Proposal and Contract for HOME BUILDING and HOME REPAIR;
|
|
- Jeffry Sparks
- 6 years ago
- Views:
Transcription
1 Proposal and Contract for HOME BUILDING and HOME REPAIR; Date of Proposal: Attachments Comprising the Contract: [ ] General Conditions of Contract [ ] Plans and specifications [ ] Allowances Sheet [ ] Other documents attached [specify]: Proposal submitted to: [full legal name] (hereinafter the Owner, whether one or more) Address: Phone Number (s): Job Site Address: Job Site Phone Number: (the Project ) (the Project ) PROPOSAL FOR CONTRACT, (sometimes called the Contractor in this agreement) hereby offers to perform the work described in the attached plans and specifications and to provide all materials and labor specified on the attached detailed list of materials, labor and repair work, all of which to be provided and performed by the Contractor in connection with the repair of the Project (collectively, the Work ). The Work will begin on or before, (the Start Date ), and will be completed no later than, (the Completion Date ). We agree to perform and provide the Work in accordance with the above referenced specifications and all attachments listed above, for the sum of: $ including the allowances set forth on the attachment hereto (the Contract Price ). This Proposal may be withdrawn by us if not accepted by A.M./P.M. on,. We represent and warrant to the Owner that (a) we are licensed to perform construction work in the state where the Project is located (copies of our licenses are attached to this Proposal for your review), (b) our state/province contractor license number is ; (c) we have the financial and staffing capacity to complete the Work as proposed; and (d) references for our work are available upon request. CONTRACTOR Contractor s Address: By Its Contractor's Phone Number: ( ) THE OWNER IS HEREBY ADVISED THAT IF THE PROJECT IS THE OWNER S HOMESTEAD, FEDERAL LAW ALLOWS THE OWNER TO TERMINATE THE CONTRACT CREATED WHEN THE OWNER ACCEPTS THIS PROPOSAL FOR ANY REASON WITHIN 3 DAYS AFTER SIGNING IT. OWNER ACCEPTANCE OF PROPOSAL AND AGREEMENT TO CONTRACT The above offer including the prices, specifications and conditions are hereby accepted. You are authorized to supply and perform the Work as specified in your Proposal and we will abide by all terms of this Contract including the Conditions of Contract attached hereto. THIS IS A LEGALLY BINDING CONTRACT. IF YOU DO NOT UNDERSTAND THIS CONTRACT, CONSULT YOUR LAWYER BEFORE YOU SIGN IT. Signature Date Signature Date The Owner s insurance company: The Owner s insurance agent: Agent s Phone Number: ( ) -1-
2 ALLOWANCES This allowance specification sheet is part of the Contract (as defined in the General Conditions of Contract) between: as the Contractor, and, the owner(s) of the Project. Project: Construction/Repair of [address] Included within the Contract Price are the following allowances for installation, labor and materials [select as applicable to the Project]: 1. Lighting fixtures $ 2. Finish floor coverings (carpet, pad, vinyl) $ 3. Built-in appliances (dishwasher, disposal, and vent hood) (upgrades at Owner's expense) $ 4. Upgrade plumbing fixtures $ 5. Ceramic tile allowance $ 6. Doors; wood work $ 7. Wall coverings $ 8. Finished landscaping $ 9. Wood burning stove $ 10. Well and Septic System $ 11. Driveway, base and culvert $ 12. Window Treatments $ 13. Kitchen and Bathroom Cabinets $ 14. $ 15. $ 16. $ Other: If on-site conditions or Owner's selections cause an increase or decrease from these allowances, the changes will be adjusted with a Change Order signed by the Owner and the Contractor. -2-
3 GENERAL CONDITIONS OF CONTRACT These General Conditions of Contract are accepted and agreed upon by, the Contractor, and, the owner(s) of the Project described in the Proposal and Contract for Building and Home Repair. A. CONTRACT DOCUMENTS. This contract for home repair consists of the following documents (which are collectively referred to herein as the Contract ): 1. The Proposal and Contract for Building and Home Repair. 2. The General Conditions of Contract. 3. All drawings, plans, specifications, and material schedules which are now or by later agreement attached to this Contract. 4. Any change orders in the form attached as part of this Contract. 5. Any supplemental Contract documents, modifications, or Change Orders executed by both parties after the date of the Proposal and Contract for Building and Home Repair. 6. Others (list): B. START DATE; COMPLETION DATE. The Start Date and the Completion Date will be as specified in the Proposal and Contract for Home Repair. Time is of the essence of this Contract. If the Contractor is delayed at any time in the progress of the Work by Change Orders, Owner's failure to make timely progress payments, fire, adverse weather conditions not reasonably anticipated, unavoidable casualties, or any other causes beyond the Contractor's control, then the Completion Date will be extended by a Change Order (as defined in Part G. of these General Conditions) for a reasonable period of time as the parties may determine by their written agreement. The Contractor will pay to the Owner $ per day for each day that the Completion Date is delayed for a reason not agreed to in a Change Order executed by both parties. The Completion Date will be the date on which (1) a Certificate of Occupancy is issued for the Project or, if no Certificate of Occupancy will be issued, the date that the city building inspector completes a final inspection of the Project, and (2) the Owner and the Contractor reasonably agree that the Work, excluding any punchlist items and remedial work to be performed by the Contractor pursuant to Part H. hereof, is completed. C. PROGRESS PAYMENTS. The Owner will make progress payments to the Contractor for Work as follows: $ as a down payment [note that smaller projects should require no down payment]. Progress payment during the conduct of the Work shall be made no more often than [monthly/bi-weekly] and will be based upon the Contractor s certification that the Work for which payment is requested has been completed and that all materials and labor reflected in that progress payment request has been or will be paid from such progress payment. In addition, payments for milestone events shall be made as follows: Payment Event Amount of Progress Payment 1. Footings $ 2. Footing and Foundation Waterproofing (prior to backfill) $ 3. Sheathing and Wall Anchoring $ 4. Framing $ 5. Electrical $ 6. Insulation $ 7. Final Plumbing and Mechanical $ 8. Completion of the Work [See Part D.] The Owner will pay the Contractor 90% of the above referenced Progress Payments, with the remaining 10% being heldback by the Owner until completion of the Work on the Completion Date. Payment will be due ten days after contractor s certification, subject to delays caused by processing insurance claims. At the request of Owner Contractor will deliver paid lien waivers from itself and all subcontractors to the extent of the amount of the progress payment. D. FINAL PAYMENT. Final payment for the unpaid balance of the Contract Price, including all retainage amounts (if any) but excluding an amount equal to 150% of the estimated cost of the Contractor completing the nonconforming Work and punchlist items pursuant to Part H. hereof, will be due and payable no later than 30 days after the Completion Date (as defined in Part B., above), subject to delays caused by processing the Owner s insurance claims. Simultaneously with final payment, the Contractor will deliver to the Owner a complete release of all liens which may have been filed and/or complete receipts and waivers of lien rights for all labor, materials and equipment for which a lien could be filed and the Contractor's sworn construction statement verifying that all charges for labor and materials have been paid. Retainage for nonconforming Work will be paid to the Contractor upon completion of all remedial Work and punchlist items pursuant to Part H. hereof. E. CONTRACTOR'S RESPONSIBILITIES. The Contractor will supervise and be solely responsible for all construction means, methods, techniques and procedures for the Work. Unless specifically agreed in writing, the Contractor will provide and pay for all labor, materials, equipment, tools, construction equipment and machinery, -3-
4 transportation and other facilities and services necessary for execution and completion of the Work. If this Contract is for the new construction of an entire structure, the Contractor will also provide water, heat, and utilities necessary to the Project. If this Contract is a contract for the repair of an existing structure, the Owner will provide water, heat and utilities necessary to complete the Work. The Contractor warrants that all of the materials used in performing the Work will be new unless otherwise specified and that all Work will be of good quality and in conformance with applicable building codes and laws. The Contractor will obtain and pay for all building permits, licenses and inspections necessary for completion of the Work. The Contractor will comply with all laws, ordinances, rules, regulations and lawful orders of any public authority having jurisdiction over performance of the Work. The Contractor will keep the Project free from the accumulation of waste and rubbish caused by the Work and, upon completion of the Work, will remove all its waste material from the Project as well as all of its tools, equipment and surplus materials. F. SUBCONTRACTORS. The Contractor will have sole discretion as to who it hires for subcontracted Work (a subcontractor is defined to be any person or entity who has a direct contract with and authority from the Contractor to perform any portion of the Work), and shall be solely responsible for the conduct and performance of such subcontractors. The Contractor will furnish to the Owner the names and addresses of each subcontractor employed to perform or supply any portion of the Work. If this Contract is not (1) for work on a structure that is being constructed for habitation by one to four families (including detached garages), or (2) for construction of or improvements to attached single family dwellings that will be used for residential purposes and that will have fewer than 13 units per structure, then the following provisions shall apply pursuant to the requirements of Section of the Minnesota Statutes: The Contractor, and all of the Contractor s subcontractors, shall promptly pay any subcontractor or material supplier within 10 days after the Contractor s receipt of payment from the Owner or Owner s agent for undisputed services provided by the subcontractor(s) or material supplier(s). Interest shall accrue and be paid to the subcontractor or material supplier by the Contractor at the rate of 1 1/2% per month on any undisputed amount not paid on time to the subcontractor or material supplier as required hereby. The minimum monthly interest penalty payment for an unpaid balance of $ or more shall be $10.00; for an unpaid balance of less than $100.00, the Contractor shall pay the actual 1 1/2% monthly penalty due to the subcontractor. A subcontractor who prevails in a civil action to collect interest penalties from the Contractor must be awarded its costs and disbursements, including attorney fees incurred in bringing the action. G. CHANGE ORDERS. Subject to the provisions of this Part G., the Work, Contract Price and Completion Date may be modified only by a properly executed Change Order (a copy of the Change Order form is attached hereto as Exhibit A). All Change Orders must be signed by the Owner and the Contractor to be binding upon the parties. H. QUALITY OF WORK. The Contractor will complete the Work according to the plans, specifications and other documents that comprise this Contract. Upon substantial completion of the Work all Work that in the Owner s reasonable opinion is not yet complete or which fails to meet Contract requirements will be specified in a punchlist executed by the Owner and the Contractor and will be promptly corrected by the Contractor, and all costs or damages to other portions of the Project resulting from such defective work or correction thereof will be paid by the Contractor. If the Contractor does not make such corrections to the Work, the Owner may do so at the expense and for the account of the Contractor. The Contractor warrants that the Work will be free from defects in materials and workmanship for a period of one year from the date of final payment under this Contract. The Contractor will obtain for the Owner s benefit, and assign to Owner, all manufacturer s warranties applicable to materials or equipment installed by the Contractor or any of its subcontractors. This warranty does not limit the Contractor s liability at law for defects in the Work. I. MECHANICS LIENS. The Contractor will timely pay all subcontractors and material suppliers for their respective performance of any of the Work so as to prevent mechanics or materialmens liens from being filed against the Project. The Contractor will indemnify, defend and hold harmless the Owner for any such liens that are filed against the Project (provided the Owner is not in default in the payment of any amounts due to the Contractor hereunder) and this indemnity will survive termination of this Contract. J. INDEMNIFICATION; PROTECTION OF PROPERTY AND PERSONS. The Contractor will indemnify, defend and hold harmless the Owner from and against all claims, damages, losses and expenses, including but not limited to reasonable attorneys fees (1) for bodily injury, sickness, disease or death or to injury to or destruction of tangible property (other than the Work itself) including the loss of use resulting therefrom arising out of or resulting from any negligent act or omission of the Contractor, any subcontractor, anyone directly or indirectly employed by the Contractor or any subcontractor or anyone for whose acts any of them may be liable, regardless of whether or not such claim, loss or expense is caused in part by a party indemnified hereunder, or (2) arising out of or relating to injury to any employee of the Contractor, any subcontractor or material supplier, or any of their respective employees, which occurs as a result of, or is in any manner related to execution of the Work or which occurs or results from the use by the Contractor, its subcontractors or suppliers or any of their respective employees of materials, equipment, instrumentalities or other property in connection with the Work, regardless of the owner thereof and all regardless of whether the Owner may be liable or claimed to be liable for the same. The Contractor will reimburse the Owner for all costs and disbursements, including reasonable attorneys fees paid or incurred to enforce the provisions of this paragraph. The Contractor furthermore agrees to obtain, maintain and pay for such general liability coverage and endorsements as will ensure the provisions of this paragraph. K. INSURANCE. The Contractor has, and will continue to maintain, insurance coverage sufficient to protect the Contractor from the claims of workers under the Workers' Compensation Act and other employee benefit acts for damages because of bodily injury, including death, and from claims for damages, other than to the Work itself, to property which may arise out of or result from the Contractor's work under this Contract, whether such operations are conducted by itself or by any subcontractor or anyone directly or indirectly employed by the Contractor or any subcontractor. The Contractor shall obtain and maintain liability insurance sufficient to protect the Owner against -4-
5 claims that arise from any operations under this Contract, which insurance policy will name the Owner as an additional insured. If this is a contract for new construction of the entire Project, the Contractor will also insure the Project against the perils of fire and extended coverage and shall include all risk insurance for physical loss or damage, including, without duplication of coverage, theft, vandalism and malicious mischief, which insurance policy will name the Owner as an additional insured. The Contractor will provide the Owner with a certificates evidencing the insurance required by this paragraph prior to the Commencement Date. If this is a contract for the repair of an existing structure, the Owner will obtain and maintain property insurance upon the real property at the Project site in the amount of the full insurable value thereof. This insurance will include the interest of the Owner, the Contractor, and any subcontractors involved in the Work and will insure against the perils of fire and extended coverage and shall include all risk insurance of physical loss or damage including, without duplication of coverage, theft, vandalism, and malicious mischief. Upon request, the Owner will provide a certificate of this insurance to the Contractor. L. DEFAULTS. If the Owner fails to make any required payment for a period of 30 days after it is due, the Contractor may, upon 2 additional days written notice to the Owner, terminate this Contract and recover from the Owner payment for all Work performed and for all materials furnished to the Project and for use of all construction equipment and machinery in the performance of the Work, including reasonable profit and damages applicable to the Work. If the Contractor (1) is judged to be bankrupt or insolvent, (2) makes a general assignment for the benefit of its creditors, or if a trustee or receiver is appointed for the Contractor or for any of its property, (3) fails to supply sufficient skilled workers or suitable materials or equipment for the Project, (4) fails to make prompt payments to subcontractors for labor and materials or equipment, (5) disregards laws, ordinances, rules, regulations or orders of any public body or public official having jurisdiction, or (6) otherwise violates any provision of this Contract, the Owner may, without prejudice to any other right or remedy the Owner may have by law, and after giving the Contractor 7 days prior written notice, terminate the services of the Contractor, take possession of the Project and all materials thereon, and finish the Work by whatever method the Owner may deem expedient. In such case, the Contractor will not be entitled to receive any further payment until the Work is finished. If the unpaid balance of the Contract Price exceeds all costs to the Owner of completing the Work, then the Contractor will be paid for all Work performed by the Contractor to the date of termination. If such costs to the Owner of completing the Work exceed such unpaid balance, the Contractor will pay the difference to the Owner immediately upon the Owner s demand for such payment. The costs to the Owner of completing the Work will include (but not be limited to) any costs incurred in retaining another contractor or other subcontractors, any additional interest or fees which the Owner must pay by reason of a delay in completion of the Work, reasonable attorneys fees and expenses, and any other damages, costs and expenses the Owner may incur by reason of completing the Work or any delay thereof. The obligations of the parties to pay each other, if any, pursuant to this paragraph shall survive termination of the Contract. M. GOVERNING LAW. This Contract is governed by the laws of the State or Province of:. N. RESTRICTION ON ASSIGNMENT. Neither the Owner nor the Contractor may assign this Contract without the express written consent of the other party. O. PERFORMANCE AND PAYMENT BONDS. [Cross this Part out if the Owner will not require this] The Contractor will provide the Owner with performance and payment bonds issued by a surety acceptable to the Owner, naming the Owner as a dual obligee, bonding and assuring performance by the Contractor of this Contract. UREA FORMALDEHYDE DISCLOSURE OF CONTRACTOR Most states or provinces have a law requiring a warning to be provided in the sale of buildings or building products containing Urea Formaldehyde. Many products, particularly particle board and plywood use formaldehyde-based glue in their manufacture. Contractors who purchase and use products containing Urea Formaldehyde also have a responsibility to pass this warning on to their customers. The warning should read as follows: IMPORTANT HEALTH NOTICE: SOME OF THE BUILDING MATERIALS USED IN THIS HOME (OR THESE BUILDING MATERIALS) EMIT FORMALDEHYDE. EYE, NOSE AND THROAT IRRITATION, HEADACHE, NAUSEA AND A VARIETY OF ASTHMA-LIKE SYMPTOMS, INCLUDING SHORTNESS OF BREATH, HAVE BEEN REPORTED AS A RESULT OF FORMALDEHYDE EXPOSURE. ELDERLY PERSONS AND YOUNG CHILDREN, AS WELL AS ANYONE WITH A HISTORY OF ASTHMA, ALLERGIES, OR LUNG PROBLEMS, MAY BE AT A GREATER RISK. RESEARCH IS CONTINUING ON THE POSSIBLE LONG-TERM EFFECTS OF EXPOSURE TO FORMALDEHYDE. REDUCED VENTILATION MAY ALLOW FORMALDEHYDE AND OTHER CONTAMINANTS TO ACCUMULATE IN THE INDOOR AIR. HIGH INDOOR TEMPERATURES AND HUMIDITY RAISE FORMALDEHYDE LEVELS. WHEN A HOME IS TO BE LOCATED IN AREAS SUBJECT TO EXTREME SUMMER TEMPERATURES, AN AIR- CONDITIONING SYSTEM CAN BE USED TO CONTROL INDOOR TEMPERATURE LEVELS. OTHER MEANS OF CONTROLLED MECHANICAL VENTILATION CAN BE USED TO REDUCE LEVELS OF FORMALDEHYDE AND OTHER INDOOR AIR CONTAMINANTS. IF YOU HAVE ANY QUESTIONS REGARDING THE HEALTH EFFECTS OF FORMALDEHYDE, CONSULT YOUR DOCTOR OR LOCAL HEALTH DEPARTMENT -5-
6 Exhibit A to General Conditions of Contract CHANGE ORDER FORM No. Dated: Contractor: Owner: Project: Construction/Repair of [address] TO: Contractor You are directed to make the changes noted below to the Work specified in our Contract. [Signature of Owner/Buyer] Nature of Change: [Signature of Owner/Buyer] Attachments [identify and attach amended plans, drawings, specifications, etc.]: Changes to Contract Price and Contract time resulting from this Change Order: Contract price before this Change Order: $ Net increase/decrease from this Change Order: $ Resulting Contract Price $ Completion date prior to this change order: $ Net increase/decrease in Contact time: days Resulting completion date: ACCEPTANCE BY CONTRACTOR: This Change Order is accepted this day of,. CONTRACTOR By: Its: -6-
7 NOTICE TO: (Name and Address of Owner) YOU HAVE ENTERED INTO A CONTRACT WITH THE UNDERSIGNED TO IMPROVE YOUR. WE ARE AUTHORIZED BY LAW TO PROVIDE YOU WITH THIS NOTICE. YOU ARE THEREFORE NOTIFIED THAT: (a) (b) ANY PERSON OR COMPANY SUPPLYING LABOR OR MATERIALS FOR THIS IMPROVEMENT TO YOUR PROPERTY MAY FILE A LIEN AGAINST YOUR PROPERTY IF THAT PERSON OR COMPANY IS NOT PAID FOR THE CONTRIBUTIONS. UNDER STATE/PROVINCE LAW, YOU HAVE THE RIGHT TO PAY PERSONS WHO SUPPLIED LABOR OR MATERIALS FOR THIS IMPROVEMENT DIRECTLY AND DEDUCT THIS AMOUNT FROM OUR CONTRACT PRICE, OR WITHHOLD THE AMOUNTS DUE THEM FROM US UNTIL 45 DAYS AFTER COMPLETION OF THE IMPROVEMENT UNLESS WE GIVE YOU A LIEN WAIVER SIGNED BY PERSONS WHO SUPPLIED ANY LABOR OR MATERIAL FOR THE IMPROVEMENT AND WHO GAVE YOU TIMELY NOTICE. Dated:, 19. CONTRACTOR By: Its: STATE OF ) ) ss. AFFIDAVIT OF SERVICE COUNTY OF ) PERSONAL SERVICE of the City of, County of, in the State of, being duly sworn, says that on the day of,, s/he served the "NOTICE" of which the foregoing is a copy, on the owner(s) therein named by personally delivering to and leaving said Notice with said owners. Subscribed and sworn to before me this day of,. Notary Public Notarial Stamp or Seal (or other Title or Rank) -7-
Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project
Document A105 2007 Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project AGREEMENT made as of the in the year (In words, indicate day, month and year.) BETWEEN
More information<insert Name and logo and address> Minnesota Contractor License No. <> HOME REMODELING/CONSTRUCTION CONTRACT. CUSTOMER TELEPHONE: Home Business Cell
Minnesota Contractor License No. HOME REMODELING/CONSTRUCTION CONTRACT Date, 20 CUSTOMER NAME(S): CUSTOMER MAILING ADDRESS: CUSTOMER TELEPHONE: Home Business Cell
More informationCONSTRUCTION CONTRACT EXAMPLE
P a g e 1 CONSTRUCTION CONTRACT EXAMPLE THIS AGREEMENT, made and entered into this date, by and between, hereinafter called CONTRACTOR, and NPC QUALITY BURGER, INC., hereinafter called OWNER. IT IS HEREBY
More informationSAMPLE DOCUMENT SUBCONTRACT AGREEMENT
SUBCONTRACT AGREEMENT THIS SUBCONTRACT, made this day of by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter "Subcontractor") with an office and
More informationContractor for any and all liability, costs, expenses, fines, penalties, and attorney s fees resulting from its failure to perform such duties.
SUBCONTRACT AGREEMENT THIS SUBCONTRACT, made this day of, 20 by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter "Subcontractor") with an office
More informationRICE UNIVERSITY SHORT FORM CONTRACT
RICE UNIVERSITY SHORT FORM CONTRACT This Rice University Short Form Contract (this Contract ) is entered into by and between WILLIAM MARSH RICE UNIVERSITY, a Texas non-profit corporation (the University
More informationW I T N E S S E T H:
GENERAL CONTRACTORS SUBCONTRACT AGREEMENT THIS CONTRACT, made and entered into the day of, 20, by and between, a Tennessee, having its principal place of business at, hereinafter referred to as "Contractor"
More informationStandard Form of Agreement Between Contractor and Subcontractor
Standard Form of Agreement Between Contractor and Subcontractor GENERAL TERMS AND CONDITIONS ARTICLE 1 THE SUBCONTRACT DOCUMENTS 1.1 The Subcontract Documents consist of (1) these General Terms and Conditions,
More informationPOST BID ADDENDUM. Project: LDS Eastview, Mesa, Iona 10 HVAC Project No.: Addendum No.: 2
POST BID ADDENDUM Project: LDS Eastview, Mesa, Iona 10 HVAC Project No.: 504-6955 Addendum No.: 2 Project Address: 2349 Virlow St., Idaho Falls, Idaho 83401 Date: 8/29/2016 Owner: Corporation of the Presiding
More informationARTICLE 1 ARTICLE 3 CONTRACTOR THE SUBCONTRACT DOCUMENTS ARTICLE 2 MUTUAL RIGHTS AND RESPONSIBILITIES
ARTICLE 1 THE SUBCONTRACT DOCUMENTS 1.1 The Subcontract Documents consist of (1) this Agreement; (2) the prime Contract, consisting of the Agreement between the Owner and Contractor and the other Contract
More informationSAFETY FIRST GRANT CONTRACT
SAFETY FIRST GRANT CONTRACT This agreement (the Contract ) is made this day of, by and between (the Contractor ) and (the Owner ), for the (Name of Parish Corporation, ABN or high school corporation) purpose
More informationI N V I T A T I O N T O B I D B I D # DOOR AND WINDOW REPLACEMENT AT SOUTH PORTLAND SCHOOLS
I N V I T A T I O N T O B I D B I D # 1 0-17 FINANCE DEPARTMENT GREGORY N. L HEUREUX Finance Director KRISTIE BRADBURY Deputy Finance Director COLLEEN C. SELBERG Purchasing Agent DOOR AND WINDOW REPLACEMENT
More informationCONSTRUCTION AGREEMENT/CONTRACT
Contract Number: Office Use Only 2233 Citygate Drive Columbus, Ohio 43219 614.418.7725 tel 614.418.7720 fax www.creativehousing.org CONSTRUCTION AGREEMENT/CONTRACT Between: For the Project: Creative Housing,
More informationMASTER SUBCONTRACT AGREEMENT
MASTER SUBCONTRACT AGREEMENT This Master Subcontract Agreement ( Subcontract ), made this day of, 20 by and between (hereinafter "Contractor"), with an office and principal place of business at and (hereinafter
More informationADDENDUM TO STANDARD FORM OF AGREEMENT BETWEEN OWNER AND CONTRACTOR FOR A RESIDENTIAL OR SMALL COMMERCIAL PROJECT AIA DOCUMENT A
ADDENDUM TO STANDARD FORM OF AGREEMENT BETWEEN OWNER AND CONTRACTOR FOR A RESIDENTIAL OR SMALL COMMERCIAL PROJECT AIA DOCUMENT A105-2007 The following addendum modifies or supplements the standard form
More informationAmount of Contract work per the plans and specifications for project. Specifications Attached. Plans Attached
Sample Company 2005 XXXX Main St Anywhere CA 99999 800 555-5555 SUBCONTRACT Contract#: 921 Contract Date: 08/20/2008 SUBCONTRACTOR: Baxter Heating & Cooling 4320 Eucalyptus Way Santa Rosa CA 95401 PROJECT:
More informationMASTER SUBCONTRACTOR AGREEMENT
The Builders Association of Minnesota, its local associations, and Fredrikson & Byron, P.A. disclaim any liability resulting from the use of these sample forms, and remind you that no single form is appropriate
More informationWESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT
WESTERN RIVERSIDE COUNCIL OF GOVERNMENTS EQUIPMENT PURCHASE AGREEMENT This Equipment Purchase Agreement ( Agreement ) is entered into this day of, 20, by and between the Western Riverside Council of Governments,
More informationCDBG/HOME CONTRACT DOCUMENTS NEW HOUSING CONSTRUCTION
CDBG/HOME CONTRACT DOCUMENTS NEW HOUSING CONSTRUCTION 2013 CDBG/HOME HOUSING NEW CONSTRUCTION CONTRACT THIS CONSTRUCTION CONTRACT is made and entered into this day of 2013, by and between, (marital status),
More informationCONTRACT. Owner and Contractor agree as follows: 1. Scope of Work.
CONTRACT This agreement (the "Contract") is made this day of, by and between (the "Contractor") and (name of parish corporation, ABN or high school corporation) (the "Owner"), for the purpose of stating
More informationDocument A Standard Form of Agreement Between Contractor and Subcontractor
Document A401 2017 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Contractor: (Name, legal
More informationDocument A401 TM. Standard Form of Agreement Between Contractor and Subcontractor
Document A401 TM 2017 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Contractor: (Name,
More informationSUBCONTRACT. by and between. to perform the Work identified in Article 2 in accordance with the Projects Contract documents.
Phone 800 555-5555 Fax 999 555-5551 TO: 4320 Eucalyptus Way Santa Rosa CA 95401 SUBCONTRACT PROJECT: 186 Williams Post Office 19420 Williams Rd. Monte Rio CA 95462 This agreement entered into this day
More informationI N V I T A T I O N T O B I D BID #33-16 RECONSTRUCTION OF RETAINING WALL
FINANCE DEPARTMENT I N V I T A T I O N T O B I D GREGORY N. L HEUREUX Finance Director KRISTIE BRADBURY Deputy Finance Director COLLEEN C. SELBERG Purchasing Agent BID #33-16 RECONSTRUCTION OF RETAINING
More informationAGC TEXT COPY THE ASSOCIATED GENERAL CONTRACTORS OF AMERICA AGC DOCUMENT NO. 603 STANDARD SHORT FORM AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR
THE ASSOCIATED GENERAL CONTRACTORS OF AMERICA AGC DOCUMENT NO. 603 STANDARD SHORT FORM AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR (Where Contractor Assumes Risk of Owner Payment) The original text
More informationDocument A Standard Abbreviated Form of Agreement Between Owner and Contractor
Document A104 2017 Standard Abbreviated Form of Agreement Between Owner and Contractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Owner: (Name, legal
More informationSubcontract Agreement
S THIS AGREEMENT made as of the day of, 2012 BETWEEN the Contractor: TCL Partners 5212 123 rd Place SE Everett, WA 98208 and the For the Following Project: The Architect for the Project: The Contractor
More informationENERGY EFFICIENCY CONTRACTOR AGREEMENT
ENERGY EFFICIENCY CONTRACTOR AGREEMENT 2208 Rev. 2/1/13 THIS IS AN AGREEMENT by and between PUBLIC UTILITY DISTRICT NO. 1 OF SNOHOMISH COUNTY (the District ) and a contractor registered with the State
More informationSHORT FORM STANDARD SUBCONTRACT. This Agreement is made this day of, 20, between
SHORT FORM STANDARD SUBCONTRACT This Agreement is made this day of, 20, between (Contractor) and (Subcontractor). The work described in Section I below shall be performed in accordance with the prime contract
More informationCONSTRUCTION CONTRACT AGREEMENT
Commonwealth of Pennsylvania Rev. 133A2CC CONSTRUCTION CONTRACT AGREEMENT This Construction Contract Agreement (this Agreement ) is made as of the 17 day of January, 2018 by and between Anthony E Cummins,
More informationPage of 5 PURCHASE AGREEMENT
Page - 1 - of 5 (the Effective Date ) PURCHASE AGREEMENT THIS PURCHASE AGREEMENT (this Purchase Agreement ), dated the date specified above, is by and between (the "Contractor") and (the "Subcontractor").
More informationTHE LOFTS ON MAIN LIMITED PARTNERSHIP. and THE CITY OF PEEKSKILL $1,044, LOAN AGREEMENT. DATED AS OF June, 2016
THE LOFTS ON MAIN LIMITED PARTNERSHIP and THE CITY OF PEEKSKILL $1,044,481.00 LOAN AGREEMENT DATED AS OF June, 2016 This instrument affects real and personal property situated in the State of New York,
More informationOGC-S Owner-Contractor Construction Agreement
Owner-Contractor Construction Agreement This agreement is entered into as of ( Effective Date ) between Lone Star College (the "College"), a public junior college pursuant to Section 130.004 of the Texas
More informationAGREEMENT BETWEEN OWNER AND SELLER
AGREEMENT BETWEEN OWNER AND SELLER 11-15-2018 THIS AGREEEMENT is effective as of the day of in the year of 2018 by and between the Velasco Drainage District, a political subdivision of the State of Texas,
More informationBETWEEN name. address. AND name (hereinafter called the Subcontractor ) address
AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR CONTRACTOR S COPY SUBCONTRACT NO. Alberta Standard Construction Subcontract THIS AGREEMENT made this day of, A.D. 20 BETWEEN name (hereinafter called the
More informationStandard Form of Agreement Between Contractor and Subcontractor
Document A401 2007 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the in the year (In words, indicate day, month and year.) day of BETWEEN the Contractor: (Name, legal
More informationAIA Document A101 TM 2007
AIA Document A101 TM 2007 Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum AGREEMENT made as of the day of in the year (In words, indicate day, month
More informationFIXED CONTRACT AMOUNT THIS AGREEMENT, Made as of (Current Date), In the Year of (Current Year),
FIXED CONTRACT AMOUNT THIS AGREEMENT, Made as of (Current Date), In the Year of (Current Year), Between the Owner: Owner s Name Phone Number And the Contractor: For the Project: Contractor s Name License
More informationSUBCONTRACT FOR BUILDING CONSTRUCTION
SUBCONTRACT FOR BUILDING CONSTRUCTION TABLE OF ARTICLES 1. AGREEMENT 2. SCOPE OF WORK 3. SCHEDULE OF WORK 4. CONTRACT PRICE 5. PAYMENT 6. CHANGES, CLAIMS AND DELAYS 7. CONTRACTOR'S OBLIGATIONS 8. SUBCONTRACTOR'S
More informationRENOVATION LOAN AGREEMENT
THIS IS A MODEL DOCUMENT FOR USE IN FANNIE MAE RENOVATION LOAN TRANSACTIONS. THIS FORM IS PROVIDED AS AN EXAMPLE AND HAS NOT BEEN EVALUATED FOR VALIDITY AND ENFORCEABILITY IN ANY JURISDICTION. LENDERS
More informationSUBCONTRACT (SHORT FORM)
SUBCONTRACTOR: PHONE SUBCONTRACT (SHORT FORM) PROJECT: LOCATION: This agreement is made and effective, by and between SUN CONSTRUCTION & FACILITY SERVICES, INC. (Contractor) and (Subcontractor) which are
More informationBUILDING CONSTRUCTION AGREEMENT
Landmark Real Estate & Dev., Inc. 320 Main Ave., Suite 300, De Pere, WI 54115 Phone: 920.337.9566 Fax: 920.337.9568 BUILDING CONSTRUCTION AGREEMENT THIS AGREEMENT is made this day of, by and between Landmark
More informationRENOVATION CONTRACT. Borrower Name(s): Phone #: Phone #:
RENOVATION CONTRACT Case Number: Date: Borrower Name(s): Phone #: Phone #: THIS RENOVATION CONTRACT ( Contract ) dated as of, by and between ( Owner ) and ( Contractor ). Owner and Contractor, in consideration
More informationSUPPLIER - TERMS AND CONDITIONS Materials and Goods
SUPPLIER - TERMS AND CONDITIONS Materials and Goods 1. BINDING EFFECT; ACCEPTANCE. This purchase order and all subsequent purchase orders delivered by Buyer to Seller (each, an "order"), shall be governed
More informationOWNER/CONTRACTOR AFFIDAVIT, WAIVER OF LIENS AND INDEMNITY AGREEMENT (NO MECHANICS LIEN AGENT APPOINTED - CONSTRUCTION RECENTLY COMPLETED)
OWNER/CONTRACTOR AFFIDAVIT, WAIVER OF LIENS AND INDEMNITY AGREEMENT PARTIES: All parties identified in this section must execute this Agreement, including any Contractors required to sign Additional Signature
More informationGENERAL RENOVATION COST PLUS FIXED FEE THIS AGREEMENT, Made as of (Current Date), In the Year of (Current Year),
GENERAL RENOVATION COST PLUS FIXED FEE THIS AGREEMENT, Made as of (Current Date), In the Year of (Current Year), Between the Owner: Owner s Name Phone Number And the Contractor: For the Project: Contractor
More informationDocument A107. Standard Form of Agreement Between Owner and Contractor for a Project of Limited Scope
TM Document A107 2007 Standard Form of Agreement Between Owner and Contractor for a Project of Limited Scope AGREEMENT made as of the in the year (In words, indicate day, month and year.) day of BETWEEN
More informationFATIGUE TECHNOLOGY INC. PURCHASE ORDER TERMS AND CONDITIONS DATED JANUARY 4, 2006
FATIGUE TECHNOLOGY INC. PURCHASE ORDER TERMS AND CONDITIONS DATED JANUARY 4, 2006 1. CONTRACT. Fatigue Technology Inc. s, hereinafter called FTI, purchase order, or change order to a purchase order, collectively
More informationPRODIGY. CONTRACTING GROUP INC. CommerCial residential industrial
Dear Subcontractor; Please find enclosed our Subcontractor Insurance/Hold Harmless agreement and Master Agreement for your signature and return. It is the company s policy and our insurance program s requirement
More informationMailing address: P.O. Box, 9422, South Portland, ME Telephone (207) Fax (207)
Page 1 of 9 Bid #10-18 Sealed bids for purchase of a replacement Sound System for the South Portland High School Auditorium, for the City of South Portland, Maine, as specified below, in the Specifications
More informationHOUSING CONSTRUCTION CONTRACT (Projects up to $10,000)
HOUSING CONSTRUCTION CONTRACT (Projects up to $10,000) THIS CONTRACT is by and between the Stockbridge-Munsee Community ( TRIBE ), for its Division of Community Housing, whose address is N8618 Oak St.,
More information1997 Part 2. Document B141. Standard Form of Architect's Services: Design and Contract Administration TABLE OF ARTICLES
TM Document B141 Standard Form of Architect's Services: Design and Contract Administration 1997 Part 2 TABLE OF ARTICLES 2.1 PROJECT ADMINISTRATION SERVICES 2.2 SUPPORTING SERVICES 2.3 EVALUATION AND PLANNING
More informationCHICAGO TITLE INSURANCE COMPANY OWNER/CONTRACTOR AFFIDAVIT, WAIVER OF LIENS AND INDEMNITY AGREEMENT (CONSTRUCTION RECENTLY COMPLETED)
PARTIES: All parties identified in this section must execute this Agreement, including any Contractors required to sign Additional Signature Pages which must be attached hereto and are hereby incorporated
More informationSUBCONTRACT CONSTRUCTION AGREEMENT
SUBCONTRACT CONSTRUCTION AGREEMENT THIS SUBCONTRACT CONSTRUCTION AGREEMENT, made and executed this day of, 20, by and between SHERWOOD CONSTRUCTION, INC (hereinafter referred to as "Contractor"), and (hereinafter
More informationCONSTRUCTION CONTRACT
CONSTRUCTION OR: Name Mailing Address City, State, Zip Code Telephone Number Fax Number E-mail address BID ACCEPTANCE DATE: COMPLETION DATE: DATE: TOTAL BID : TABLE OF CONTENTS ARTICLE 1 PARTIES... Page
More informationTHIS CONSTRUCTION CONTRACT ( Contract ) dated as of ( Owner ) and ( Contractor ) having a principal place of business at.
Homeowner Contractor HomeStyle Renovation Contract Loan Number: Date: Borrower Name(s): Phone #: Phone #: THIS CONSTRUCTION CONTRACT ( Contract ) dated as of by and between ( Owner ) and ( Contractor )
More informationC R D A Capital Region Development Authority
C R D A Capital Region Development Authority 100 Columbus Boulevard Suite 500 Hartford, CT 06103-2819 Tel (860) 527-0100 Fax (860) 527-0133 www.crdact.net September 26, 2018 Addendum #3 Regional Market
More informationDocument A401 TM. Standard Form of Agreement Between Contractor and Subcontractor
Document A401 TM 2007 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Contractor: (Name,
More informationGENERAL: WITNESSETH: That the said Contractor and the said District, for consideration hereinafter named agree as follows: DESCRIPTION OF WORK:
GENERAL: This Contract made and entered into this day of, 2013, by and between the Sundown Sanitary Sewer District, hereinafter called "District", and, hereinafter called "Contractor", duly authorized
More informationDrexel University Independent Contractor Service Provider Agreement. Name: [ ] Limited Liability Company [ ] Professional Corporation
This is a form agreement for discussion purposes only. It does not constitute a binding offer or contract of Drexel University until all of the terms have been approved and this agreement is executed by
More informationCITY OF EAST POINT BID NO BID TITLE: CONTRACT FOR CONSTRUCTION AND INCORPORATED GENERAL CONDITIONS
CITY OF EAST POINT BID NO. 2017- BID TITLE: Revised 12/05/2014 TABLE OF CONTENTS Page # ARTICLE I THE CONTRACT AND THE CONTRACT DOCUMENT... 1 1.1 The Contract... 1 1.2 The Contract Documents... 1 1.3 Entire
More informationProposal and Agreement for Construction on Purchaser s Lot
Proposal and Agreement for Construction on Purchaser s Lot This Proposal and Agreement is made this day of, 200, by and between The Company, (hereinafter referred to as The Company), and (hereinafter referred
More informationMUSCOGEE (CREEK) NATION CHURCH & CEREMONIAL GROUND CAMP, CAMP HOUSE & FELLOWSHIP HALL GRANT PROGRAM APPLICATION CHECKLIST
MUSCOGEE (CREEK) NATION CHURCH & CEREMONIAL GROUND CAMP, CAMP HOUSE & FELLOWSHIP HALL GRANT PROGRAM APPLICATION CHECKLIST D A letter from the Ceremonial Ground Mekko or Pastor stating the need for the
More informationRevised GENERAL CONDITIONS (Procurement Contract)
Revised 2005-03-14 GENERAL CONDITIONS (Procurement Contract) INDEX GC1 INTERPRETATION... 1 GC2 ASSIGNMENT AND SUB-LETTING... 2 GC3 CONDUCT OF THE WORK... 2 GC4 PERSONAL INFORMATION AND PRIVACY... 3 GC5
More informationCONTRACT AGREEMENT FOR PARKING AREA CONSTRUCTION. THIS AGREEMENT, made this day of, 2018,
CONTRACT AGREEMENT FOR PARKING AREA CONSTRUCTION THIS AGREEMENT, made this day of, 2018, signed between Nampa & Meridian Irrigation District, hereafter referred to as "NMID" and, of (address), hereinafter
More information[LENDER COVERAGE ONLY]
OWNER/CONTRACTOR AFFIDAVIT, INDEMNITY AND LIEN SUBORDINATION AGREEMENT (NO MECHANICS LIEN AGENT APPOINTED - CONSTRUCTION IN PROCESS OR IMMEDIATELY [LENDER COVERAGE ONLY] PARTIES: All parties identified
More informationTOWN OF BURLINGTON PURCHASING DEPARTMENT New Four Stage Breathing Air Compressor Contract #17S
TOWN OF BURLINGTON PURCHASING DEPARTMENT New Four Stage Breathing Air Compressor Contract #17S-220-0006 If this document is used to submit a bid then you must submit your contact information to Kate Moskos
More informationDEVELOPER EXTENSION AGREEMENT
DEVELOPER EXTENSION AGREEMENT SILVER LAKE WATER DISTRICT APPLICATION AND AGREEMENT TO CONSTRUCT EXTENSION TO DISTRICT SYSTEM Project: Developer: The undersigned, Developer (also referred to as Owner )
More informationFIXTURE TERMS & CONDITIONS Materials & Goods
FIXTURE TERMS & CONDITIONS Materials & Goods 1. BINDING EFFECT; ACCEPTANCE. This purchase order and all subsequent purchase orders delivered by Supplier to The Pep Boys Manny, Moe & Jack, and its affiliates,
More informationSERVICE AGREEMENT. THIS AGREEMENT ( Agreement ) is made and entered into as of, 20 by and between ( Owner ) and ( Vendor ).
SERVICE AGREEMENT THIS AGREEMENT ( Agreement ) is made and entered into as of, 20 by and between ( Owner ) and ( Vendor ). WITNESSETH: WHEREAS, Owner desires to engage Vendor, as an independent contractor,
More informationARBITRATION AGREEMENT
ARBITRATION AGREEMENT This Arbitration Agreement ( Agreement ) is executed contemporaneously with, and as additional consideration for, an installment or sales contract ( Contract ) for the purchase of
More informationAIA Document A105 TM 2017
AIA Document A105 TM 2017 Standard Short Form of Agreement Between Owner and Contractor AGREEMENT made as of the» day of in the year 2018» (In words, indicate day, month and year.) BETWEEN the Owner: (Name,
More informationTHIS AGREEMENT, made the day of in the year BETWEEN
Building Loan Contract CONSULT YOUR LAWYER BEFORE SIGNING THIS INSTRUMENT THIS INSTRUMENT SHOULD BE USED BY LAWYERS ONLY. THIS AGREEMENT, made the day of in the year BETWEEN hereinafter referred to as
More informationBuilding Loan Contract CONSULT YOUR LAWYER BEFORE SIGNING THIS INSTRUMENT THIS INSTRUMENT SHOULD BE USED BY LAWYERS ONLY.
Building Loan Contract CONSULT YOUR LAWYER BEFORE SIGNING THIS INSTRUMENT THIS INSTRUMENT SHOULD BE USED BY LAWYERS ONLY. THIS AGREEMENT, made the day of in the year BETWEEN hereinafter referred to as
More informationG E O R G I A P O R T S A U T H O R I T Y I N S U R A N C E R E Q U I R E M E N T S
Page 11 of 17 G E O R G I A P O R T S A U T H O R I T Y I N S U R A N C E R E Q U I R E M E N T S The contractor shall provide certificates of insurance in a form acceptable to the Georgia Ports Authority
More informationGENERAL CONDITIONS OF THE CONTRACT FOR NON-CONSTRUCTION
GENERAL CONDITIONS OF THE CONTRACT FOR NON-CONSTRUCTION ---------------------------ARTICLE 1 --------------------------- GENERAL PROVISIONS 1.1 Governing Law: The Contract shall be governed by the law
More informationFIXTURING/INSTALLATION AGREEMENT
Dept Index Contract No. Requisition No. FIXTURING/INSTALLATION AGREEMENT This FIXTURING/INSTALLATION AGREEMENT by and between THE UNIVERSITY OF NORTH FLORIDA BOARD OF TRUSTEES, a public body corporate
More informationAGREEMENT TO ESTABLISH. THIS AGREEMENT, made and entered into this day of, 200_. between, an Ohio Corporation, (hereinafter referred to as Owner ),
AGREEMENT TO ESTABLISH STREAM MITIGATION BANK THIS AGREEMENT, made and entered into this day of, 200_ between, an Ohio Corporation, (hereinafter referred to as Owner ),, and Water Resources Improvement
More informationTacoma Power Conservation Contractor Agreement
Tacoma Power THIS AGREEMENT is made and entered into this day of, 2012 ( Effective Date ) by and between the City of Tacoma, Department of Public Utilities, Light Division, Tacoma Power (hereinafter referred
More informationICSC CENTERBUILD CONFERENCE DECEMBER 2-5, 1998 ARIZONA BILTMORE PHOENIX, ARIZONA
ICSC CENTERBUILD CONFERENCE DECEMBER 2-5, 1998 ARIZONA BILTMORE PHOENIX, ARIZONA A COMPARATIVE ANALYSIS OF THE 1997 CHANGES TO THE AIA GENERAL CONDITIONS TO THE CONTRACT FOR CONSTRUCTION (A201) STUART
More informationINDEPENDENT CONTRACTOR AGREEMENT
INDEPENDENT CONTRACTOR AGREEMENT THIS AGREEMENT is made and entered into this by and between: Abbey Residential Services, Inc., with offices at 1930 Stonegate Drive, Vestavia Hills, Alabama 35242, in its
More informationINTERIM WAIVER AND RELEASE UPON PAYMENT
EXHIBIT F STATE OF GEORGIA COUNTY OF INTERIM WAIVER AND RELEASE UPON PAYMENT THE UNDERSIGNED MECHANIC AND/OR MATERIALMAN, HAS BEEN EMPLOYED BY TO FURNISH FOR THE CONSTRUCTION OF IMPROVEMENTS KNOWN AS WHICH
More informationSTANDARD FIXED PRICE AGREEMENT BETWEEN OWNER AND CONTRACTOR DRAFT
STANDARD FIXED PRICE AGREEMENT BETWEEN OWNER AND CONTRACTOR This Agreement, made January 10, 2012 by and between Marion County, a political subdivision of the State of Florida, (hereinafter referred to
More informationTRINITY UNIVERSITY CONSULTING SERVICES AGREEMENT
TRINITY UNIVERSITY CONSULTING SERVICES AGREEMENT This CONSULTING SERVICES AGREEMENT (this Agreement ) is entered into effective as of, by and between Trinity University, an agency and institution of higher
More informationDocument A401. Standard Form of Agreement Between Contractor and Subcontractor
TM Document A401 1997 Standard Form of Agreement Between Contractor and Subcontractor AGREEMENT made as of the day of in the year (In words, indicate day, month and year) BETWEEN the Contractor: (Name,
More informationApollo Engineering, LLC S. West Bayshore Rd. Suite 10 Traverse City, MI (231) Office
REQUEST FOR PROPOSAL BOILER REPLACEMENT INSTALLATION AT Lincoln Elementary School 810 E. 5th Avenue Sault Ste. Marie, Michigan 49783 Washington Elementary 1200 Ryan Avenue Sault Ste. Marie, MI 49783 Soo
More informationSUBCONTRACTOR AGREEMENT
SUBCONTRACTOR AGREEMENT THIS AGREEMENT MADE THIS DAY OF IN THE YEAR OF 2016 (In words, indicate day, month and year) BETWEEN DeWitt & Associates, Inc. 1256 South Barnes Springfield, Missouri 65804 AND:
More information2. Attachments a) Design Drawings Drawing(s) Revision Revision Date Specifications (T1.1-T2.8) N/A N/A A /06/17 A1.1 N/A N/A A2.
contractor ract and Scope of Work 8.812 ract To: contractor: LBA Construction LLC 2733 Ross Clark Circle Dothan, Alabama 36301 Scope: Window Film: Provide and install 7 mil shatter resistant window film
More informationPROPOSAL AND SPECIFICATIONS FOR FURNISH, HAULING AND SPREADING PROCESSED ROAD GRAVEL
CONTRACTOR 17GRAVEL2 PROPOSAL AND SPECIFICATIONS FOR FURNISH, HAULING AND SPREADING PROCESSED ROAD GRAVEL Furnish, Haul and Spread processed road gravel (22-A Modified or 21AA) at various locations in
More informationAPPENDIX A. Main Extension Agreement (MEA)
APPENDIX A Main Extension Agreement (MEA) Monroe County Water Authority MAIN EXTENSION AGREEMENT This MAIN EXTENSION AGREEMENT (the Agreement ) by the Monroe County Water Authority, a New York public benefit
More informationDIVISION OF HOUSING AND COMMUNITY RESOURCES WEATHERIZATION ASSISTANCE PROGRAM
CONTRACT FOR WEATHERIZATION SERVICES BETWEEN THE OF Agency name (Hereinafter referred to as the "Agency") AND Contractor name (Hereinafter referred to as the "Contractor") FOR CONTRACT # GRANT AGREEMENT
More informationMASTER SUBCONTRACT AGREEMENT
Back s Construction, Inc. 1602 Front Street, Suite 100 San Diego, CA 92101 Phone: 619-713-2566 Fax: 619-713-0992 MASTER SUBCONTRACT AGREEMENT This subcontract made and entered into this Monday, January
More informationDocument A104 TM. Standard Abbreviated Form of Agreement Between Owner and Contractor
Document A104 TM 2017 Standard Abbreviated Form of Agreement Between Owner and Contractor AGREEMENT made as of the Twenty Eighth day of June in the year Two Thousand Eighteen (In words, indicate day, month
More informationSUBCONTRACT AGREEMENT
200 Parr Boulevard, Richmond, CA 94801 p 510-234-0926 f 510-237-2435 www.overaa.com Subcontractor Contact Person Address Project Project Location Owner SUBCONTRACT AGREEMENT Phone No. Fax No. Subcontract
More information203(K) STANDARD OWNER/CONTRACTOR AGREEMENT
203(K) STANDARD OWNER/CONTRACTOR AGREEMENT Loan Number: : Provided By: Primary Borrower: CARRINGTON MORTGAGE SERVICES, LLC Property Address: Homeowner (s) ( Homeowner and/or Borrower ) FHA Case #: Address:
More informationANNEX A Standard Special Conditions For The Salvation Army
ANNEX A Standard Special Conditions For The Salvation Army TO BE ATTACHED TO AIA B101-2007 EDITION ABBREVIATED STANDARD FORM OF AGREEMENT BETWEEN OWNER AND ARCHITECT 1. Contract Documents. This Annex supplements,
More informationSUBCONTRACT AGREEMENT PROFESSIONAL SERVICES
SUBCONTRACT AGREEMENT PROFESSIONAL SERVICES This Subcontract Agreement (this Agreement ) is made this day of, 20, by and between LARON INCORPORATED, an Arizona corporation ( Contractor ), and ( Subcontractor
More informationIMPERIAL CONSTRUCTION, INC. 400 Interstate 20 Wet, Suite 200 Weatherford, Texas PHONE FACSIMILE
IMPERIAL CONSTRUCTION, INC. 400 Interstate 20 Wet, Suite 200 Weatherford, Texas 76086 817-341-8886 PHONE 817-341-0191 FACSIMILE BLANKET AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR (Building Construction)
More informationSTATE OF SOUTH CAROLINA ) ) CONTRACTOR AGREEMENT COUNTY OF HORRY )
STATE OF SOUTH CAROLINA ) ) CONTRACTOR AGREEMENT COUNTY OF HORRY ) THIS AGREEMENT is made this day of, 20, by and between Horry County, a political subdivision of the State of South Carolina, whose Administrative
More informationSECTION IV CONTRACT BID NUMBER
SECTION IV CONTRACT BID NUMBER 171006 THIS AGREEMENT made and entered into this day of, 2017, between PUBLIC UTILITY DISTRICT NO. 1 OF CLALLAM COUNTY (hereinafter called the "District") and, located at
More information