Request for Qualifications for Owner s Program Management Services For Wilton Police Headquarters Renovation and Expansion

Size: px
Start display at page:

Download "Request for Qualifications for Owner s Program Management Services For Wilton Police Headquarters Renovation and Expansion"

Transcription

1 Page 1 of 11 Request for Qualifications for Owner s Program Management Services For Wilton Police Headquarters Renovation and Expansion The Town of Wilton (the Town) will receive sealed qualifications to provide owner s program management services for the Police Headquarters Renovation and Expansion construction project in Wilton, Connecticut (the Project ). Qualifications are due no later than 2:00pm on November 30, 2018.

2 Page 2 of INTRODUCTION The Town of Wilton (the Town ) is soliciting statements of qualifications ( SOQ ) for owner s program management services to be provided by an experienced program manager ( Program Manager ) for renovation and expansion of the Wilton Police Department headquarters building (the Building ). This RFQ does not constitute a contract offer, and no contract will exist unless and until a written contract is executed by the Town and the selected Program Manager. Interested parties should submit an SOQ in accordance with the requirements and directions contained in this RFQ. Respondents are prohibited from contacting any Town employee, officer or other related officials, including members of the Building Committee, concerning this RFQ, except as set forth in Section 6. A respondent s failure to comply with this requirement may result in disqualification. If there are any conflicts between the provisions in these standard instructions and any other documents comprising this RFQ, these standard instructions shall prevail. 2. PROJECT DESCRIPTION A. Project Background The Building was constructed in The needs of the Wilton Police Department (the Department ) have changed significantly in the intervening years. The Town has concluded that the Building can no longer adequately serve the needs of the Department. B. Project Description The Town desires to provide additional space for the Department, including facilities to accommodate male and female officers. Space configuration will be determined during Phase I of the Project. The Building Committee has done substantial research and planning, and all of the documents and information produced and discovered to date will be shared with the selected respondent. The Town anticipates that construction will be completed by multiple trade contractors. The Town anticipates that a construction manager will be retained to manage various aspects of the Project. It is possible that the Town will request the Program Manager to expand its scope of services to include services customarily performed by a construction manager. C. Contract The successful respondent will be expected to enter into a contract with the Town in the form of AIA Document C , Standard Form of Agreement Between Owner and Program Manager (the Program Manager Agreement ). The Program Manager Agreement may be superseded by an AIA Document C132, Standard Form of Agreement Between Owner and Construction Manager if the Program Manager is retained in the role of construction manager. D. General Description of Phases and Responsibilities Phase I (Design Development) The Town expects to engage an architect with experience in law enforcement facilities to develop the design from concept to final. When the Building Committee is satisfied that the design has sufficient details to enable a preliminary construction and Project budgets to be established, it will seek approval from the Board of Selectmen ( BOS ) to proceed to Phase II. The Program Manager will be expected to materially assist the Building Committee throughout Phase I.

3 Page 3 of 11 Phase II (Bid Documents) Following approval from the BOS, the Building Committee, working with the Program Manager and the architect, will develop bid documents so that accurate pricing can be obtained. The Program Manager will assist with the development of these documents, providing value engineering where appropriate, and ensuring that all of the specifications of the architect s plans are appropriately met. Phase III (Bids and Awards) The Program Manager will assist the Town in the development and issuance of bid packages. Bid packages will include AIA contract documents, including a bid bond, performance bond and labor and materials payment bond, unless otherwise directed. The Program Manager will obtain legal clearance from the Town s attorney of a sample bid package prior to commencement of bidding on trade contracts. The Program Manager will review the bids for each trade for appropriateness and completeness and shall advise the Town accordingly. For each trade contract, the Program Manager will coordinate the assembly of the successful bidder s construction contract, bonds and insurance certificate(s) and deliver the assembled package to the Town s attorney for legal clearance. Upon receipt of legal clearance, the Program Manager will present the trade contract to the Town for approval and execution by the First Selectwoman. Subsequent Phases The Program Manager may be retained by the Town to assist in the daily management of the Project in all phases of the construction from site preparation to the issuance of a Certificate of Occupancy. 3. DETAILED SCOPE OF SERVICES Note: The Town may or may not choose to engage the Program Manager beyond the bidding stage. Similarly, the Town may choose to engage the Program Manager to serve in the role of construction manager or to retain some other party to serve in the role of construction manager. The following is intended to represent the full scope of possible services so that the respondent can demonstrate evidence of his/her qualifications for such work. The scope of services for the Project will be as described in this RFQ (the Services ). All Services shall be performed in a manner consistent with all applicable federal, state and local statutes, regulations, ordinances and laws, and the Program Manager Agreement. In general, the Services expected by the Town to be provided by the Program Manager will consist of the following. Basic Services Summary 1. Work with the Town, the design team, and potentially the construction manager to provide oversight, consultation and advice in the program management, design, construction, commissioning, and closeout of the Project. 2. Provide ongoing professional input on the construction manager s master budget and schedule for the Project; monitor and report regularly. 3. Ensure that the requirements for, and review of, surety bonds, insurance certificates, schedule of values, certified payrolls, staffing and schedules are being maintained. 4. Attend all meetings when requested by Town relating to the Project. 5. Oversee the construction manager s monthly written reports to the Town indicating the financial and schedule status of the Project.

4 Page 4 of Evaluate and monitor procedures established by the architect and construction manager for quality assurance and quality control during construction. 7. Review, evaluate and monitor required federal, state and local approvals and permits to ensure that all the proper inspections, permits and approvals are obtained. 8. Review, evaluate and monitor the construction manager s project controls program and construction planning process. 9. Review and evaluate construction manager s procedures for bid packaging, bonding, safety, scheduling, material delivery management and shop drawings. 10. Evaluate and monitor the construction manager s procedure for change order pricing and processing. 11. Evaluate and monitor the construction manager s procedure for the review, recommendation, processing and payment of all payment applications. 12. Evaluate and audit as necessary the Project for schedule, cost and quality. 13. Review and evaluate construction manager s procedures for communication and coordination among subcontractors, designers and suppliers. 14. Review and evaluate the construction manager s system of cost control. Ensure that the trade contractors' current cost forecast reflects potential, approved, and pending changes and develop cash flow forecasts on a monthly basis. 15. Ensure the timely and proper turnover to Town of all as-built drawings, operations and maintenance manuals, warranties, and coordinate all training/instruction periods. 16. Work with the commissioning consultant to develop the final commissioning, close out and punch list procedures for the Project. 17. Review and monitor safety programs for the Project as developed by the construction manager. 18. Assist the construction manager in the coordination of the commissioning and start-up for the building systems and the turnover of the Project to the Town. 19. Review and accept all close-out documentation on behalf of the Town and ensure that all such documentation is received prior to the final close-out of the Project. Administrative 1. Establish a listing of responsible parties for the review of Project submittals, including bonds, insurance, a schedule of values, project supervision, project schedules and the Town required documents. 2. Attend construction manager/contractor meetings and construction managar/architect meetings to provide status reports and update the Town and the Building Committee on construction, and closeout activities. 3. Review and comment on corresponding budgets and schedules. 4. Provide other enhancements to the program management services that will ensure efficient and cost effective implementation. 5. Evaluate existing procedure for the review, evaluation, approval, and processing of payment applications from the architect, construction manager, commissioning consultant, contractors and suppliers. 6. Prepare monthly executive summary reports, addressing scope, budget, schedule, issues, and cash-flow projections for the Town officials. The Program Manager s services shall be generally divided into the following phases:

5 Page 5 of 11 Project Integration 1. Review and become familiar with the following documents. a. Architect s, construction manager s, commissioning agent and environmental consultant s contracts. b. Construction manager s 100% design development budget, with value engineering items identified. c. 100% design development documents, updated cost estimates and value engineering logs. d. Construction manager s 50% construction documents cost estimates. 2. Meet with team members (architect, construction manager, commissioning consultant, Town personnel. 3. Prepare and update an open issues list for review with the Building Committee. 4. Work with the Director of Public Works and the Building Committee to identify incentive or grant programs that could benefit both the Project and the Town financially as well as to promote energy efficiency. Construction Phase 1. Review and evaluate the construction manager s procedure for requesting, evaluating and awarding purchase orders and construction contracts. 2. Attend bid evaluation meetings. Review and evaluate recommendations for award of purchase orders and construction contracts. 3. Coordinate legal clearance of contract packages of each trade contract. 4. Provide on-site staff, as necessary, to monitor construction. Review, evaluate and audit as necessary each phase of the Project to determine completion in accordance with objectives of cost, time and quality. 5. Provide reasonable oversight of the design. 6. Provide owner-level scheduling and estimating services in overseeing Project progress. 7. Review and evaluate the on-site organization and lines of authority to determine whether they are sufficient to carry out the Project and make suggestions as appropriate. 8. Review and evaluate the construction manager s procedures for communication and coordination among the architect, suppliers and trade contractors with respect to all aspects of the Project. Monitor the implementation of such procedures. 9. Review and evaluate the Project as construction progresses. Identify potential variances between scheduled and probable start and completion dates. Suggest possible "work-around" schedules or recovery plans to avoid or mitigate delays. 10. Review and evaluate construction manager s system of Project cost control to ensure that the construction manager revises and refines the initially approved Project budget to incorporate approved changes as they occur and develop cash flow reports and forecasts as needed. Review and evaluate variance between actual and budgeted or estimated costs as presented by construction manager. Develop and suggest cost/budget recovery plans as necessary. 11. Review and evaluate the construction manager s procedures for the preparation, review and processing of payment applications and suggest changes as appropriate. Monitor the implementation of such procedures. After architect s review, review and evaluate each application; provide recommendation for processing by the Town. 12. Review and evaluate the construction manager s procedures for the preparation, review and processing of change orders and suggest changes as appropriate. Monitor the implementation of such procedures. Review and evaluate requests and recommendations for changes; assist with negotiations. 13. Assist in obtaining permits and approvals that are the Town s responsibility and monitor the status of permits and approvals that are construction manager s and/or the trade contractors responsibility.

6 Page 6 of Assist the Town in selecting and retaining professional services such as testing laboratories, special inspection services, etc.; coordinate these services with end users and construction manager, as necessary. 15. Review and evaluate the construction manager s procedures for processing and approving shop drawings and samples. Monitor the implementation of such procedures, as well as timeliness of submittals and reviews of same. 16. Review and comment as appropriate on all written monthly progress reports to the Town from the construction manager, including information with respect to design, construction management, construction and the percentage of completion. 17. Review procedures for the identification, review, analysis, and resolution of potential claims and/or disputes. Recommend improvements to same. Monitor the construction manager s and architect s adherence to these procedures. 18. Review and evaluate the construction manager s procedure for obtaining and maintaining a current set of record drawings, specifications and operating manuals. Provide assessment and recommendations. 19. Review and evaluate the construction manager s procedures for obtaining documents of all required guaranties and warranties. Review and evaluate all such warranties and guaranties to determine compliance with requirements. Provide assessment and recommendations. 20. Review and evaluate construction manager s procedures for delivery of maintenance and operation manuals. Provide assessment and recommendations. 21. Review and evaluate construction manager s procedures for Project close out. Provide assessment and recommendations. Closeout Timely and thorough closeout of the Project is critical. 1. Track progress of assembly and delivery of Operation and Maintenance Manuals (O&Ms). 2. Review Operating and Maintenance manuals for completeness and adherence to contract documents. 3. Oversee commissioning consultant s work on the Project; support their necessary integration into the Project timeline at the appropriate 4. Ensure As-Built drawings are accurate and delivered in a timely manner according to contract requirements. 5. Organize, manage, expedite and monitor punch list and Project close out issues after substantial completion. 4. SELECTION PROCESS A. Schedule Request for Qualifications Issued November 9, 2018 Questions Due Date November 19, 2018 Proposal Due Date November 30, 2018 Tentative Interview Date Week of December 10-14, 2018 Estimated Award Date December 18, 2018 B. Desired Qualifications The Town expects each respondent to meet at least the following minimum qualifications. 1. Proven experience of successfully managing the scope, schedule, and budget of similar sized police facilities in Connecticut.

7 Page 7 of Proven capabilities to communicate (both transmitting and receiving ), both written and oral, with a variety of parties. 3. Experience serving as an owner s program manager on at least three (3) similarly sized police construction projects. Preference will be given to respondents with experience serving as a project manager on municipal construction projects in Connecticut. C. Evaluation Criteria Firms or individuals who meet the desired qualifications set forth above and who comply with the requirements of this RFQ will be evaluated based on the following evaluation criteria. CRITERIA POINTS Relevant Project Experience 35 Project Team Qualifications 35 Project Approach 30 Total Possible Points 100 The Town will base its initial ranking of respondents on the above evaluation criteria. If necessary, the Town will conduct interviews. 5. SUBMISSION REQUIREMENTS Proposals shall include the following information. I. Executive Summary Please provide a narrative history of your firm and its relevant owner s program management experience. II. Relevant Project Experience Reference a minimum of three (3) relevant owner s program management projects of similar type and scale to this scope. Include project name, location, brief description, year commenced and completed, and total square feet, and a client reference. Include the name, telephone number and address of a contact person for the owner of each project. III. Proposed Project Team Provide an organization chart and resumes for all key personnel. For each of the key personnel provide a resume that includes the following information. Relevant background, credentials and experience with specific project of comparable nature and scope. Clearly defined roles and responsibilities as well as estimated time commitment to this Project.

8 Page 8 of 11 IV. Project Approach Include your project understanding, approach and methodology, and key elements and factors which differentiate your firm from your competition. Description of your proposed project management information system (a web-based system is preferred). V. Fee Proposal A comprehensive budget for the total fees is not required at this time. A. The fee shall be indicated by such measure or measures as the respondent deems appropriate, including, without limitation, fixed fee, percentage of the cost of work or hourly rates. B. The proposal shall include a list of the hourly rates for all personnel who are likely to perform work on the Project. The respondent shall address how the respondent proposes to address expenses, including travel, overhead and profit and direct expenses. VI. Company Profile A. Description of company ownership structure (professional corporation, sole proprietor, partnership, etc). B. Corporations and limited liability companies must identify the state and date of incorporation/organization. C. Dun and Bradstreet number. D. Federal Tax Identification Number (EIN). E. Description of any significant prior or ongoing contract failures (actual or alleged), contract breaches, any civil or criminal litigation or investigation pending which involves the respondent or in which the respondent has been judged guilty or liable. F. Location(s) of all company offices and location of the office that will provide the Services. G. Number of employees both locally and nationally. H. Description of professional licenses held by individuals responsible for the Services and proof of current licensure. I. Location(s) from which employees will be assigned to the Services. J. Name, address and contact information of the individual responsible for the Services. K. Description of the respondent s background/history and explanation as to why the respondent is qualified to provide the Services. L. Length of time the respondent has been providing program management services to the public and/or private sector. Provide a brief description, including approximate number and geographic location of projects/assignments. M. Statement as to whether or not the respondent has ever been engaged under contract by any Town agency. Provide a brief description of each engagement. N. A list of all proposed persons including consultants and subcontractors who will assisting in the performance of the Services who are currently employed or have ever been employed by the Town. O. Resumes of the key staff that will be responsible for performance of the Services. P. Statement that respondent maintains insurance policies meeting or exceeding the requirements indicated in Exhibit A and will furnish evidence of insurance to the Town upon request. Q. Statement that no conflict of interest issues would exist if contracted to perform the Services, while under contract with the Town.

9 Page 9 of QUESTIONS AND AMENDMENTS Any questions regarding the RFQ should be directed to the contact listed below via by end of business on November 19, 2018 Chris Burney Director, Public Works, Facilities, and Energy Management Town of Wilton 238 Danbury Road Wilton, CT Chris.burney@wiltonct.org Answers to questions will be posted on the Town s website RIGHT OF REJECTION AND CLARIFICATION The Town reserves the right to reject any and all SOQs. 8. INDEPENDENT CONTRACTOR The Program Manager shall be and operate as an independent contractor in the performance of the program management services. The Program Manager shall have complete charge of the personnel proposed as part of its team, and all persons employed by the Program Manager shall be employees of the Program Manager and not employees of the Town in any respect. 9. COMPLIANCE WITH LAWS The Program Manager shall comply with all applicable laws, bylaws and regulations, federal, state, local government, and any political subdivision thereof, including but not limited to, unemployment and workers' compensation, occupational safety, equal employment and affirmative action and wage and price laws insofar as applicable to the performance of the contract. 10. SUB-CONTRACTORS The selected Program Manager shall be prohibited from subcontracting any of its work or services to be performed to others without the express prior written consent of the Town. 11. NONDISCLOSURE The Program Manager firm agrees that it will not divulge to third parties, without the written consent of the Town, any information obtained from or through the Town, the architect or others in connection with the Project, except to the extent necessary to comply with this RFQ.

10 Page 10 of SUBMISSION DEADLINE One (1) signed original, three (3) identical hard copies and one (1) e-copy (CD or Memory Stick) of the SOQ must be sent to following address by 2:00pm on November 30, It is the responsibility of the respondent to ensure that the SOQ is received by the recipient below. Failure of any delivery service including, but not limited to the United States Postal Service, Fed-Ex, UPS or such shall not be grounds for the acceptance of delayed delivery of proposals. Note that SOQs cannot be ed. Jacqueline Rochester Office of the First Selectman Town of Wilton 238 Danbury Road Wilton, CT 06897

11 Page 11 of 11 EXHIBIT A INSURANCE REQUIREMENTS 1. Workers Compensation. Workers compensation insurance required by law with employer s liability limits for at least the amounts of liability for bodily injury by accident of $500,000 each accident and bodily injury by disease of $500,000 including a waiver of subrogation. 2. Commercial General Liability. Commercial general liability insurance including products and completed operations and including XCU coverage if applicable. Limits shall be at least: Bodily injury & property damage coverage with an occurrence limit of $1,000,000; Personal & advertising injury limit of $1,000,000 per occurrence; General aggregate limit of $2,000,000 (other than products and completed operations); Products and completed operations aggregate limit of $2,000,000. Coverage will continue three years after the completion of the work. The policy shall name the Town as an additional insured and include ISO Form CG 2010 (04/13) and CG 2037 (04/13) or equivalent. The coverage will be provided on an occurrence basis and shall be primary and shall not contribute in any way to any insurance or self-insured retention carried by the Town. The policy shall contain a waiver of subrogation in favor of the Town. The coverage shall contain a broad form contractual liability endorsement or wording within the policy form to comply with the hold harmless and indemnity provision(s) of all agreements between the Town and the respondent. A per project aggregate limit of liability endorsement shall apply for any construction contract. Deductible and self-insured retentions shall be declared and are subject to the approval of the Town. 3. Commercial Automobile. Commercial automobile insurance for any owned, non-owned or hired autos, in the amount of $1,000,000 each accident covering bodily injury and property damage on a combined single limit basis. The policy shall name the Town as an additional insured and provide a waiver of subrogation. 4. Umbrella or Excess Liability. Umbrella or excess liability policy in excess (without restriction or limitation) of those limits and coverages described in items (1) through (3) above. The policy shall contain limits of liability in the amount of $5,000,000 each occurrence and $5,000,000 in the aggregate. The Town reserves the right to require higher limits of umbrella or excess liability coverage depending on the scope of the agreement. 5. Errors & Omissions. Errors & omissions insurance for liability resulting from the negligent performance of professional duties or operations. The policy shall contain limits of liability in the amount of $1,000,000 each claim and $3,000,000 in the aggregate. The policy shall name the Town as an additional insured and provide a waiver of subrogation.

The Town of Wilton. 238 Danbury Rd. Wilton, CT 06897

The Town of Wilton. 238 Danbury Rd. Wilton, CT 06897 The Town of Wilton 238 Danbury Rd Wilton, CT 06897 The Town of Wilton is requesting sealed proposals for the provision of a new potable water supply to Fire House #2 located at 707 Ridgefield Rd, Wilton,

More information

FAYETTE COUNTY SCHOOL DISTRICT REQUEST FOR PROPOSAL FOR CONSTRUCTION MANAGEMENT AT RISK SERVICES

FAYETTE COUNTY SCHOOL DISTRICT REQUEST FOR PROPOSAL FOR CONSTRUCTION MANAGEMENT AT RISK SERVICES FAYETTE COUNTY SCHOOL DISTRICT REQUEST FOR PROPOSAL FOR CONSTRUCTION MANAGEMENT AT RISK SERVICES The Fayette County School District (FCSD) desires to retain the services of a professional Construction

More information

Town of Manchester, Connecticut General Services Department. Request for Proposals for Fingerprinting Services 17/18-85.

Town of Manchester, Connecticut General Services Department. Request for Proposals for Fingerprinting Services 17/18-85. Town of Manchester, Connecticut General Services Department Request for Proposals for Fingerprinting Services 17/18-85 Proposals Due: May 29, 2018 @ 4:00 P.M. General Services Department 494 Main St. Manchester,

More information

INDOOR BLEACHER SAFETY RAILS MANDATORY WALK-THRU ON MONDAY, MAY 16, 2016 AT 10:00 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD.

INDOOR BLEACHER SAFETY RAILS MANDATORY WALK-THRU ON MONDAY, MAY 16, 2016 AT 10:00 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD. SPECIFICATIONS AND BID FORMS FOR INDOOR BLEACHER SAFETY RAILS MANDATORY WALK-THRU ON MONDAY, MAY 16, 2016 AT 10:00 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD., WESTON, CT 06883 BID: #16-007- BOE Due on

More information

REQUEST FOR QUALIFICATIONS (RFQ) Central Valley Opportunity Center Winton Vocational Training Center Project Proposals Due: February 21, 2014

REQUEST FOR QUALIFICATIONS (RFQ) Central Valley Opportunity Center Winton Vocational Training Center Project Proposals Due: February 21, 2014 REQUEST FOR QUALIFICATIONS (RFQ) Central Valley Opportunity Center Winton Vocational Training Center Project Proposals Due: February 21, 2014 The Central Valley Opportunity Center ( CVOC ) is soliciting

More information

Request For Qualifications Construction Management at Risk

Request For Qualifications Construction Management at Risk Request For Qualifications Construction Management at Risk DAVIE COUNTY HIGH SCHOOL REPURPOSING PROJECT SOLICITATION: REC-2018-020 Representative for RFQ: Brad Blackwelder bblackwelder@daviecountync.gov

More information

AGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER PRE-CONSTRUCTION AND CONSTRUCTION SERVICES

AGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER PRE-CONSTRUCTION AND CONSTRUCTION SERVICES AGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER PRE-CONSTRUCTION AND CONSTRUCTION SERVICES AGREEMENT made by and between, hereinafter called the Owner, and SITESCOMMERCIAL, LLC 185 WIND CHIME COURT, SUITE

More information

Charlotte-Mecklenburg Schools. Request for Qualifications

Charlotte-Mecklenburg Schools. Request for Qualifications Charlotte-Mecklenburg Schools Request for Qualifications Move Management Services December 2, 2018 Table of Contents Section 1 - ADVERTISEMENT...3 Section 2 INTRODUCTION/OVERVIEW/GENERAL INFORMATION...4

More information

TOWN OF FARMINGTON REQUEST FOR PROPOSALS INSURANCE / RISK MANAGEMENT SERVICES

TOWN OF FARMINGTON REQUEST FOR PROPOSALS INSURANCE / RISK MANAGEMENT SERVICES TOWN OF FARMINGTON REQUEST FOR PROPOSALS INSURANCE / RISK MANAGEMENT SERVICES GENERAL INFORMATION 1. Issuing Office: This Request for Proposals (RFP) is issued by the Town of Farmington, Finance Office.

More information

WESTON HIGH SCHOOL BLEACHER REPAIRS MANDATORY WALK-THRU, MONDAY, JUNE 15, AT 10:30 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD., WESTON, CT

WESTON HIGH SCHOOL BLEACHER REPAIRS MANDATORY WALK-THRU, MONDAY, JUNE 15, AT 10:30 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD., WESTON, CT SPECIFICATIONS AND BID FORMS FOR WESTON HIGH SCHOOL BLEACHER REPAIRS MANDATORY WALK-THRU, MONDAY, JUNE 15, AT 10:30 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD., WESTON, CT 06883. BID: #15-013 BOE Due on

More information

REQUEST FOR PROPOSALS For On-Call Construction Inspection Services CITY OF SAN MATEO, CALIFORNIA

REQUEST FOR PROPOSALS For On-Call Construction Inspection Services CITY OF SAN MATEO, CALIFORNIA REQUEST FOR PROPOSALS For On-Call Construction Inspection Services CITY OF SAN MATEO, CALIFORNIA The City of San Mateo Public Works Department hereby requests proposals from qualified firms to provide

More information

WINDSOR NORTH WEST PARK NATURE CENTER ADDITION AND STRUCTURE PROJECT 145 LANG ROAD. WINDSOR, CT

WINDSOR NORTH WEST PARK NATURE CENTER ADDITION AND STRUCTURE PROJECT 145 LANG ROAD. WINDSOR, CT INVITATION TO BID Contractor Services Associated with: WINDSOR NORTH WEST PARK NATURE CENTER ADDITION AND STRUCTURE PROJECT 145 LANG ROAD. WINDSOR, CT 06095 THIS IS AN INVITATION FOR BIDS AND THE TOWN

More information

TOWN OF PEMBROKE PARK REQUEST FOR PROPOSALS (RFP) PROFESSIONAL FINANCIAL ACCOUNTING SERVICES

TOWN OF PEMBROKE PARK REQUEST FOR PROPOSALS (RFP) PROFESSIONAL FINANCIAL ACCOUNTING SERVICES TOWN OF PEMBROKE PARK REQUEST FOR PROPOSALS (RFP) PROFESSIONAL FINANCIAL ACCOUNTING SERVICES I. PROJECT DESCRIPTION Town of Pembroke Park, Florida ( Town ) is soliciting proposals from interested accounting

More information

PROPOSAL LIQUID CALCIUM CHLORIDE

PROPOSAL LIQUID CALCIUM CHLORIDE Gary Hammond, P.E. Commissioner of Public Works Tioga County Department of Public Works 477 Route 96 Owego, New York 13827 (607) 687-0302 Fax (607) 687-4453 Richard Perkins, P.E. Deputy Commissioner of

More information

Center Township Butler County, Pennsylvania REQUEST FOR PROPOSALS AND QUALIFICATIONS FOR PROFESSIONAL ENGINEERING SERVICES

Center Township Butler County, Pennsylvania REQUEST FOR PROPOSALS AND QUALIFICATIONS FOR PROFESSIONAL ENGINEERING SERVICES Butler County, Pennsylvania REQUEST FOR PROPOSALS AND QUALIFICATIONS FOR PROFESSIONAL ENGINEERING SERVICES Submission deadline: 4:00 p.m. Wednesday, December 7, 2011 I. General Center Township Butler County,

More information

West Ridge Park Ballfield Light Pole Structural Assessment

West Ridge Park Ballfield Light Pole Structural Assessment Request for Proposal Professional Services October 3, 2017 West Ridge Park Ballfield Light Pole Structural Assessment West Ridge Park 636 Ridge Rd. Highland Park, IL 60035 Submission Deadline: Tuesday,

More information

REQUEST FOR PROPOSALS (RFP) FULL COST ALLOCATION STUDY AND USER FEE STUDY. City of Foster City, California. Financial Services Department

REQUEST FOR PROPOSALS (RFP) FULL COST ALLOCATION STUDY AND USER FEE STUDY. City of Foster City, California. Financial Services Department REQUEST FOR PROPOSALS (RFP) FULL COST ALLOCATION STUDY AND USER FEE STUDY City of Foster City, California Financial Services Department 610 Foster City Blvd. Foster City, CA 94404 (650) 286-3200 July 7,

More information

ANNEX A Standard Special Conditions For The Salvation Army

ANNEX A Standard Special Conditions For The Salvation Army ANNEX A Standard Special Conditions For The Salvation Army TO BE ATTACHED TO AIA B101-2007 EDITION ABBREVIATED STANDARD FORM OF AGREEMENT BETWEEN OWNER AND ARCHITECT 1. Contract Documents. This Annex supplements,

More information

REQUEST FOR PROPOSALS

REQUEST FOR PROPOSALS REQUEST FOR PROPOSALS Covington Point Lift Station Improvements CCE PROJECT NO. 812-100(C) February 21, 2013 PREPARED BY: CITY OF COVINGTON 317 NORTH JEFFERSON AVENUE COVINGTON, LOUISIANA 70433 I. REQUEST

More information

REQUEST FOR PROPOSAL (RFP) OWNER S REPRESENTATION/PROJECT MANAGER. New Combined Court Facility In Montezuma County

REQUEST FOR PROPOSAL (RFP) OWNER S REPRESENTATION/PROJECT MANAGER. New Combined Court Facility In Montezuma County REQUEST FOR PROPOSAL (RFP) OWNER S REPRESENTATION/PROJECT MANAGER New Combined Court Facility In Montezuma County 12/11/2015 Prepared by: Montezuma County 109 W. Main, Room 302 Cortez, CO 81321 Melissa

More information

COWLEY COUNTY, KANSAS REQUEST FOR PROPOSAL. SALARY STUDY SUBMITTAL DEADLINE June 1, 2012 RFP NUMBER

COWLEY COUNTY, KANSAS REQUEST FOR PROPOSAL. SALARY STUDY SUBMITTAL DEADLINE June 1, 2012 RFP NUMBER REQUEST FOR PROPOSAL SALARY STUDY SUBMITTAL DEADLINE June 1, 2012 RFP NUMBER 12-001 1. BACKGROUND INFORMATION: COWLEY COUNTY, KANSAS SCOPE OF SERVICES Cowley County, a municipal corporation existing under

More information

City of Jeffersontown. Request for Qualifications ON-CALL. Electrical Services

City of Jeffersontown. Request for Qualifications ON-CALL. Electrical Services City of Jeffersontown Request for Qualifications ON-CALL Electrical Services Table of Contents Request of Qualifications I. Invitation and Instructions to Interested Firms II. III. IV. General Provisions

More information

REQUEST FOR PROPOSAL FOR AUDIT SERVICES City of Yreka, California Dated February 08, 2018

REQUEST FOR PROPOSAL FOR AUDIT SERVICES City of Yreka, California Dated February 08, 2018 REQUEST FOR PROPOSAL FOR AUDIT SERVICES City of Yreka, California Dated February 08, 2018 RETURN PROPOSALS TO: Rhetta Hogan Finance Department City of Yreka 701 Fourth Street Yreka, CA 96097 DEADLINE FOR

More information

REQUEST FOR QUALIFICATIONS FOR DESIGN SERVICES FOR BRADFORD PARK SOFTBALL COMPLEX PARKING LOT EXPANSION

REQUEST FOR QUALIFICATIONS FOR DESIGN SERVICES FOR BRADFORD PARK SOFTBALL COMPLEX PARKING LOT EXPANSION REQUEST FOR QUALIFICATIONS FOR DESIGN SERVICES FOR BRADFORD PARK SOFTBALL COMPLEX PARKING LOT EXPANSION TOWN OF HUNTERSVILLE, NORTH CAROLINA 1.0 PURPOSE The Town of Huntersville is accepting Request for

More information

TOWN OF MANCHESTER GENERAL SERVICES DEPARTMENT 494 MAIN STREET PO BOX 191 MANCHESTER, CONNECTICUT (860) FAX (860)

TOWN OF MANCHESTER GENERAL SERVICES DEPARTMENT 494 MAIN STREET PO BOX 191 MANCHESTER, CONNECTICUT (860) FAX (860) TOWN OF MANCHESTER GENERAL SERVICES DEPARTMENT 494 MAIN STREET PO BOX 191 MANCHESTER, CONNECTICUT 06045-0191 (860) 647-3031 FAX (860) 647-5206 REQUEST FOR PROPOSAL FOR ELECTRONICS RECYCLING RFP NO. 17/18-91

More information

CAPITOL REGION PURCHASING COUNCIL REQUEST FOR PROPOSAL (RFP) FOR E-PROCUREMENT SYSTEM. Issue Date: January 14, 2019

CAPITOL REGION PURCHASING COUNCIL REQUEST FOR PROPOSAL (RFP) FOR E-PROCUREMENT SYSTEM. Issue Date: January 14, 2019 CAPITOL REGION PURCHASING COUNCIL REQUEST FOR PROPOSAL (RFP) FOR E-PROCUREMENT SYSTEM Issue Date: January 14, 2019 Deadline for Questions: January 30, 2019 Response Date/Time: February 20, 2019 (2:00 p.m.

More information

WESTON SCHOOL DISTRICT BOILER CLEANING. MANDATORY WALK-THRU, MONDAY, April 24, AT 10:30 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD., WESTON, CT

WESTON SCHOOL DISTRICT BOILER CLEANING. MANDATORY WALK-THRU, MONDAY, April 24, AT 10:30 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD., WESTON, CT SPECIFICATIONS AND BID FORMS FOR WESTON SCHOOL DISTRICT BOILER CLEANING MANDATORY WALK-THRU, MONDAY, April 24, AT 10:30 A.M. AT CENTRAL OFFICE ANNEX, 24 SCHOOL RD., WESTON, CT 06883. BID: # 17-002BOE_

More information

LEGAL NOTICE TOWN OF MADISON REQUEST FOR PROPOSALS FOR PROFESSIONAL AUDITING SERVICES FEBRUARY 15, 2017

LEGAL NOTICE TOWN OF MADISON REQUEST FOR PROPOSALS FOR PROFESSIONAL AUDITING SERVICES FEBRUARY 15, 2017 LEGAL NOTICE TOWN OF MADISON REQUEST FOR PROPOSALS FOR PROFESSIONAL AUDITING SERVICES FEBRUARY 15, 2017 The Town of Madison, Connecticut is requesting proposals from qualified firms of certified public

More information

REQUEST FOR PROPOSALS PROFESSIONAL CONSULTING SERVICES RFP

REQUEST FOR PROPOSALS PROFESSIONAL CONSULTING SERVICES RFP REQUEST FOR PROPOSALS FOR PROFESSIONAL CONSULTING SERVICES RFP 252018 Town of Scarborough P.O. Box 360 259 U.S. Route One Scarborough, Maine 04070-0360 Released on April 12, 2018 Proposals Due on May 7,

More information

Request For Proposal. For Construction Management Services. For The. Benton County Jail and Sheriff s Office

Request For Proposal. For Construction Management Services. For The. Benton County Jail and Sheriff s Office For For The Issue Date: June 1, 2018 Due Date: June 25, 2018 by 10:00 a.m. Central Time Submit RFP to: Benton County Commission c/o Michelle McLerran Kreisler P.O. Box 1238 316 Van Buren Warsaw, Missouri

More information

ARCHITECT OF RECORD & DSA CLOSEOUT CERTIFICATION SERVICES RFQ# 029

ARCHITECT OF RECORD & DSA CLOSEOUT CERTIFICATION SERVICES RFQ# 029 CITY COLLEGE OF SAN FRANCISCO REQUEST FOR QUALIFICATIONS #029 ARCHITECT OF RECORD & DSA CLOSEOUT CERTIFICATION SERVICES RFQ# 029 Respond to: Purchasing/City College of San Francisco 33 Gough Street San

More information

TOWN OF GUILFORD REQUEST FOR QUALIFICATIONS AND PROPOSALS RFQ/RFP # PENSION and OTHER POST-EMPLOYMENT BENEFITS ACTUARIAL SERVICES

TOWN OF GUILFORD REQUEST FOR QUALIFICATIONS AND PROPOSALS RFQ/RFP # PENSION and OTHER POST-EMPLOYMENT BENEFITS ACTUARIAL SERVICES TOWN OF GUILFORD REQUEST FOR QUALIFICATIONS AND PROPOSALS RFQ/RFP #3-1819 PENSION and OTHER POST-EMPLOYMENT BENEFITS ACTUARIAL SERVICES TABLE OF CONTENTS I. LEGAL NOTICE. 2 II. GENERAL SPECIFICATIONS....

More information

REQUEST FOR QUALIFICATIONS/ PROPOSALS LEASE-LEASEBACK CONTRACTOR FOR

REQUEST FOR QUALIFICATIONS/ PROPOSALS LEASE-LEASEBACK CONTRACTOR FOR SANTA BARBARA UNIFIED SCHOOL DISTRICT REQUEST FOR QUALIFICATIONS/ PROPOSALS LEASE-LEASEBACK CONTRACTOR FOR Multi-Purpose Building Renovation Projects at Harding University Partnership School and Roosevelt

More information

AIA Document A201 TM 1997

AIA Document A201 TM 1997 AIA Document A201 TM 1997 General Conditions of the Contract for Construction for the following PROJECT: (Name and location or address): Project University of Maine at Farmington THE OWNER: (Name and address):

More information

REQUEST FOR QUALIFICATIONS

REQUEST FOR QUALIFICATIONS REQUEST FOR QUALIFICATIONS FOR DESIGN SERVICES BROUGHAM DRIVE REGIONAL DETENTION PN 2-C-002-16 SMP #: BR-09-001 January 13, 2017 RFQ-1 I. INTRODUCTION AND BACKGROUND The City of Olathe, Kansas, Public

More information

REQUEST FOR QUALIFICATIONS (RFQ) FOR DSA INSPECTOR OF RECORD (IOR) SERVICES

REQUEST FOR QUALIFICATIONS (RFQ) FOR DSA INSPECTOR OF RECORD (IOR) SERVICES REQUEST FOR QUALIFICATIONS (RFQ) FOR DSA INSPECTOR OF RECORD (IOR) SERVICES ALVORD UNIFIED SCHOOL DISTRICT Angie Lopez, Director of Facilities Planning 10365 Keller Avenue Riverside, CA 92505 VARIOUS PROJECTS

More information

SHORT FORM STANDARD SUBCONTRACT. This Agreement is made this day of, 20, between

SHORT FORM STANDARD SUBCONTRACT. This Agreement is made this day of, 20, between SHORT FORM STANDARD SUBCONTRACT This Agreement is made this day of, 20, between (Contractor) and (Subcontractor). The work described in Section I below shall be performed in accordance with the prime contract

More information

Management of Jobing.com Arena

Management of Jobing.com Arena Request for Proposal Related to: Management of Jobing.com Arena Issued by: (Date) Introduction The (City), through its Materials Management Department, is accepting responses to this Request for Proposal

More information

REQUEST FOR PROPOSALS FOR General Counsel Legal Services

REQUEST FOR PROPOSALS FOR General Counsel Legal Services REQUEST FOR PROPOSALS FOR General Counsel Legal Services RFP Issued: October 6, 2017 RFP Submission Deadline: November 1, 2017 Issued by: Colusa Groundwater Authority 100 Sunrise Blvd., Suite A Colusa,

More information

REQUEST FOR PROPOSAL (RFP) for PROFESSIONAL CONSULTING SERVICES. to perform an

REQUEST FOR PROPOSAL (RFP) for PROFESSIONAL CONSULTING SERVICES. to perform an REQUEST FOR PROPOSAL (RFP) for PROFESSIONAL CONSULTING SERVICES to perform an ANALYSIS OF IMPEDIMENTS TO FAIR HOUSING CHOICE 24 C.F.R. 570.601 (a) (2) 24 C.F.R. 91.225 (a) June 27, 2011 ALL PROPOSALS ARE

More information

TOWN OF MANCHESTER REQUEST FOR PROPOSAL RFP NO. 15/16-32 FOR RISK MANAGEMENT CONSULTANT SERVICES PROPOSALS DUE: NOVEMBER 13, 4:00 P.M.

TOWN OF MANCHESTER REQUEST FOR PROPOSAL RFP NO. 15/16-32 FOR RISK MANAGEMENT CONSULTANT SERVICES PROPOSALS DUE: NOVEMBER 13, 4:00 P.M. TOWN OF MANCHESTER REQUEST FOR PROPOSAL RFP NO. 15/16-32 FOR RISK MANAGEMENT CONSULTANT SERVICES PROPOSALS DUE: NOVEMBER 13, 2015 @ 4:00 P.M. GENERAL SERVICES DEPARTMENT 494 MAIN ST. MANCHESTER, CT 06040

More information

HUNTERSVILLE GATEWAY APPROX 327 HUNTERSVILLE GATEWAY DR HUNTERSVILLE, NC ABC STORE # 22

HUNTERSVILLE GATEWAY APPROX 327 HUNTERSVILLE GATEWAY DR HUNTERSVILLE, NC ABC STORE # 22 REQUEST FOR QUALIFICATIONS (RFQ) For ARCHITECTURAL/ENGINEERING SERVICES FOR THE MECKLENBURG COUNTY ALCOHOLIC BEVERAGE CONTROL BOARD HUNTERSVILLE GATEWAY APPROX 327 HUNTERSVILLE GATEWAY DR HUNTERSVILLE,

More information

Request for Qualifications

Request for Qualifications Request for Qualifications Needs Assessment and Feasibility Study For New El Centro Public Library Facility Release Date: January 22, 2015 Contact Information: City of El Centro Community Services Department

More information

REQUEST FOR PROPOSAL (RFP) # DESIGN BUILD NEW CHIEFLAND MIDDLE/HIGH SCHOOL CONSULTANTS' COMPETITIVE NEGOTIATION ACT (CCNA)

REQUEST FOR PROPOSAL (RFP) # DESIGN BUILD NEW CHIEFLAND MIDDLE/HIGH SCHOOL CONSULTANTS' COMPETITIVE NEGOTIATION ACT (CCNA) REQUEST FOR PROPOSAL (RFP) # 2017-01 DESIGN BUILD NEW CHIEFLAND MIDDLE/HIGH SCHOOL CONSULTANTS' COMPETITIVE NEGOTIATION ACT (CCNA) EXHIBIT I SCOPE OF WORK PREPARED BY: LEVY COUNTY SCHOOL BOARD FACILITIES

More information

Greater Dayton Regional Transit Authority 4 S. Main Street Dayton, OH 45402

Greater Dayton Regional Transit Authority 4 S. Main Street Dayton, OH 45402 Greater Dayton Regional Transit Authority 4 S. Main Street Dayton, OH 45402 February 25, 2016 TO: RE: Prospective Proposers Request for Quotation (RFQ) Schedules & Maps Layout and Updates The Greater Dayton

More information

Request for Proposals Architectural and Engineering Design Services associated with

Request for Proposals Architectural and Engineering Design Services associated with Request for Proposals Architectural and Engineering Design Services associated with SAGE PARK MIDDLE SCHOOL PARTIAL ROOF REPLACEMENT 25 SAGE PARK ROAD WINDSOR, CT 06095 THIS IS AN INVITATION FOR PROPOSALS

More information

REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER

REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER The Town of Griswold is requesting qualifications statements leading to proposals for Construction Management Services for the construction of the Griswold

More information

MODIFIED REQUEST FOR PROPOSALS. PROFESSIONAL SERVICES FOR FIRE STATION NO. 1 GEOTHERMAL TEST WELL Activity ID

MODIFIED REQUEST FOR PROPOSALS. PROFESSIONAL SERVICES FOR FIRE STATION NO. 1 GEOTHERMAL TEST WELL Activity ID CITY OF DES MOINES ENGINEERING DEPARTMENT MODIFIED REQUEST FOR PROPOSALS PROFESSIONAL SERVICES FOR FIRE STATION NO. 1 GEOTHERMAL TEST WELL Activity ID 21-2011-063 1. Purpose: The City of Des Moines, Iowa,

More information

Request for Proposal

Request for Proposal Central Whidbey Island Fire & Rescue 1164 Race Road Coupeville, WA 98239 Professionalism Integrity Compassion Excellence (360) 678-3602 www.cwfire.org Request for Proposal Fire Station Planning and Design

More information

PHASE 1 STAFF FACILITIES LOCKER ROOM

PHASE 1 STAFF FACILITIES LOCKER ROOM CARMEL AREA WASTEWATER DISTRICT Carmel, California REQUEST FOR QUALIFICATIONS CONSTRUCTION/BUILDING SERVICES FOR: PHASE 1 STAFF FACILITIES LOCKER ROOM Issued on: October 14, 2014 QUALIFICATIONS DUE: November

More information

WINDSOR HIGH SCHOOL POOL HOUSE HVAC UNIT REPLACEMENT PROJECT 50 SAGE PARK ROAD. WINDSOR, CT

WINDSOR HIGH SCHOOL POOL HOUSE HVAC UNIT REPLACEMENT PROJECT 50 SAGE PARK ROAD. WINDSOR, CT INVITATION TO BID Contractor Services Associated with: WINDSOR HIGH SCHOOL POOL HOUSE HVAC UNIT REPLACEMENT PROJECT 50 SAGE PARK ROAD. WINDSOR, CT 06095 THIS IS AN INVITATION FOR BIDS AND THE TOWN RESERVES

More information

AIA Document A201 TM 1997

AIA Document A201 TM 1997 AIA Document A201 TM 1997 General Conditions of the Contract for Construction for the following PROJECT: (Name and location or address): A201 conversion Michigan State University East Lansing, MI THE OWNER:

More information

CITY OF CONROE PURCHASING DEPARTMENT REQUEST FOR PROPOSALS

CITY OF CONROE PURCHASING DEPARTMENT REQUEST FOR PROPOSALS CITY OF CONROE PURCHASING DEPARTMENT REQUEST FOR PROPOSALS REQUEST FOR PROPOSAL No. 2018-621 RESIDENTIAL CURBSIDE TEXTILE RECYCLING SERVICE The City of Conroe is seeking proposals from qualified firms

More information

Town of Manchester, Connecticut General Services Department

Town of Manchester, Connecticut General Services Department Town of Manchester, Connecticut General Services Department Request for Qualifications/Proposal Architectural and Related Consultant Services For Elementary Schools Facilities Study RFP 17/18-67 Proposals

More information

Document A133 TM. AGREEMENT made as of the day of in the year Two Thousand and Sixteen. BETWEEN the Owner:

Document A133 TM. AGREEMENT made as of the day of in the year Two Thousand and Sixteen. BETWEEN the Owner: Document A133 TM 2009 Standard Form of Agreement Between Owner and Construction Manager as Constructor where the basis of payment is the Cost of the Work Plus a Fee with a Guaranteed Maximum Price AGREEMENT

More information

REQUEST FOR QUALIFICATIONS (RFQ) FOR DSA INSPECTOR OF RECORD (IOR) SERVICES. April 18, 2006

REQUEST FOR QUALIFICATIONS (RFQ) FOR DSA INSPECTOR OF RECORD (IOR) SERVICES. April 18, 2006 REQUEST FOR QUALIFICATIONS (RFQ) FOR DSA INSPECTOR OF RECORD (IOR) SERVICES April 18, 2006 Sealed Statement of Qualification documents must be received no later than Noon on Monday, May 1, 2006, at the

More information

WEST VALLEY SANITATION DISTRICT

WEST VALLEY SANITATION DISTRICT WEST VALLEY SANITATION DISTRICT Request for Proposal (RFP) for Independent External Audit Services RFP #: FIN 2015 1 Schedule of Key Events: RFP Release Date: April 14, 2015 Written Questions Due: 4:00

More information

EXHIBIT "A" RESPONSIBILITIES AND SERVICES OF PROGRAM MANAGER 1. BASIC SERVICES A-1 2. GENERAL PROGRAM SERVICES A-6

EXHIBIT A RESPONSIBILITIES AND SERVICES OF PROGRAM MANAGER 1. BASIC SERVICES A-1 2. GENERAL PROGRAM SERVICES A-6 EXHIBIT "A" RESPONSIBILITIES AND SERVICES OF PROGRAM MANAGER 1. BASIC SERVICES A-1 2. GENERAL PROGRAM SERVICES A-6 3. PLANNING AND ADMINISTRATION A-6 OF THE PROJECT 4. PRECONSTRUCTION PHASE A-7 5. PRE-BIDDING

More information

SAN DIEGO CONVENTION CENTER CORPORATION

SAN DIEGO CONVENTION CENTER CORPORATION SAN DIEGO CONVENTION CENTER CORPORATION REQUEST FOR PROPOSALS FOR CONSTRUCTION PROJECT MANAGEMENT RFP # 19-1159 Issue Date: Friday, October 5, 2018 Pre-Bid Conference: Pre-Bid Question Deadline: Bid Deadline:

More information

Town of Manchester, Connecticut General Services Department. Request for Proposal

Town of Manchester, Connecticut General Services Department. Request for Proposal Town of Manchester, Connecticut General Services Department Request for Proposal Engineering Services for Manganese Removal from Globe Hollow Treated Surface Water RFP# 17/18-34 Proposals Due: October

More information

SUBCONTRACT (SHORT FORM)

SUBCONTRACT (SHORT FORM) SUBCONTRACTOR: PHONE SUBCONTRACT (SHORT FORM) PROJECT: LOCATION: This agreement is made and effective, by and between SUN CONSTRUCTION & FACILITY SERVICES, INC. (Contractor) and (Subcontractor) which are

More information

SECTION SUPPLEMENTARY CONDITIONS

SECTION SUPPLEMENTARY CONDITIONS SECTION 00800 SUPPLEMENTARY CONDITIONS PART 1 GENERAL 1.01 GENERAL CONDITIONS A. The Supplementary Conditions modify, delete and/or add to the General Conditions, AIA Document A201/Cma, Construction Management

More information

DESIGN PROFESSIONAL SERVICES (Type) MASTER CONTRACT CONTRACT NO.

DESIGN PROFESSIONAL SERVICES (Type) MASTER CONTRACT CONTRACT NO. MARICOPA COUNTY SPECIAL HEALTHCARE DISTRICT dba MARICOPA INTEGRATED HEALTH SYSTEM Contracts Department 2611 East Pierce Street, 2nd Floor Phoenix, Arizona 85008-6092 Phone: 602-344-1403 DESIGN PROFESSIONAL

More information

Educational Use Only S A M P L E S A M P L E

Educational Use Only S A M P L E S A M P L E CONSENSUSDOCS 750 STANDARD FORM OF AGREEMENT BETWEEN CONTRACTOR AND SUBCONTRACTOR This document was developed through a collaborative effort of entities representing a wide cross-section of the construction

More information

TOWN OF WILTON REQUEST FOR QUALIFICATIONS AND PROPOSALS PENSION INVESTMENT CONSULTANT TABLE OF CONTENTS

TOWN OF WILTON REQUEST FOR QUALIFICATIONS AND PROPOSALS PENSION INVESTMENT CONSULTANT TABLE OF CONTENTS TOWN OF WILTON REQUEST FOR QUALIFICATIONS AND PROPOSALS PENSION INVESTMENT CONSULTANT TABLE OF CONTENTS I. LEGAL NOTICE. 2 II. GENERAL SPECIFICATIONS. 3 III. SUBMISSION OF QUALIFICATION STATEMENT/FEE PROPOSALS.

More information

Regional School District No. 8 REQUEST FOR PROPOSALS FOR AUDITING SERVICES LEGAL NOTICE. REQUEST FOR PROPOSALS - Regional School District No.

Regional School District No. 8 REQUEST FOR PROPOSALS FOR AUDITING SERVICES LEGAL NOTICE. REQUEST FOR PROPOSALS - Regional School District No. Regional School District No. 8 REQUEST FOR PROPOSALS FOR AUDITING SERVICES LEGAL NOTICE REQUEST FOR PROPOSALS - Regional School District No. 8 REQUEST FOR PROPOSALS FOR AUDITING SERVICES Regional School

More information

REQUEST FOR PROPOSALS

REQUEST FOR PROPOSALS REQUEST FOR PROPOSALS REVEREND PETER ATKINS PARK BATHROOM PROJECT CCE PROJECT NO. 117-106 NOVEMBER 2, 2017 PREPARED BY: CITY OF COVINGTON 317 NORTH JEFFERSON AVENUE COVINGTON, LOUISIANA 70433 1.0 INTRODUCTION

More information

Request for Proposals: Environmental Site Assessment for Single Property

Request for Proposals: Environmental Site Assessment for Single Property OBDD RFP No. C2019048 Request for Proposals: Environmental Site Assessment for Single Property Proposal due date: January 29, 2019 at 3:00 p.m. Pacific Time 1.0 SOLICITATION INFORMATION AND REQUIREMENTS

More information

Date: Subcontractor or Supplier. Shiel Sexton Company, Inc.

Date: Subcontractor or Supplier. Shiel Sexton Company, Inc. Date: To: From: Subject: Subcontractor or Supplier Shiel Sexton Company, Inc. Subcontractor & Supplier Information Form Shiel Sexton has taken pride over the years to provide top quality buildings to its

More information

WESTPORT BOARD OF EDUCATION 110 MYRTLE AVENUE WESTPORT, CT SPECIFICATION COVER SHEET BID # BOE PURCHASE OF 3PAR EQUIPMENT

WESTPORT BOARD OF EDUCATION 110 MYRTLE AVENUE WESTPORT, CT SPECIFICATION COVER SHEET BID # BOE PURCHASE OF 3PAR EQUIPMENT WESTPORT BOARD OF EDUCATION 110 MYRTLE AVENUE WESTPORT, CT 06880 203 341-1002 SPECIFICATION COVER SHEET VENDOR MUST ENCLOSE TWO COPIES OF THIS SPECIFICATION COVER SHEET and TWO COPIES OF THE BID SPECIFICATIONS

More information

PATRIOT PARK CONCESSION OPERATION BID DOCUMENTS. 4. Patriot Park Concession Operation Agreement between Park Board and Contractor

PATRIOT PARK CONCESSION OPERATION BID DOCUMENTS. 4. Patriot Park Concession Operation Agreement between Park Board and Contractor PATRIOT PARK CONCESSION OPERATION BID DOCUMENTS 1. Notice to Bidders 2. Bid Form 3. Instructions, Project Scope and Specifications 4. Patriot Park Concession Operation Agreement between Park Board and

More information

Greater Dayton Regional Transit Authority 4 S. Main Street Dayton, OH 45402

Greater Dayton Regional Transit Authority 4 S. Main Street Dayton, OH 45402 Greater Dayton Regional Transit Authority 4 S. Main Street Dayton, OH 45402 January 3, 2017 TO: RE: Prospective Proposers Request for Quotation (RFQ) RFQ 17-01 First Aid Kits, Installation, and Vendor

More information

AGREEMENT FOR TRANSPORTATION SERVICES

AGREEMENT FOR TRANSPORTATION SERVICES AGREEMENT FOR TRANSPORTATION SERVICES This Agreement is made this day of 20, by and between Long Island University ( University ), an educational institution incorporated and doing business under the laws

More information

SILVER FALLS SCHOOL DISTRICT 4J REQUEST FOR PROPOSALS REAL ESTATE SALES SERVICES

SILVER FALLS SCHOOL DISTRICT 4J REQUEST FOR PROPOSALS REAL ESTATE SALES SERVICES SILVER FALLS SCHOOL DISTRICT REQUEST FOR PROPOSALS REAL ESTATE SALES SERVICES DEADLINE FOR RECEIPT OF RFP: TO BE OPENED BY: May 1, 2016 at 3:00 p.m. Superintendent Andy Bellando Silver Falls School District

More information

RFP # SPECIAL MAGISTRATE SERVICES FOR CODE ENFORCEMENT CASES

RFP # SPECIAL MAGISTRATE SERVICES FOR CODE ENFORCEMENT CASES RFP # 2018-06 SPECIAL MAGISTRATE SERVICES FOR CODE ENFORCEMENT CASES The Baker County Board of County Commissioners, Florida (County) will receive sealed proposals until 3:00 p.m. local time, on April

More information

REQUEST FOR PROPOSAL (RFP) WILTON MUNICIPAL SOLAR PROJECT

REQUEST FOR PROPOSAL (RFP) WILTON MUNICIPAL SOLAR PROJECT REQUEST FOR PROPOSAL (RFP) WILTON MUNICIPAL SOLAR PROJECT The Town of Wilton is seeking proposals for an engineering, procurement and construction contractor ( EPC Contractor ) for roof-mounted solar photovoltaic

More information

LEGAL ADVERTISEMENT CITY OF WINTER GARDEN REQUEST FOR QUALIFICATIONS (RFQ) RFQ #EN DESIGN CRITERIA PROFESSIONAL SERVICES

LEGAL ADVERTISEMENT CITY OF WINTER GARDEN REQUEST FOR QUALIFICATIONS (RFQ) RFQ #EN DESIGN CRITERIA PROFESSIONAL SERVICES LEGAL ADVERTISEMENT CITY OF WINTER GARDEN REQUEST FOR QUALIFICATIONS (RFQ) RFQ #EN13-004 DESIGN CRITERIA PROFESSIONAL SERVICES REQUEST FOR QUALIFICATIONS (RFQ) NO. EN13-004 FOR A DESIGN CRITERIA PROFESSIONAL

More information

BAKER LAKE WATER REMOVAL, DEBRIS REMOVAL AND RESTORATION PROJECT FALLON COUNTY, MONTANA REQUEST FOR QUALIFICATIONS FOR ENGINEERING SERVICES

BAKER LAKE WATER REMOVAL, DEBRIS REMOVAL AND RESTORATION PROJECT FALLON COUNTY, MONTANA REQUEST FOR QUALIFICATIONS FOR ENGINEERING SERVICES BAKER LAKE WATER REMOVAL, DEBRIS REMOVAL AND RESTORATION PROJECT FALLON COUNTY, MONTANA REQUEST FOR QUALIFICATIONS FOR ENGINEERING SERVICES BAKER LAKE WATER REMOVAL, DEBRIS REMOVAL & RESTORATION PROJECT

More information

REQUEST FOR QUALIFICATIONS NATURAL RESOURCES, TECHNICAL AND/OR ENGINEERING SERVICES FOR MINING PERMIT APPLICATIONS RFQ#

REQUEST FOR QUALIFICATIONS NATURAL RESOURCES, TECHNICAL AND/OR ENGINEERING SERVICES FOR MINING PERMIT APPLICATIONS RFQ# REQUEST FOR QUALIFICATIONS NATURAL RESOURCES, TECHNICAL AND/OR ENGINEERING SERVICES FOR MINING PERMIT APPLICATIONS RFQ# 2018-19 Issued By: Baker County Board of County Commissioners 55 North 3 rd Street

More information

REQUEST FOR QUALIFICATIONS FOR ENVIRONMENTAL CONSULTANT SERVICES

REQUEST FOR QUALIFICATIONS FOR ENVIRONMENTAL CONSULTANT SERVICES Dear Interested Party: Date: November 6, 2017 REQUEST FOR QUALIFICATIONS FOR ENVIRONMENTAL CONSULTANT SERVICES The Connecticut Housing Finance Authority ("CHFA") requests written qualifications for Environmental

More information

ARCHITECTURAL/DESIGN SERVICES LAKEVILLE POLICE STATION BUILDING PROJECT LAKEVILLE, MASSACHUSETTS

ARCHITECTURAL/DESIGN SERVICES LAKEVILLE POLICE STATION BUILDING PROJECT LAKEVILLE, MASSACHUSETTS TOWN OF LAKEVILLE REQUEST FOR QUALIFICATIONS (RFQ) FOR ARCHITECTURAL/DESIGN SERVICES FOR THE LAKEVILLE POLICE STATION BUILDING PROJECT LAKEVILLE, MASSACHUSETTS Proposals Due: 11/30/16 @ 2:00 PM Late Proposals

More information

LEGAL NOTICE REQUEST FOR QUALIFICATIONS. Broome County Multi-Jurisdictional All-Hazard Mitigation Plan Update

LEGAL NOTICE REQUEST FOR QUALIFICATIONS. Broome County Multi-Jurisdictional All-Hazard Mitigation Plan Update LEGAL NOTICE Broome County is seeking REQUEST FOR QUALIFICATIONS (RFQ) from all interested and qualified firms to provide professional services to the Broome County Department of Planning and Economic

More information

Request for Qualifications (RFW: 18-19/01) Architectural/Engineering Firms

Request for Qualifications (RFW: 18-19/01) Architectural/Engineering Firms Request for Qualifications (RFW: 18-19/01) Architectural/Engineering Firms RFQ Due Date: May 3, 2019 @ 2:00 p.m. Mr. Alonso Casas, Project Manager Building 10, Room #16 Imperial Community College District

More information

ALPINE SCHOOL DISTRICT 490 North State Street, Lindon, Utah Office (801) Fax Number (801)

ALPINE SCHOOL DISTRICT 490 North State Street, Lindon, Utah Office (801) Fax Number (801) ALPINE SCHOOL DISTRICT 490 North State Street, Lindon, Utah 84042 Office (801) 717-4760 Fax Number (801) 785-8782 July 12, 2011 Notice to Contractors: Alpine School District is requesting Bids for Construction

More information

Request for Qualifications (RFQ)

Request for Qualifications (RFQ) Snohomish County Fire Protection District No. 21 Request for Qualifications (RFQ) ARCHITECTURAL/ENGINEERING CONSULTING SERVICES FOR New Fire Station Snohomish County Fire Protection District No. 21 District

More information

REQUEST FOR QUALIFICATIONS (RFQ) PROFESSIONAL ENGINEERING SERVICES ON A CONTINUING CONTRACT BASIS

REQUEST FOR QUALIFICATIONS (RFQ) PROFESSIONAL ENGINEERING SERVICES ON A CONTINUING CONTRACT BASIS REQUEST FOR QUALIFICATIONS (RFQ) PROFESSIONAL ENGINEERING SERVICES ON A CONTINUING CONTRACT BASIS I. GENERAL The Westgate/Belvedere Homes Community Redevelopment Agency (WCRA) is seeking proposals from

More information

REQUEST FOR PROPOSALS FOR RISK MANAGEMENT INSURANCE CONSULTANT/BROKER SERVICES

REQUEST FOR PROPOSALS FOR RISK MANAGEMENT INSURANCE CONSULTANT/BROKER SERVICES Dear Interested Party: Date: August 14, 2017 REQUEST FOR PROPOSALS FOR RISK MANAGEMENT INSURANCE CONSULTANT/BROKER SERVICES The Connecticut Housing Finance Authority ("CHFA") requests proposals for Risk

More information

REQUEST FOR PROPOSALS Public Relations Services ALBANY CAPITAL CENTER TABLE OF ARTICLES 1. DEFINITIONS 5. CONSIDERATION OF RESPONSES

REQUEST FOR PROPOSALS Public Relations Services ALBANY CAPITAL CENTER TABLE OF ARTICLES 1. DEFINITIONS 5. CONSIDERATION OF RESPONSES REQUEST FOR PROPOSALS Public Relations Services ALBANY CAPITAL CENTER TABLE OF ARTICLES 1. DEFINITIONS 5. CONSIDERATION OF RESPONSES 2. CRITICAL DATES 6. FORM OF AGREEMENT BETWEEN SMG AND RESPONDENT 3.

More information

REQUEST FOR QUALIFICATIONS (RFQ) FOR 2015 PROFESSIONAL SERVICES ON-CALL LIST

REQUEST FOR QUALIFICATIONS (RFQ) FOR 2015 PROFESSIONAL SERVICES ON-CALL LIST REQUEST FOR QUALIFICATIONS (RFQ) FOR 2015 PROFESSIONAL SERVICES ON-CALL LIST I. OVERVIEW The District is seeking qualified firms to provide On-Call Professional Services in support of Capital Improvement

More information

WESTPORT BOARD OF EDUCATION 110 MYRTLE AVENUE WESTPORT, CT

WESTPORT BOARD OF EDUCATION 110 MYRTLE AVENUE WESTPORT, CT WESTPORT BOARD OF EDUCATION 110 MYRTLE AVENUE WESTPORT, CT 06880 203 341-1002 SPECIFICATION COVER SHEET BID #18-002-BOE VENDOR MUST ENCLOSE TWO COPIES OF THIS SPECIFICATION COVER SHEET and TWO COPIES OF

More information

Santa Ana Unified School District

Santa Ana Unified School District Santa Ana Unified School District Facilities & Governmental Relations Orin Williams, Assistant Superintendent Stefanie P. Phillips, Ed.D. Superintendent of Schools REQUEST FOR QUALIFICATIONS FOR PROPERTY

More information

AGREEMENT BETWEEN THE VENTURA COUNTY TRANSPORTATION COMMISSION AND Conrad LLP FOR PROFESSIONAL SERVICES

AGREEMENT BETWEEN THE VENTURA COUNTY TRANSPORTATION COMMISSION AND Conrad LLP FOR PROFESSIONAL SERVICES AGREEMENT BETWEEN THE VENTURA COUNTY TRANSPORTATION COMMISSION AND Conrad LLP FOR PROFESSIONAL SERVICES This is an agreement ( Agreement ) by and between the Ventura County Transportation Commission, hereinafter

More information

ARTICLE 8: BASIC SERVICES

ARTICLE 8: BASIC SERVICES THE SCOPE OF SERVICES ADDED BY THIS AMENDMENT IS FOR A CM AT RISK PROJECT ONLY. THE SCOPE OF SERVICES SPECIFIED BELOW INCLUDES ARTICLES 8.1, 8.3, 8.4, 8.5, 8.6, 8.7 AND 8.8. THE SERVICES SPECIFIED IN ARTICLE

More information

REQUEST FOR PROPOSAL (RFP) # FY DESIGN BUILD COMPRESSED NATURAL GAS (CNG) FUELING STATION CONSULTANTS COMPETITIVE NEGOTIATION ACT (CCNA)

REQUEST FOR PROPOSAL (RFP) # FY DESIGN BUILD COMPRESSED NATURAL GAS (CNG) FUELING STATION CONSULTANTS COMPETITIVE NEGOTIATION ACT (CCNA) REQUEST FOR PROPOSAL (RFP) # FY 2014 2015 001 DESIGN BUILD COMPRESSED NATURAL GAS (CNG) FUELING STATION CONSULTANTS COMPETITIVE NEGOTIATION ACT (CCNA) EXHIBIT I SCOPE OF WORK PREPARED BY: CITY OF HALLANDALE

More information

CITY OF KIRKLAND REQUEST FOR PROPOSALS BUSINESS RETENTION CONSULTANT JOB # CM

CITY OF KIRKLAND REQUEST FOR PROPOSALS BUSINESS RETENTION CONSULTANT JOB # CM CITY OF KIRKLAND REQUEST FOR PROPOSALS BUSINESS RETENTION CONSULTANT JOB # 24-09-CM BACKGROUND The City of Kirkland Economic Development Program is focused on business retention. The satisfaction of existing

More information

OKEECHOBEE COUNTY ROAD STRIPING AND MARKING SERVICES

OKEECHOBEE COUNTY ROAD STRIPING AND MARKING SERVICES OKEECHOBEE COUNTY ROAD STRIPING AND MARKING SERVICES RFP 2017-17 Due September 27, 2017 Room 123 304 NW 2 nd Street Okeechobee, FL 34972 1 INSTRUCTIONS TO BIDDERS In order to be considered responsive,

More information

COUNTY OF WISE, VIRGINIA REQUEST FOR QUALIFICATIONS FOR PROFESSIONAL CONSULTING SERVICES BROWNFIELDS GRANT. Date of Issue: September 25, 2017

COUNTY OF WISE, VIRGINIA REQUEST FOR QUALIFICATIONS FOR PROFESSIONAL CONSULTING SERVICES BROWNFIELDS GRANT. Date of Issue: September 25, 2017 COUNTY OF WISE, VIRGINIA REQUEST FOR QUALIFICATIONS FOR PROFESSIONAL CONSULTING SERVICES BROWNFIELDS GRANT Date of Issue: September 25, 2017 Due Date for Proposal: October 6, 2017 COUNTY OF WISE, VA REQUEST

More information

REQUEST FOR PROPOSAL. Architectural and Space Planning Services

REQUEST FOR PROPOSAL. Architectural and Space Planning Services COLORADO HOUSING AND FINANCE AUTHORITY REQUEST FOR PROPOSAL (RFP) COLORADO HOUSING AND FINANCE AUTHORITY 1981 BLAKE STREET DENVER, CO 80202 REQUEST FOR PROPOSAL Architectural and Space Planning Services

More information

REQUEST FOR PROPOSALS Comprehensive User Fee Study and Full Cost Allocation Plan

REQUEST FOR PROPOSALS Comprehensive User Fee Study and Full Cost Allocation Plan REQUEST FOR PROPOSALS Comprehensive User Fee Study and Full Cost Allocation Plan RFP Release Date January 5, 2018 Proposal Submittal Deadline February 2, 2018-4:00 p.m. Contact Person: Sonya Williams Finance

More information

Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project

Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project Document A105 2007 Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project AGREEMENT made as of the in the year (In words, indicate day, month and year.) BETWEEN

More information