERMS AND CONDITIONS - COMMERCIAL PROCUREMENTS FEBRUARY 2011 GENERAL Acknowledgment, shipment, or performance of any part of this purchase order
More informationGeneral Terms and Conditions
General Terms and Conditions 1. Scope of application 1.1. These General terms and Conditions GTC shall apply in the relationship between CAMOplus GmbH (hereinafter CAMOPLUS ) and natural and legal persons
More informationWINDSOR HIGH SCHOOL POOL HOUSE HVAC UNIT REPLACEMENT PROJECT 50 SAGE PARK ROAD. WINDSOR, CT
INVITATION TO BID Contractor Services Associated with: WINDSOR HIGH SCHOOL POOL HOUSE HVAC UNIT REPLACEMENT PROJECT 50 SAGE PARK ROAD. WINDSOR, CT 06095 THIS IS AN INVITATION FOR BIDS AND THE TOWN RESERVES
More informationSuccessfully Crafting and Prosecuting Contract Disputes Act Claims Against the Government
Successfully Crafting and Prosecuting Contract Disputes Act Claims Against the Government Webinar July 28, 2015 Sandy Hoe shoe@cov.com 202-662-5394 Justin Ganderson jganderson@cov.com 202-662-5422 Agenda
More informationFIRM FIXED PRICE TERMS AND CONDITIONS AES-1 Applicable to Architect-Engineering Services Contracts INDEX CLAUSE NUMBER TITLE PAGE
Applicable to Architect-Engineering Services Contracts INDEX CLAUSE NUMBER TITLE PAGE 1. DEFINITIONS 1 2. COMPOSITION OF THE ARCHITECT-ENGINEER 1 3. INDEPENDENT CONTRACTOR 1 4. RESPONSIBILITY OF THE ARCHETECT-ENGINEER
More informationTAMUS Contract Review Guidelines and Checklist. Does Contract Require Review by TAMUS Office of General Counsel ( OGC )? Yes No
TAMUS Contract Review Guidelines and Checklist [Member] Department: Vendor/Contractor: Dept. Contact: Vendor/Contractor Contact: Contact #: Contact #: Contract Effective Date: Contract Expiration Date:
More informationMANDATORY GENERAL TERMS AND CONDITIONS:
MANDATORY GENERAL TERMS AND CONDITIONS: A. PURCHASING MANUAL: This solicitation is subject to the provisions of the College s Purchasing Manual for Institutions of Higher Education and their Vendors and
More informatione.com-cert Ltd. General business conditions and certification rules
Area of validity Current regulation details the general business and certification conditions of e.com-cert Ltd. which is deemed obligatory to itself, and handled as contractual agreement towards its partners.
More informationECOMMERCE PRODUCT TERMS
ECOMMERCE PRODUCT TERMS E-Commerce Services are provided by NETSTARTER PTY LTD ABN 28 110 067 96 of Level 3, 116 Miller Street, North Sydney, New South Wales, 2060 pursuant to the General Terms and the
More informationNOTICE OF REQUEST FOR PROPOSALS TOWN OF CHAPEL HILL, NORTH CAROLINA FOR DOWNTOWN MUNICIPAL SERVICE DISTRICT (MSD) SERVICES
NOTICE OF REQUEST FOR PROPOSALS TOWN OF CHAPEL HILL, NORTH CAROLINA FOR DOWNTOWN MUNICIPAL SERVICE DISTRICT (MSD) SERVICES DATE: April 8, 2016 PROPOSAL: Q16-131 The Town of Chapel Hill Business Management
More informationACA UNIFORM TERMS AND CONDITIONS
ACA UNIFORM TERMS AND CONDITIONS 1. Definition of Terms As used in this Solicitation and any resulting Contract, the terms listed below are defined as follows: 1.1. ACA means the Arizona Commerce Authority.
More informationCustomer, you, your the person (whether a business customer or a consumer) who has accepted and signed this Form of Acceptance
Changes to the Terms of Business We may revise these Terms at any time at our sole discretion. You can check when these Terms were last updated by checking the date at the top of the Terms. If we make
More informationTOWN OF PEMBROKE PARK REQUEST FOR QUALIFICATIONS. To Provide Solid Waste Franchise Financial Auditor Services for the Town of Pembroke Park
TOWN OF PEMBROKE PARK REQUEST FOR QUALIFICATIONS To Provide Solid Waste Franchise Financial Auditor Services for the Town of Pembroke Park Issued By: Town Manager 3150 Southwest 52 nd Avenue Pembroke Park,
More information